2007 RBF Consulting/Monumentation SurveyLast Revised 8-14-07
PROFESSIONAL SERVICES AGREEMENT
THIS AGREEMENT FOR CONTRACT SERVICES (the "Agreement") is made and
entered into by and between the CITY OF LA QUINTA, ("City"), a California municipal
corporation, and RBF Consulting, a California Corporation ("Consultant"). The parties
hereto agree as follows:
1.0 SERVICES OF CONSULTANT
1.1 Scope of Services. In compliance with all terms and conditions of this Agreement,
Consultant shall provide those services related to Citywide Monumentation - Survey,
Project No. 2007-15, as specified in the "Scope of Services" attached hereto as Exhibit
"A" and incorporated herein by this reference (the "services" or "work"). Consultant
warrants that all services will be performed in a competent, professional and satisfactory
manner in accordance with the standards prevalent in the industry for such services.
1.2 Compliance with Law. All services rendered hereunder shall be provided in
accordance with all ordinances, resolutions, statutes, rules, regulations and laws of the
City of La Quinta and any Federal, State or local governmental agency of competent
jurisdiction.
1.3 Licenses Permits. Fees and Assessments. Except as otherwise specified
herein, Consultant shall obtain at its sole cost and expense such licenses, permits and
approvals as may be required by law for the performance of the services required by
this Agreement. Consultant shall have the sole obligation to pay for any fees,
assessments and taxes, plus applicable penalties and interest, which may be imposed
by law and arise from or are necessary for the performance of the services required by
this Agreement.
1.4 Familiarity with Work. By executing this Agreement, Consultant warrants that
(a) it has thoroughly investigated and considered the work to be performed, (b) it has
investigated the site of the work and fully acquainted itself with the conditions there
existing, (c) it has carefully considered how the work should be performed, and (d) it
fully understands the facilities, difficulties and restrictions attending performance of the
work under this Agreement. Should Consultant discover any latent or unknown
conditions materially differing from those inherent in the work or as represented by City,
Consultant shall immediately inform City of such fact and shall not proceed except at
Consultant's risk until written instructions are received from the Contract Officer (as
defined in Section 4.2 hereof).
1.5 Care of Work and Standard of Work.
a. Care of Work. Consultant shall adopt reasonable methods during the life of
the Agreement to furnish continuous protection to the work performed by Consultant,
and the equipment, materials, papers and other components thereof to prevent losses
or damages, and shall be responsible for all such damages, to persons or property, until
acceptance of the work by City, except such losses or damages as may be caused by
City's own negligence. The performance of services by Consultant shall not relieve
Consultant from any obligation to correct any incomplete, inaccurate or defective work
at no further cost to City, when such inaccuracies are due to the negligence of
Consultant.
b. Standard of Work. Consultant acknowledges and understands that the
services and work contracted for under this Agreement require specialized skills and
abilities and that, consistent with this understanding, Consultant's services and work
shall be performed in accordance with the generally accepted standards of quality and
workmanship of similar professionals in the County of Riverside. Consistent with
Section 1.4 hereinabove, Consultant represents to City that it holds the necessary skills
and abilities to meet these standard of work as set forth in this Agreement.
1.6 Additional Services. In accordance with the terms and conditions of this
Agreement, Consultant shall perform services in addition to those specified in the Scope
of Services when directed to do so by the Contract Officer, provided that Consultant
shall not be required to perform any additional services without compensation. Any
addition in compensation not exceeding five percent (5%) of the Contract Sum may be
approved by the Contract Officer. Any greater increase must be approved by the City
Council.
1.7 Special Requirements. Additional terms and conditions of this Agreement, if
any, which are made a part hereof are set forth in Exhibit "D" (the "Special
Requirements"). In the event of a conflict between the provisions of the Special
Requirements and any other provisions of this Agreement, the provisions of the Special
Requirements shall govern.
2.0 COMPENSATION
2.1 Contract Sum. For the services rendered pursuant to this Agreement,
Consultant shall be compensated in accordance with Exhibit "B" (the "Schedule of
Compensation") in a total amount not to exceed Twenty-eight Thousand Three Hundred
Fifty Dollars ($28,350.00) (the "Contract Sum"), except as provided in Section 1.6. The
method of compensation set forth in the Schedule of Compensation may include a lump
sum payment upon completion, payment in accordance with the percentage of
completion of the services, payment for time and materials based upon Consultant's
rate schedule, but not exceeding the Contract Sum, or such other methods as may be
specified in the Schedule of Compensation. Compensation may include reimbursement
for actual and necessary expenditures for reproduction costs, transportation expense,
telephone expense, and similar costs and expenses when and if specified in the
Schedule of Compensation.
