Loading...
07-2811 (RR)P.O. BOX 1504 78-495 CALLE TAMPICO' LA QUINTA, CALIFORNIA 92253 T4'yl " BUILDING & SAFETY DEPARTMENT BUILDING PERMIT Application Number: 07-00002811 Property Address: 51371 AVENIDA NAVARRO APN: 773-103-008-2 -000000- Application description: RE -ROOF Property Zoning: COVE RESIDENTIAL Application valuation: 13467 Applicant: Architect or Engineer: LICENSED CONTRACTOR'S DECLARATION I hereby affirm under penalty of p6jury that I am licensed under provisions of Chapter 9 (commencing with . Section 7000) of Division 3 of the Business and Professionals Code, and my License is in full force and effect. License Class: B C39 License No.: 235717 tractor: OWNER -BUILDER DECLARATION I hereby affirm under penalty of perjury that I am exempt from the Contractor's State License Law for the - following reason (Sec. 7031 .5, Business and Professions Code: Any city or county that requires a permit to construct, alter, improve, demolish, or repair any structure, prior to its issuance, also requires the applicant for the permit to file a signed statement that he or she is licensed pursuant to the provisions of the Contractor's State License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code) or that he or she is exempt therefrom and the basis for the alleged exemption. Any violation of Section 7031.5 by any applicant for a permit subjects the applicant to a civil penalty of not more than five hundred dollars ($500).: (_ 1 I, as owner of the property, or my employees with wages as their sole compensation, will do the work, and _ the structure is not intended or offered for sale (Sec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who does the work himself or herself through his or her own employees, provided that the improvements are not intended or offered for sale. If, however, the building or improvement is sold within one year of completion, the owner -builder will have the burden of proving that he or she did not build or improve for the purpose of sale.). (_ 1 I, as owner of the property, am exclusively contracting with licensed contractors to construct the project (Sec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who contracts for the projects with a contractor(s) licensed pursuant to the Contractors' State License Law.). I—) I am exempt under Sec. , B.&P.C. for this reason Date Owner: CONSTRUCTION LENDING AGENCY I hereby affirm under penalty of perjury that there is a construction lending agency for the performance of the work for which this permit is issued (Sec. 3097, Civ. C.). Lender's Name: Lender's Address: JA LQPERnIIT Owner: BRENDA GOLDBACH 51371 AVENIDA NAVARRO -LA QUINTA, CA 92253 Contractor: WESTERN PACIFIC ROOFING 3462 LA CAMPANA WAY PALM SPRINGS, CA 92262 (760)416-5877 Lic. No.: 235717 VOICE.(760) 777-7012 FAX (760) 777-7011 INSPECTIONS (760) 777-7153 Date: 10/24/07 ` WORKER'S COMPENSATION DECLARATION V I hereby affirm under penalty of perjury one of the following declarations: I have and will maintain a certificate of consent.to self -insure for workers' compensation, as provided' for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. I have and will maintain workers' compensation insurance, as required by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. My workers' compensation insurance carrier and policy number are: Carrier STATE FUND Policy Number 852-0002600 I certify that, in the performance of the work for which this permit is issued, I shall not employ any person in any manner so as to become subject to -the workers' compensation laws of California, and agree that, if I should become subject to the workers' compensation provisions of Section 00 of the Labor Code, I s ororthwith comply it ose provisions. Da' / V7 pplicant:-7=es�/! �` WARNING: FAILURE TO SECURE WORKERS' COMPENSATION COVERAGE IS UNLAWFUL, AND SHALL SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO ONE HUNDRED THOUSAND DOLLARS ($100,000). IN ADDITION TO THE COST OF COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE, INTEREST, AND ATTORNEY'S FEES. APPLICANT ACKNOWLEDGEMENT IMPORTANT Application is hereby made to the Director of Building and Safety for a permit subject to the conditions and restrictions set forth on this application. 