RJ Bullard/Bridge Railing 02SECTION 1300
AGREEMENT
THIS CONTRACT, by and between the CITY OF LA QUINTA, a municipal corporation, herein referred to
as "City, and R. J. Bullard Construction, Inc., herein referred to as, "Contractor."
WITNESSETH:
In consideration of their mutual covenants, the parties hereto agree as follows:
1. Contractor shall furnish all necessary labor, material, equipment, transportation and services for
Project No. 99-05A, Bridge Barrier and Railing Enhancements at the Jefferson Street Bridge over the All -
American Canal, in the City of La Quinta, California pursuant to the Invitation to Bid, dated December 19, 2001,
the project Specifications, and Contractor's Bid, dated, January 25, 2002, all of which documents shall be considered
a part hereof as though fully set herein.
Should any provisions of Contractor's Bid be in conflict with the Notice Inviting Bids, Specifications,
or this Contract, then the provisions of said Contract, Specifications, and Invitation to Bid shall be controlling, in that
order of precedence. The time frames for construction work shall be in accordance with those specified in the
Contractor's Bid.
2. Contractor will comply with all Federal, State, County, and La Quinta Municipal Code, which are,
as amended from time to time, incorporated herein by reference.
All work shall be done in a manner satisfactory to the City Engineer.
4. Contractor shall commence work after the issuance of a written Notice to Proceed and agrees to have
all work completed within 75 Consecutive Calendar Days from the date specified in the Notification to Proceed.
5. In consideration of said work, City agrees to pay Contractor such sums as shall be approved by the
City Engineer at lump sums and/or unit prices stated in the Contractor's Bid, the base consideration of ONE
HUNDRED TWENTY THOUSAND FORTY DOLLARS and NO/CENTS ($120,040.00), plus such additional
amounts for adjustments to the estimated quantities contained in the Bidder's Schedule and for extra work covered by
approved Change Orders, if any, as are provided for in the Specifications, without prior approval of the City Council
and written amendment to this Contract. All payments shall be subject to approval by the City Engineer and shall be
in accordance with the terms, conditions, and procedures provided in the Specifications.
6. ' The Contractor shall not knowingly pay less than the general prevailing rate for per diem wages, as
determined by the State of California Department of Industrial Relations and referred to in the Invitation to Bid, to any
workman employed for the work to be performed under this contract; and the Contractor shall forfeit as a penalty to
the City the sum of Twenty -Five Dollars ($25.00) for each calendar day, or fraction thereof, for such workman paid
by him or by any subcontractor under him in violation of this provision (Sections 1770-1777, Labor Code of
California).
7. Concurrently with the execution of this Contract, Contractor shall furnish bonds of a surety
satisfactory to City, as provided in said Specifications or Invitation to Bid, the cost of which shall be paid by Contractor.
8. Contractor agrees to indemnify, hold harmless, release and defend (even if the allegations are false,
fraudulent or groundless), to the maximum extent permitted by law, the City, its City Council and each member
thereof, and its officers, employees, commission members and representatives, from any and all liability, loss, suits,
claims, damages, costs, judgements and expenses (including attorney's fees and costs of litigation) which in whole or
Agreement 1300-1
in part are claimed to result from or to arise out of the usage or operation, including the malfunctioning of, or, any
injury caused by, any product purchased herein; or any acts, errors or omissions (including, without limitation,
professional negligence) of Contractor, its employees, representatives, subcontractors, or agents in connection with the
performance of this Contract. The is agreement to indemnify includes, but is not limited to, personal injury (including
death at any time) and damage to property (including, but without limitation, contract or tort or patent, copyright, trade
secret or trademark infringement) sustained by any person or persons (including, but not limited to, companies, or
corporations, Contractor and its employees or agents, and members of the general public).
9. Except as otherwise required, Contractor shall concurrently with the execution of this contract,
furnish the City satisfactory evidence of insurance of the kinds and in the amounts provided in said Specifications.