2.2 Method of Payment. Any month in which Consultant wishes to receive
payment, Consultant shall submit to City no later than the tenth (10th) working day of
such month, in the form approved by City's Finance Director, an invoice for services
rendered prior to the date of the invoice. Such invoice shall (1) describe in detail the
services provided, including time and materials, and (2) specify each staff member who
has provided services and the number of hours assigned to each such staff member.
Such invoice shall contain a certification by a principal member of Consultant specifying
that the payment requested is for work performed in accordance with the terms of this
Agreement. City will pay Consultant for all expenses stated thereon which are
approved by City pursuant to this Agreement no later than thirty (30) days after invoices
are received by the City's Finance Department.
3.0 PERFORMANCE SCHEDULE
3.1 Time of Essence. Time is of the essence in the performance of this
Agreement.
3.2 Schedule of Performance. All services rendered pursuant to this Agreement
shall be performed diligently and within the time period established in Exhibit "C" (the
"Schedule of Performance"). Extensions to the time period specified in the Schedule of
Performance may be approved in writing by the Contract Officer.
3.3 Force Maieure. The time period specified in the Schedule of Performance for
performance of the services rendered pursuant to this Agreement shall be extended
because of any delays due to unforeseeable causes beyond the control and without the
fault or negligence of Consultant, including, but not restricted to, acts of God or of the
public enemy, fires, earthquakes, floods, epidemic, quarantine restrictions, riots, strikes,
freight embargoes, acts of any governmental agency other than City, and unusually
severe weather, if Consultant shall within ten (10) days of the commencement of such
delay notify the Contract Officer in writing of the causes of the delay. The Contract
Officer shall ascertain the facts and the extent of delay, and extend the time for
performing the services for the period of the forced delay when and if in his or her
judgment such delay is justified, and the Contract Officer's determination shall be final
and conclusive upon the parties to this Agreement.
3.4 Term. The term of this agreement shall commence on August 1, 2007 and
terminate on December 31, 2007 (initial term). This agreement may be extended upon
mutual agreement by both parties (extended term). Unless earlier terminated in
accordance with Sections 7.7 or 7.8 of this Agreement, this Agreement shall continue in
full force and effect until completion of the services, except as otherwise provided in the
Schedule of Performance.
4.0 COORDINATION OF WORK
4.1 Representative of Consultant. The following principals of Consultant are
hereby designated as being the principals and representatives of Consultant authorized
to act in its behalf with respect to the work specified herein and make all decisions in
connection therewith:
r
Brad Donais, P.E.
Levi Cox, P.L.S.
a. It is expressly understood that the experience, knowledge, capability, and
reputation of the foregoing principals were a substantial inducement for City to enter into
this Agreement. Therefore, the foregoing principals shall be responsible during the term
of this Agreement for directing all activities of Consultant and devoting sufficient time to
personally supervise the services hereunder.
The foregoing principals may not be changed by Consultant and no other
personnel may be assigned to perform the service required hereunder without the
express written approval of City.
4.2 Contract Officer. The Contract Officer shall be Timothy R. Jonasson, P.E.,
Public Works Director/City Engineer or such other person as may be designated by the
City Manager of City. It shall be Consultant's responsibility to assure that the Contract
Officer is kept informed of the progress of the performance of the services and
Consultant shall refer any decisions, which must be made by City to the Contract
Officer. Unless otherwise specified herein, any approval of City required hereunder
shall mean the approval of the Contract Officer.
4.3 Prohibition Against Subcontracting or Assignment. The experience,
knowledge, capability and reputation of Consultant, its principals and employees were a
substantial inducement for City to enter into this Agreement. Except as set forth in this
Agreement, Consultant shall not contract with any other entity to perform in whole or in
part the services required hereunder without the express written approval of City. In
addition, neither this Agreement nor any interest herein may be assigned or transferred,
voluntarily or by operation of law, without the prior written approval of City.
4.4 Independent Contractor. Neither City nor any of its employees shall have
any control over the manner, mode or means by which Consultant, its agents or
employees, perform the services required herein, except as otherwise set forth.
Consultant shall perform all services required herein as an independent contractor of
City and shall remain at all times as to City a wholly independent contractor with only
such obligations as are consistent with that role. Consultant shall not at any time or in
any manner represent that it or any of its agents or employees are agents or employees
of City.
4.5 City Cooperation. City shall provide Consultant with any plans, publications,
reports, statistics, records or other data or information pertinent to services to be
performed hereunder which are reasonably available to Consultant only from or through
action by City.