1 . Each person upon whose behalf this application is made, each person at whose request and for whose benefit work is performed under or pursuant to any permit issued as a result of this application, the owner, and the applicant, each agrees to, and shall defend, indemnify and hold harmless the City of La Quinta, its officers, agents and employees for any act or omission related to the work being performed under or following issuance of this permit. 2. Any permit issued as a result of this application becomes null and void if work is not commenced within 180 days from date of issuance of such permit, or cessation of work for 180 days will subject permit to cancellation. I certify that I have read this application and state that the above information is correct. I agree to comply with. all city and county ordinances and state laws relating to building construction, and hereby au ooririizzee representatives of this coun y to ter upon the above-mentioned property f e�po�1������/ � s/Z 0'7 nature (Applicant or Agent): Application Number . . . . . 07-00002811 Permit . ... . . . RE -ROOF Additional deoo ` Permit Fee 30.00 ' Plan Check Fee .no Issue Date . . , � Valuation . . . .. ' 0 Expiration Date . . 4/21/08 ' Qty Unit Charge Per Extension BASE FEE `--_----------- z0.00 ------------------------------------------------------------- i I Notes and Comments INSTALL POLYURETHANE roxun a coxxrzmG ROOF SYSTEM ` ..Fee summary Char1ged Paid ----------------- ----------- -----'---- Credited Doe - eezmit Fee Total 30`00, --------- .oO ' ---------~ ,80 30.00 eIao Check Total �oo .00 .00 .00 ` Grand Total 30.00 ' .00' .00 30.00 . ` - ' ' - . . ` Bin # City of La Quinta Building 81 Safety Division P.O. Box 1504, 78-495 Calle Tampico La Quinta, CA 92253 - (760). 777-7012 Building Permit Application and Tracking Sheet Permit # Project Address: f 37 oy4iio Owner's Name: A. P. Number: Address:. 5-1371 AVc_ Af AWr4_1-a Legal Description: City, ST, Zip: C,rt 1,zS 3 Contractor:v, � it/n Telephone: Address: 3 Y4l✓.c� Project Description: City, ST, Zip: � ^ fere_, / nn Telephone: 76o- %&-5rpr) - G» i., ►maw re,. State Lic. # : Z3r7/'7 City Lic. #: Arch., Engr., Designer: Address: City, ST, Zip: Telephone: NMI Construction Type: Occupancy: State Lic. #: Project type (circle one):. -New ' Add'n Alter Repair Demo Name of Contact Person:�^� Sq. Ft.: # Stories: .# Units: Telephone # of Contact Person: p — j 5—o —07 7t Estimated Value of Project: °r %3 (, 7 APPLICANT: DO NOT WRITE BELOW THIS LINE # Submittal Req'd Rec'd TRACKING PERMIT FEES Plan Sets Plan Check submitted Item Amount Structural Cates. Reviewed, ready for corrections Plan Check Deposit Truss Calcs. Called Contact Person Plan Check Balance Energy Calcs. Plans bicked up Construction Flood plain plan Plans resubmitted Mechanical Grading.plan 2" Review, ready for corrections/issue Electrical Subcontactor List Called Contact Person Plumbing Grant Deed Plans picked up S.M.I. H.O.A. Approval. Plans resubmitted Grading IN HOUSE:- Review, ready for corrections/issue Developer Impact Fee Planning Approval Called Contact Person A.I.P.P. Pub. Wks. Appr Date of permit issue School Fees Total Permit Fees 'WESTERN PACIFIC Roofing Corporation Since 1949 Lic.#235717 September 25, 2007 Brenda Goldbach 51371 Ave. Navarro La Quinta, CA 92253 Subject: 51371 Ave. Navarro, La Quinta, CA 92253 Installation of a Polyurethane Foam and Coating System. Dear Ms. Goldbach: Thank you for the opportunity to submit a proposal for the re -roofing at the above referenced property. We are pleased to submit our proposal for the work as described below. The scope of work and associated costs are as follows: GENERAL Unless expressly stated to the contrary, the contractor shall be responsible for performing the following: DESCRIPTION A. The general conditions of this standard construction contract shall form a part of these specifications with the same force and effort as though repeated herein. B. The contractor shall furnish all labor, materials, equipment, permits, contractor's licenses and insurance