This insurance shall be kept in full force and effect by Contractor during this entire contract and all premiums thereon
shall be promptly paid by it. Each policy shall further state that it cannot be canceled without 30 days unconditional
written notice to the City and shall name the City as an additional insured. Contractor shall furnish evidence of having
in effect, and shall maintain, Workers Compensation Insurance coverage of not less than the statutory amount or
otherwise show a certificate of self-insurance, in accordance with the Workers Compensation laws of the State of
California. Failure to maintain the required amounts and types of coverage throughout the duration of this Contract
shall constitute a material breach of this Contract.
10. Contractor shall forfeit as a penalty to City $25.00 for each laborer, workman, or mechanic employed
in the execution of this Contract by said Contractor, or any subcontractor under it, upon any of the work herein
mentioned, for each calendar day during which such laborer, workman, or mechanic is required or permitted to work
at other than a rate of pay provided by law for more than 8 hours in any one calendar day and 40 hours in any one
calendar week, in violation of the provisions of Sections 1810-1815 of the Labor Code of the State of California.
11. In accepting this Contract, Contractor certifies that in the conduct of its business it does not deny the
right of any individual to seek, obtain and hold employment without discrimination because of race, religious creed,
color, national origin, ancestry, physical handicap, medical condition, marital status, sex or age as provided in the
California Fair Employment Practice Act (Government Code Sections 12900, et seq.) Contractor agrees that a finding
by the State Fair Employment Practices Commission that Contractor has engaged during the term of this Contract in
any unlawful employment practice shall be deemed a breach of this Contract and Contractor shall pay to City $500.00
liquidated damages for each such breach committed under this contract.
12. Contractor also agrees that for contracts in excess of $30,000 and more than 20 calendar days
duration, that apprentices will be employed without discrimination in an approved program in a ratio established in
the apprenticeship standards of the craft involved (Sections 1777.5 and 1777.6, Labor Code of California). Contractors
who willfully fail to comply will be denied the right to bid on public projects for a period of six months in addition to
other penalties provided by law.
13. This Contract shall not be assignable by Contractor without the written consent of City.
14. Contractor shall notify the City Engineer (in writing) forthwith when the Contract is deemed
completed.
15. In accepting this Contract, Contractor certifies that no member or officer of the firm or corporation
is an officer or employee of the City except to the extent permitted by law.
16. Contractor certifies that it is the holder of any necessary California State Contractor's License and
authorized to undertake the above work.
17. The City, or its authorized auditors or representatives, shall have access to and the right to audit and
reproduce any of the Contractor records to the extent the City deems necessary to insure it is receiving all money to
which it is entitled under the contract and/or is paying only the amounts to which Contractor is properly entitled under
the Contract or for other purposes relating to the Contract.
18. The Contractor shall maintain and preserve all such records for a period of at least three years after
termination of the contract.
Agreement 1300-2
19. The Contractor shall maintain all such records in the City of La Quinta. If not, the Contractor shall,
upon request, promptly deliver the records to the City or reimburse the City for all reasonable and extra costs incurred
in conducting the audit at a location other than at City offices including, but not limited to, such additional (out of the
City) expenses for personnel, salaries, private auditors, travel, lodging, meals and overhead.
20. The further terms, conditions, and covenants of the Contract are set forth in the Contract Documents,
each of which is by this reference made a part hereof.
The remainder of this page is intentionally left blank.
Agreement 1300-3
IN WITNESS WHEREOF, the parties have executed this Agreement as of the dates stated below.
Dated: -(:n -.