5.0 INSURANCE, INDEMNIFICATION AND BONDS.
5.1 Insurance. Prior to the beginning of and throughout the duration of the Work
performed under this Agreement, Consultant shall procure and maintain, at its cost, and
submit concurrently with its execution of this Agreement, personal and public liability
and property damage insurance against all claims for injuries against persons or
damages to property resulting from Consultant's acts or omissions rising out of or
related to Consultant's performance under this Agreement. The insurance policy shall
contain a severability of interest clause providing that the coverage shall be primary for
losses arising out of Consultant's performance hereunder and neither City nor its
insurers shall be required to contribute to any such loss. A certificate evidencing the
foregoing and naming City and its officers and employees as additional insured shall be
delivered to and approved by City prior to commencement of the services hereunder.
The amount of insurance required hereunder shall be determined by the Contract
Sum in accordance with the following table:
Contract Sum Personal Iniurv/Property Damage Coverage
Less than $50,000 $100,000 per individual; $300,000 per occurrence
$50,000 - $300,000 $250,000 per individual; $500,000 per occurrence
Over $300,000 $500,000 per individual; $1,000,000 per
occurrence
Consultant shall carry automobile liability insurance of $1,000,000 per accident
against all claims for injuries against persons or damages to property arising out of the
use of any automobile by Consultant, its officers, any person directly or indirectly
employed by Consultant, any subcontractor or agent, or anyone for whose acts any of
them may be liable, arising directly or indirectly out of or related to Consultant's
performance under this Agreement. If Consultant or Consultant's employees will use
personal autos in any way on this project, Consultant shall provide evidence of personal
auto liability coverage for each such person. The term "automobile" includes, but is not
limited to, a land motor vehicle, trailer or semi -trailer designed for travel on public roads.
The automobile insurance policy shall contain a severability of interest clause providing
that coverage shall be primary for losses arising out of Consultant's performance
hereunder and neither City nor its insurers shall be required to contribute to such loss.
A certificate evidencing the foregoing and naming City and its officers and employees
as additional insured shall be delivered to and approved by City prior to commencement
of the services hereunder.
Consultant shall carry Workers' Compensation Insurance in accordance with State
Worker's Compensation laws with employer's liability limits no less than $1,000,000 per
accident or disease.
Professional Liability or Errors and Omissions Insurance as appropriate shall be
written on a policy form coverage specifically designed to protect against acts, errors or
omissions of the consultant and "Covered Professional Services" as designated in the
policy must specifically include work performed under this agreement. The policy limit
shall be no less than $1,000,000 per claim and in the aggregate. The policy must "pay
on behalf of the insured and must include a provision establishing the insurer's duty to
defend. The policy retroactive date shall be on or before the effective date of this
agreement.
Insurance procured pursuant to these requirements shall be written by insurers
that are admitted carriers in the State of California and with an A.M. Bests rating of "A"
or better and a minimum financial size VII. Notwithstanding this last sentence, the City
will accept insurance procured from Lloyds of London.
All insurance required by this Section shall be kept in effect during the term of this
Agreement and shall not be cancelable without thirty (30) days written notice to City of
proposed cancellation. The procuring of such insurance or the delivery of policies or
certificates evidencing the same shall not be construed as a limitation of Consultant's
obligation to indemnify City, its officers, employees, contractors, subcontractors, or
agents.
5.2 Indemnification.
To the fullest extent permitted by law, Consultant shall indemnify, protect, defend
and hold harmless the Agency and the City and any and all of their officials, employees
and agents ("Indemnified Parties') from and against any and all losses, liabilities,
damages, costs and expenses, including attorney's fees and costs which arise out of,
pertain to, or relate to the negligence, recklessness, or willful misconduct of the
Consultant.
5.3 Remedies. In addition to any other remedies City may have if Consultant
fails to provide or maintain any insurance policies or policy endorsements to the extent
and within the time herein required, City may, at its sole option:
a. Obtain such insurance and deduct and retain the amount of the
premiums for such insurance from any sums due under this Agreement.
b. Order Consultant to stop work under this Agreement and/or withhold
any payment(s) which become due to Consultant hereunder until Consultant
demonstrates compliance with the requirements hereof.
C. Terminate this Agreement.
Exercise of any of the above remedies, however, is an alternative to any other
remedies City may have. The above remedies are not the exclusive remedies for
Consultant's failure to maintain or secure appropriate policies or endorsements.
Nothing herein contained shall be construed as limiting in any way the extent to which
Consultant may be held responsible for payments of damages to persons or property
resulting from Consultant's or its subcontractors' performance of work under this
Agreement.