certifications to perform all operations required and specified. The contractor shall provide labor and material customarily included in work of the same nature to give a quality, complete job. C. If any unforeseen or unexpected conditions are encountered duringthe work, and the conditions adversely affect the cost or progress of the work, the contractor will notify the owner immediately, and the owner will negotiate a written change -order to resolve the unexpected condition be it for an increase or decrease to the contract amount. D. The Contractor shall occupy, use, and permit others to use the premises only for the purpose of completing the work to be performed under this contract with the Owner. The Contractor shall not authorize or permit any other person to use said premises for any purpose whatsoever. Western Pacific is to be given all reasonable set-up and staging areas. Due to the limited access, some driveways or parking areas may be blocked during this construction process. 3462 La Campana Way o Palm Springs, CA 92262 0 (760) 416-5877 o Fax (760) 320-8912 www.westpacroof.com o E-mail: wprcps@westpacroof com Brenda Goldbach September 25, 2007 Page 2 . E. Contractor's scope of work shall not include the identification, detection, abatement, encapsulation or removal of asbestos or similar hazardous substances including mold or mildew. If Contractor encounters any such products, materials or conditions in the course of performing its work, or if such hazardous materials are encountered by any other firm performing work at the jobsite and contractor determines that such materials -present a hazard to its employees, contractor shall have the right to discontinue its work and remove its employees from the jobsite until such products or materials, and any hazards connected therewith, are located and abated, encapsulated or removed, or it is detennined that no hazard exists ( as the case may require), and contractor shall receive an extension of time to complete its work hereunder and compensation for delays encountered as a result of such situation and correction. Due to the possibility of mold or mildew being present before, during or after our work, Contractor's scope of work shall not include the identification, detection or the removal of mold or mildew. Owner agrees to hold Contractor harmless, and shall indemnify Contractor harmless for any mold related claims in the future. F. Should suit be brought to enforce or interpret any part of this Agreement, the "prevailing party" shall be entitled to recover, as an element of costs of suit and not as damages, reasonable attorneys' fees to be fixed by the Court. The "prevailing party" shall be entitled to recover its costs of suit, regardless of whether such suit proceeds to final judgment.. SURFACE PREPARATION A. Remove existing roof systems down to the substrate. Any material so firmly affixed that repeated attempts to remove it could damage the substrate will be left in place. B. Install '/4" Dens Deck mechanically fastened. C. Install new perimeter edge metal. (Unpainted) D. Prime roof deck with neoprime primer. E. Remove and replace fascia with 2" x 8" fascia board. (No paint included) F. Remove damaged sheathing and replace with 5/8" plywood. Fill void with insulation or particle board prior to the installation of Dens Deck. (No paint is included) . APPLICATION OF POLYURETHANE FOAM AND COATING A. Urethane shall be insulation shall be spray -applied to a minimal thickness of 1.5" (plus or minus 1/4") Only 3 lbs. Density foam will be used in this application. B. Coating shall be applied in a minimum of two separate coats. 