ATTEST:
June Greek, City Clerk
APPROVED AS TO FORM:
ACi*Attome�y
Dated: j /V/"p z
Dated: Z
A
Dated: `5 G2 co —0
Dated: Q d o4_
CONTRACTOR:
By:
Name: ee94,T
Title:
1)0,em Zc�
Name:uS�r/
Title:
"CONTRACTOR"
(If corporation, affix seal)
Agreement 1300-4
SF1665
SECTION 1320
IZ3140 I DI:
KNOW ALL MEN BY THESE PRESENTS:
THAT the City of La Quinta, a municipal corporation, hereinafter designated the City, has, on
FEBRUARY 19, 2002, awarded to R. J. BULLARD CONSTRUCTION, INC., hereinafter designated as the
Principal, a Contract for PROJECT NO 99-05A, BRIDGE BARRIER AND RAILING ENHANCEMENTS AT
THE JEFFERSON STREET BRIDGE OVER THE ALL-AMERICAN CANAL, and
WHEREAS, said Principal is required to furnish a bond in connection and with said Contract, providing that
if said Principal, or any of it or its subcontractors shall fail to pay for any materials, provisions, or other supplies used
in, upon, for, or about the performa»oe of the work contracted to be done, or for any work or labor done thereon of any
kind, the Surety of this bond will pay the same to the extent hereinafter set forth:
United States Fidelity and
NOW, THEREFORE, we, the Principal, and Guaranty Company , as Surety, arc held
and firmly bound unto the City in the just and full amount of ONE HUNDRED TWENTY THOUSAND FORTY
DOLLARS AND NOXENTS ($120,040.00) lawful money of the United States, for the payment of which sum well
and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally,
firmly by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH, that if said Principal, it or its heirs, executors,
administrators, successors, or assigns, shall fail to pay for any materials, provisions, or other supplies used in, upon,
for, or about the performance of the work contracted to be done, or for any work or labor thereon of any kind or for
amount due under the Unemployment Insurance Act with respect to such work or labor, or for any amounts due, or
to be withheld pursuant to Sections 18806 of the Revenue and Taxation Code of the State of California with respect
to suchwork or labor, then said surety will pay the same in or to an amount not exceeding the amount hereinabove set -
forth, and also will pay in case suit is brought upon this bond, such reasonable attorney's fees to the City as shall be
fixed by the court.
This bond shall insure tothe benefit of any and all persons, companies, and corporations named in Section
3181 of the Civil Code of the State of California so as to give a right of action to them or their assigns in any suit
brought upon this bond.
And the said Surety, for: value received, hereby stipulates and agrees that no change, extension of time,
alteration, or addition of the terms of the Contract or to the work to be performed thereunder or the specifications
accompanying the same shall, in any way, affect its obligations of this bond, and it does hereby waive notice of any
change, extension of time, alteration, or addition to the terms of the contract or to the work or to the specifications.
Said Surety hereby waives the previsions of Sections 2819 and 2845 of the Civil Code of the State of California.
Payment Bond 1300-7
IN WITNESS WHEREOF, the Principal and Surely Dave executed this instrument under their
seals this 5th day of March , i,v 200 rn
the name and corporate seal of each
corporate party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to
authority of its governing body.
R.J. Bullard Construction, Inc.
Principal
(Seal)
Signature for Principal
dJE-L�'T�..y le'e
Title of Signatory
United States Fidelity and Guaranty Company
Surety
(Seal) •
a.
Signature for Surety Nanette Mariella—Myers
Attot:;ney--in—Fact
Title of Signatory
United States Fidelity and Guaranty Company
333 City Boulevard West, Suite 1100
Orange, CA 92868
Address of Surety
(714) 620-1200
Phone # of Surety
Jeff Derosier
Contact. Person For Surety
Payment Bond 1300-5
CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
No. 5907
State of California
County of Orange
S /o;, before me, Leigh McDonough Notary Public
On 3/,
DATE NAME, TITLE OF OFFICER - E.G., "JANE DOE, NOTARY PUBLIC"
personally appeared Nanette Mariella-Myers ,
NAME(S) OF SIGNER(S)
® personally known to me - OR - ❑ proved to me on the basis of satisfactory evidence to be the person(s)
whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her/their
signature(s) on the instrument the person(s), or the entity upon
LEIGM MCDONOUGH behalf of which the person(s) acted, executed the instrument.
Commission # 1328674 Z
• Notary Public - Cstifomis -
Orange County
WITNESS my hand and official seal.
My Comm. Expirse Now 6, 204
SIGNATURE OF NO RY
OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and
could prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER
❑ INDIVIDUAL
❑ CORPORATE OFFICER
TITLE(S)
❑ PARTNER(S) LIMITED
GENERAL
® ATTORNEY -IN -FACT
❑ TRUSTEE(S)
❑ GUARDIAN/CONSERVATOR
❑ OTHER:
SIGNER IS REPRESENTING:
NAME OF PERSON(S) OR ENTITY(IES)
DESCRIPTION OF ATTACHED DOCUMENT
TITLE OR TYPE OF DOCUMENT
NUMBER OF PAGES
DATE OF DOCUMENT
SIGNER(S) OTHER THAN NAMED ABOVE
S-4067/GEEF 2/98 U 1993 NA I IUNAL NU I AKY AJJUGIA I IUN • uz313 Kemmet Ave., r.v. tsox t i a4 • %-anoga rant, %,m a , vva-i , oy
7he.9Fhul POWER OF ATTORNEY
Seaboard Surety Company United States Fidelity and Guaranty Company
St. Paul Fire and Marine Insurance Company Fidelity and Guaranty Insurance Company
St. Paul Guardian Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc.
St. Paul Mercury Insurance Company
Power of Attorney No. 22665
Certificate No. J 0 7 0 22 7
KNOW ALL MEN BY THESE PRESENTS: That Seaboard Surety Company is a corporation duly organized under the laws of the State of New York, and that
St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company and St. Paul Mercury Insurance Company are corporations duly organized under
the laws of the State of Minnesota, and that United States Fidelity and Guaranty Company is a corporation duly organized under the laws of the State of Maryland, and
that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance
Underwriters, Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do
hereby make, constitute and appoint
James A. Schaller, Rhonda C. Abel, Jane Kepner, Nanette Mariella-Myers, Mike Parizino, Linda Enright,
Jeri Apodaca and Patricia H. Brebner
Costa Mesa
California
of the City of , State , their true and lawful Attorney(s)-in-Fact,
each in their separate capacity if more than one is named above, to sign its name as surety to, and to execute, seal and acknowledge any and all bonds, undertakings,
contracts and other written instruments in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the
performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law.
IN WITNESS WHEREOF, the Companies have caused this instrument`toe signed and sealed'thig. , 31St Jay 2UU1
day of
Seaboard Surety Company Vnited States Fidelity and Guaranty Company
St. Paul Fire and Marine Insuralnce "Company Fidelity and Guaranty Insurance Company
St. Paul Guardian Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc.
S
St. Paul Mercury Insurance Company
�y� M iNs, P�•iNs�q�k, 1' �
SUfiEI O T� .....:Gq o°: 1• : y}, �y�Q3'y,-�ty, �y.�,,,�
* Y^ I,tOFPOR.1>F /v ;•'OORPORA if i p , � •`CMMTW
< aZ� 19n 1951
7.92i `°s BAL:'a° 1898
fW
AEALioI s•., a o,�(Q
m� sa' S•-..
...
��OFNEW� 19 ISN AN�
State of Maryland
City of Baltimore THOMAS E. HUIBREGTSE, Assistant Secretary
On this 31St day of July 2001 , before me, the undersigned officer, personally appeared John F. Phinney and
Thomas E. Huibregtse, who acknowledged themselves to be the Vice President and Assistant Secretary, respectively, of Seaboard Surety Company, St. Paul Fire and
Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, United States Fidelity and Guaranty Company, Fidelity and
Guaranty Insurance Company, and Fidelity and Guaranty Insurance Underwriters, Inc.; and that the seals affixed to the foregoing instrument are the corporate seals of
said Companies; and that they, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing the names of the
corporations by themselves as duly authorized officers.
QF N EAS�y� V
In Witness Whereof, I hereunto set my hand and official seal. NOTARY 0 9 pVe�IC
My Commission expires the 13th day of July, 2002. `�pq f cal as REBECCA EASLEY-ONOKALA, Notary Public