1. The base coat shall be applied at a rate of 1.50 gallons per 100 square feet. 2. The top coat shall be applied at a rate of 1.50 gallons per 100 square feet, yielding a total system thickness for all coats of 22-24 TOTAL DRY MILS. Top coat color to be Light Grey. p�7� NpWESTERN PACIFIC ' II T Xn fng Curporarim, - - See Iw9 - L'c.'7571 i ' Brenda Goldbach September 25, 2007 Page 3 3. Embed ceramic granules in the wet top coat material at a rate of 50 pounds per 100 square feet. 4. All foam is to be coated. Coating shall extend up and over all foamed vent pipes and terminated a minimum of 2" above the foam, creating a neat appearance, self -terminating flashing. CONTRACT AMOUNT: $13,467.00 NOTE #1: There is an electrical line that must be raised prior to the installation of the new roof system. The power Penes mounted on the roof surface must also be relocated. This work - is NOT included in the contract amount. NOTE #2: The HVAC unit must be disconnected and re -installed during the re -roofing process. This work IS included in the contract amount. PAYMENT TERMS: 10% deposit upon approval of the contract. Twice -monthly payments until completion of contract. Invoices to be paid with 10 days of receipt. No retention to be held. Any remaining balance due following completion to be paid within 15 days of receipt of the invoice. WARRANTY A Five (5) year labor and material warranty will be issued by Western Pacific Roofing upon completion of the roof and final payment is received. The price quoted has been structured to reflect standards we assume are mutually desired: quality installation, service reliability and long -term performance. The price may be subject to change 15 days from the date of this proposal. If you are in accordance with the conditions herein, please execute the agreement below and return both copies to this office. We will, in turn, sign them and return one copy to you. Thank you for your cooperation in expediting this contract for your roofing needs. LAW REQUIRES ANYONE WHO CONTRACTS TO DO CONSTRUCTION WORK TO BE LICENSED BY THE CONTRACTORS STATE LICENSE BOARD IN THE LICENSE CATEGORY IN WHICH THE CONTRACTOR IS GOING TO BE WORKING IF THE TOTAL PRICE OF THE JOB 1S $500 OR MORE (INCLUDING LABOR AND MATERIALS). �(� WESTERN PACIFIC G�TJ eo lig c� ��.on�il tiin<. lo+e U-2357 17 Brenda Goldbach September 25, 2007 Page 4 "LICENSED CONTRACTORS ARE REGULATED BY LAWS DESIGNED TO PROTECT THE PUBLIC. IF YOU CONTRACT WITH SOMEONE WHO DOES NOT HAVE A LICENSE, THE CONTRACTORS STATE LICENSE BOARD MAY BE UNABLE TO ASSIST YOU WITH A COMPLAINT. YOUR ONLY REMEDY AGAINST AN UNLICENSED CONTRACTOR MAY BE IN CIVIL COURT, AND YOU MAY BE LIABLE FOR DAMAGES ARISING OUT OF ANY: INJURIES TO THE CONTRACTOR OR HIS OR HER EMPLOYEES. "YOU MAY CONTACT THE CONTRACTORS STATE LICENSE BOARD TO FIND OUT IF THIS CONTRACTOR HAS A VALID LICENSE. THE BOARD HAS COMPLETE INFORMATION ON THE HISTORY OF LICENSED CONTRACTORS, INCLUDING ANY POSSIBLE SUSPENSIONS, REVOCATIONS, JUDGMENTS, AND CITATIONS. THE BOARD HAS OFFICES THROUGHOUT CALIFORNIA. PLEASE CHECK THE GOVERNMENT PAGES OF THE WHITE PAGES FOR THE OFFICE NEAREST YOU OR CALL 1-800-CSLB OR WWW.CSLB.CA.GOV FOR MORE INFORMATION." ACKNOWLEDGMENT: Owner acknowledges that he/she has read and received a legible copy of this agreement including all terms and standard provisions before any work is performed and that he/she has read and received a legible copy of every other document that owner has signed during this negotiation. Uwe hereby acknowledge under the penalty of perjury that Uwe am/are the legal owners and am/are authorized to sign this contract as an agent of the legal owner. ACCEPTANCE: The above prices, specifications and conditions are satisfactory and are hereby accepted. You are authorized to do the work as specified. Payment will be as outlined above. You, the buyer may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction. See the attached Notice of Cancellation for an explanation of this right. Owner has the right to require contractor to have a performance and payment bond at Owner=s expense. See other attached documents. BRENDA GOLDBACH WESTERN PACIFIC ROOFING, CORP. Contractors License # 235717 Owner or Owner'eA gent Ronal R. Winkle l,0 D _September 25, 2007 Date/ ate Date WESTERN PACIFIC ROOFING HAS THE RIGHT TO RESCIND THIS CONTRACT WITHIN FIFTEEN DAYS OF ACCEPTANCE. THIS AGREEMENT IS NOT BINDING UNTIL ACCEPTED BY THE OFFICE MANAGEMENT AT 3462 LA CAMPANA WAY, PALM SPRINGS, CA 92262. NO CHANGES OR ADDITIONS TO THIS AGREEMENT SHALL BE EFFECTIVE UNTIL APPROVED BY WESTERN PACIFIC MANAGEMENT.<. MANAGERS ACCEPTANCE: DATE �pp8 WESTERN PACIFIC