86203 Rev. 7-2000 Printed in U.S.A.
Bond No. SF1665
SECTION 1310
FAITHFUL PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS:
THAT the City of La Quinta, a municipal corporation, hereinafter designated the City, has, on February 19,
2002, awarded to R. J. BULLARD CONSTRUCTION, INC., hereinafter designated as the Principal, a Contract
for PROJECT NO 99-05A, BRIDGE BARRIER AND RAJLiNG ENHANCEMENTS AT THE JEFFERSON
STREET BRIDGE OVER THEALL-AMERICAN CANAL, and
WHEREAS, said Principal is required under the terms of said Contract to furnish a bond for the faithful
performance of said Contract:
United States Fidelity and
NOW, THEREFORE, we, the Principal, and Guaranty Company , as Surety, are
held and firmly bound unto the City in the just and full amount of ONE HUNDRED TWENTY THOUSAND
FORTY DOLLARS AND NO/CENTS ($120,040.00) lawful money of the United States, for the payment of which
sum well and truly to be made, wie bind ourselves, our heirs, executors, administrators, and successors, jointly and
severally, firmly by these presents;
THE CONDITION OF THIS OBLIGATION IS SUCH, that if said Principal, his or its heirs, executors,
administrators, successors, or assigns, shall in all things stand to and abide by, and well and truly keep and faithfully
perform the covenants, conditions, and agreements in the said contract and any alterations made as therein provided,
on his or their part to be kept and performed, at the time and in the manner therein specified, and in all respects
according to their true intent and meaning, and shall indemnify and save harmless, the City, its officers and agents
as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and
virtue.
It is acknowledged that the Contract provides for one-year guarantee period, during which time this bond
remains in full force and effort..
And the said Surety, for: value received, hereby stipulates and agrees that no change, extension of time,
alteration, or addition to the terms of the Contract or to the work to be performed thereunder or the specifications
accompanying the same shall, in any way, affect its obligations on this bond, and it does hereby waive notice of any
such change, extension of time.: alteration, or addition to the terms of the Contract or to the work or to the
specifications. Said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of
California.
I+aithM Performance Bond p 1300-5
IN WITNESS WHEREOF, the Principal and Surety have executed this instrument under their
seals this 5th day of March , 4 2002 the name and corporate seal of each
corporate party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to
authority of its governing body.
R.J. Bullard Construction, Inc.
Principal
(Seal)
Signature for Principal
, f �2fe--'--//-��5�v
Title of Signatory If
United States Fidelity and Guaranty Company
Surety
(Seal)
Signature for Surety
Nanette Mariella—Myers
Attorney —in —Fact
Title of Signatory
United States Fidelity and Guaranty Company
333 City Boulevard West, Suite 1100
Orange, CA 92868
Address of Surety
(714) 620-1200
Phone # of Surety
Jeff Derosier
Contact Person For Suretv
FaitLfut Performance Bond 1300-6
CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
No. 5907
State of California
County of Orange
On before me, Leigh McDonough Notary Public ,
ATE NAME, TITLE OF OFFICER - E.G., "JANE DOE, NOTARY PUBLIC'
personally appeared Nanette Mariella-Myers
N personally known to me - OR- ❑
NAME(S) OF SIGNER(S)
proved to me on the basis of satisfactory evidence to be the person(s)
whose name(s) is/are subscribed to the within instrument and
acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her/their
signature(s) on the instrument the person(s), or the entity upon
�Ei �00NWGH behalf of which the person(s) acted, executed the instrument.
Commission #
Notsty public -
Cal fomia
omn" county
My C,Wm, EWW0 NW 6, Z0%
WITNESS my hand and official seal.
SIGNATURE OF NOT
OPTIONAL
Though the data below is not required by law, it may prove valuable to persons relying on the document and
could prevent fraudulent reattachment of this form.
CAPACITY CLAIMED BY SIGNER
❑ INDIVIDUAL
❑ CORPORATE OFFICER
TITLE(S)
❑ PARTNER(S) LIMITED
GENERAL
® ATTORNEY -IN -FACT
❑ TRUSTEE(S)
❑ GUARDIAN/CONSERVATOR
❑ OTHER:
SIGNER IS REPRESENTING:
NAME OF PERSON(S) OR ENTITY(IES)
DESCRIPTION OF ATTACHED DOCUMENT
TITLE OR TYPE OF DOCUMENT
NUMBER OF PAGES
DATE OF DOCUMENT
SIGNER(S) OTHER THAN NAMED ABOVE
S-4067/GEEF 2/98 U 1993 NA I IUNAL NU I AKY A55UGIA I IUN • tslsb Kemmet Ave., v.U. tsox t i ts4 - uanoga varK, UA W16U`J-/ 1134
SECTION 1330
WORKERS' COMPENSATION INSURANCE CERTIFICATE
In accordance with California Labor Code Section 1861, prior to commencement of work on the Contract, the
Contractor shall sign and file with the City the following certification:
"I am aware of the provisions of Section 3700 of the Labor Code which require every employer to
be insured against liability for workers' compensation or to undertake self-insurance in accordance
with the provisions of that code, and I will comply with such provisions before commencing the
performance of the work of this contract."
Signature
Name of Contractor
Title
Date
So l G Y... .:.i l° :I ••. t. 'i Y �. l r.
Workers' Compensadon Insurance 1300-9
v = 5
c% 4
w�
CF�1 OF Ttit 9
Sheet 1 of 2
CONTRACT: BRIDGE BARRIER AND RAILING AT THE JEFFERSON STREET
BRIDGE OVER THE ALL AMERICAN CANAL PROJECT NO. 99-05-A
CONTRACTOR: R. J. Bullard Construction, Inc.
P.O. Box 1577
Bonsall, Ca. 92003-1577
CONTRACT CHANGE ORDER NO. 1
Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the
following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform
to the terms, general conditions, and special provisions of the original Contract.
DESCRIPTION OF CHANGE
This Contract Change Order allows for the construction of the Metal Beam Guard Rail originally planned for installation with the
Jefferson Street Improvements. Total Price : $ 6,044.80
Previous Contract Amount Through Change Order No. 1 $ 120,040.00
Add This Change Order $ 6,044.80
Revised Contract Total $ 126,084.80
By reason of this contract change order the time of com 'on i lusted as follows: -7- days added/deleted to contract time.
The revised contract completion date shall be: /
Submitted By: Date:
Approved By:
Date:
We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved, that we
will provide all equipment, furnish all materials, perform all labor, except as may be noted above, and perform all services necessary to complete the
above specified work, and hereby accept as full payment the amount shown above, which includes all direct and indirect overhead expenses for any
delays.
Accepted By:
Contractor:
Title:
Date:
J. Bullard Construction, Inc; 760 731 7501; Jun-13-02 12:19PM; Page 213
7]
77
X
:+
C
C
lu
V
z
z
m.s
D
C'
1�
0
3
tQA
-yi
a
�
m
�
m
O
r
iy
z
r
v
"
y
=
0
a
p
X
R
0
0
a
r
—J
TIT92.,
�
y
��
1C
m
z
Z
a
�o`
sC
�
C
J]
r
c
Lt a
i Z
a
A
z
J
Ci
o
,a.
n
i
2
>C
tim
�r
Q
0.
I
0
`
�r
V
u
o..
cz
za
o�
t . 0
r^^ a o
X X
n
f
.. Z
• >
r
x
P
�
D
n
r
�
O
.x
.{
1
O
>
o 0
r
o
70ovo
�.gop�iap
0
r
r
v
r
a�o
>C
.
,
a
�r
0
si
<
D
)'
r
>h
r
={
zp
0
m
u
n
zt
0
z
0
0
a
N
:� n 0
0 o 0
x = w
1 7 (1
A r -4
X =
T �
d
0
ar
m
C
d
C7
0
N3
O
• - P. L
H 1 4 4 . A -2 TM . NAME:
H
ti5
OF T1ati�
Sheet 1 of I
CONTRACT: BRIDGE BARRIER AND RAILING AT THE JEFFERSON STREET
BRIDGE OVER THE ALL AMERICAN CANAL PROJECT NO. 99-05-A
CONTRACTOR: R. J. Bullard Construction, Inc.
P.O. Box 1577
Bonsall, Ca. 92003-1577
CONTRACT CHANGE ORDER NO.2
Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the
following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform
to the terms, general conditions, and special provisions of the original Contract.
DESCRIPTION OF CHANGE
This Contract Change Order allows for a time extension from July 1, 2002 to July 9, 2002 , for a total of 8 consecutive calendar days with
no cost or assessed Liquidated Damages due to modifications to the rail system during fabrication. Total Price : $0.00
Previous Contract Amount Through Change Order No. 2 $ 126,084.80
Add This Change Order $ 0.00
Revised Contract Total $ 126,084.80
By reason of this contract change order the time of completion is adjusted as follows: -8- days added to contract time.
The revised contract completion date shall be: 7/09/02
Submitted By
Approved By:
gzz3L2
- 2 -7 -- vZ
We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved, that we
will provide all equipment,' furnish all materials, perform all labor, except as may be noted above, and perform all services necessary to complete the
above specified work and hereby accept as full payment the amount shown above, which includes all direct and indirect overhead expenses for any
delays.
Accepted By:D4� % D Title: Sub ec /Al Tewd e,,?"
Contractor: S. B( t fir& Date: %-"aS—
0
RE
PLEASE COMPLETE THIS INFORMATION
RECORDING REQUESTED q+{js!
L7
CITY '0
CITY C'
AND WHEN RECORDED MAI4 TO:
ere'rCew
DOC a 2002-337696
10/04/2002 08:00A Fee:NC
Page 1 of 2
E IVE D Recorded in Official Records
County of Riverside
Gary L. Orso
Assessor, County Clerk 8 Recorder
1 OIF F I C II IIIIIII (IIII III IIIII IIII IIII
IIIIII IIIIII IIIIII III III
M
S
U
PAGE
SIZE
DA
PCOR
NOCOR
SMF
MISC.
A
R
L
COPY
LONG
REFUND
NCHG
I EXAM
I�
Title of Document
T"n1o"AREA FOrm-
rn"'E`%0RDErn"\""'
USE ONL
THIS PAGE ADDED TO PROVIDE ADEQUATE SPACE FOR RECORDING INFORMATION
($3:00 Additional Recording Fee Applies)
ACR 238-02 (REV 03/02)
Return to:
CITY CLERK
City of La Quinta
P.O. Box 1504
La Quinta, Ca. 92253
NOTICE OF COMPLETION
NOTICE IS HEREBY GIVEN THAT:
1. The City of La Quinta, California, is a municipal corporation, organized and incorporated
pursuant to the laws of the State of California.
2. The City Clerk of the City of La Quinta is authorized and directed to execute, on behalf of
said City, any and all notices of completion.
3. The address of the City of La Quinta is City Hall, 78-495 Calle Tampico, La Quinta, California
(P.O. Box 1504, La Quinta, Calif. 92253.
4. The public work improvement - JEFFERSON STREET BRIDGE BARRIER & RAILING OVER THE
ALL AMERICAN CANAL - PROJECT NO. 99-05-A on the hereinafter referred to real property
within the City was COMPLETED on the 6th day of August, 2002.
5. The name of the contractor for such work of improvement was R. J. BULLARD
CONSTRUCTION, INC.
6. The property on which said public work of improvement was completed is in the City of La
Quinta, County of Riverside, State of California, and is described as follows: CHANGES IN
FABRICATION OF DECORATIVE RAILING ON CONCRETE BARRIER AT THE JEFFERSON
STREET BRIDGE BARRIER & RAILING OVER THE ALL AMERICAN CANAL
7. The street address of said property is: JEFFERSON STREET SOUTH OF AVENUE 52
DATED: August 7, 2002 CITY OF LA QUINTA, CALIFORNIA
BY
TITLE CITY CLERK
STATE OF CALIFORNIA )
COUNTY OF RIVERSIDE )
I hereby certify that I am the City Clerk of the governing board of the City Council of the City
of La Quinta, the political subdivision which executed the foregoing notice and on whose behalf I
make this verification; that I have read said notice, know its contents, and that the same is true.
I certify under penalty of perjury that the foregoing is true and correct.
Executed at La Quinta, California on August 7, 2002.
JUN GREEK, City Clerk
City of La Quinta, California
111111111mi .20m.;;=