5.4 General Conditions pertaining to provisions of insurance coverage by
Consultant. Consultant and City agree to the following with respect to insurance
provided by Consultant:
1. Consultant agrees to have its insurer endorse the third party general
liability coverage required herein to include as additional insureds City, its officials,
employees and agents, using standard ISO endorsement No. CG 2010 with an edition
prior to 1992. Consultant also agrees to require all contractors, and subcontractors to
do likewise.
2. No liability insurance coverage provided to comply with this Agreement
shall prohibit Consultant, or Consultant's employees, or agents, from waiving the right of
subrogation prior to a loss. Consultant agrees to waive subrogation rights against City
regardless of the applicability of any insurance proceeds, and to require all contractors
and subcontractors to do likewise.
3. All insurance coverage and limits provided by Contractor and available
or applicable to this agreement are intended to apply to the full extent of the policies.
Nothing contained in this Agreement or any other agreement relating to the City or its
operations limits the application of such insurance coverage.
4. None of the coverages required herein will be in compliance with these
requirements if they include any limiting endorsement of any kind that has not been first
submitted to City and approved of in writing.
5. No liability policy shall contain any provision or definition that would
serve to eliminate so-called "third party action over" claims, including any exclusion for
bodily injury to an employee of the insured or of any contractor or subcontractor.
6. All coverage types and limits required are subject to approval,
modification and additional requirements by the City, as the need arises. Consultant
shall not make any reductions in scope of coverage (e.g. elimination of contractual
liability or reduction of discovery period) that may affect City's protection without City's
prior written consent.
7. Proof of compliance with these insurance requirements, consisting of
certificates of insurance evidencing all of the coverages required and an additional
insured endorsement to Consultant's general liability policy, shall be delivered to City at
or prior to the execution of this Agreement. In the event such proof of any insurance is
not delivered as required, or in the event such insurance is canceled at any time and no
replacement coverage is provided, City has the right , but not the duty, to obtain any
insurance it deems necessary to protect its interests under this or any other agreement
and to pay the premium. Any premium so paid by City shall be charged to and promptly
paid by Consultant or deducted from sums due Consultant, at City option.
8. Certificate(s) are to reflect that the insurer will provide thirty (30) days
notice to City of any cancellation of coverage. Consultant agrees to require its insurer
to modify such certificates to delete any exculpatory wording stating that failure of the
insurer to mail written notice of cancellation imposes no obligation, or that any party will
"endeavor' (as opposed to being required) to comply with the requirements of the
certificate.
9. It is acknowledged by the parties of this agreement that all insurance
coverage required to be provided by Consultant or any subcontractor, is intended to
apply first and on a primary, non-contributing basis in relation to any other insurance or
self insurance available to City.
10. Consultant agrees to ensure that subcontractors, and any other party
involved with the project who is brought onto or involved in the project by Consultant,
provide the same minimum insurance coverage required of Consultant. Consultant
agrees to monitor and review all such coverage and assumes all responsibility for
ensuring that such coverage is provided in conformity with the requirements of this
section. Consultant agrees that upon request, all agreements with subcontractors and
others engaged in the project will be submitted to City for review.
11. Consultant agrees not to self -insure or to use any self -insured
retentions or deductibles on any portion of the insurance required herein and further
agrees that it will not allow any contractor, subcontractor, Architect, Engineer or other
entity or person in any way involved in the performance of work on the project
contemplated by this agreement to self -insure its obligations to City, If Consultant's
existing coverage includes a deductible or self -insured retention, the deductible or self -
insured retention must be declared to the City. At that time the City shall review options
with the Consultant, which may include reduction or elimination of the deductible or self -
insured retention, substitution of other coverage, or other solutions.
12. The City reserves the right at any time during the term of the contract to
change the amounts and types of insurance required by giving the Consultant ninety
(90) days advance written notice of such change. If such change results in substantial
additional cost to the Consultant, the City will negotiate additional compensation
proportional to the increased benefit to City.
13. For purposes of applying insurance coverage only, this Agreement will
be deemed to have been executed immediately upon any party hereto taking any steps
that can be deemed to be in furtherance of or towards performance of this Agreement.
14. Consultant acknowledges and agrees that any actual or alleged failure
on the part of City to inform Consultant of non-compliance with any insurance
requirement in no way imposes any additional obligations on City nor does it waive any
rights hereunder in this or any other regard.
15. Consultant will renew the required coverage annually as long as City, or
its employees or agents face an exposure from operations of any type pursuant to this
agreement. This obligation applies whether or not the agreement is canceled or
terminated for any reason. Termination of this obligation is not effective until City
executes a written statement to that effect.
16. Consultant shall provide proof that policies of insurance required herein
expiring during the term of this Agreement have been renewed or replaced with other
policies providing at least the same coverage. Proof that such coverage has been
ordered shall be submitted prior to expiration. A coverage binder or letter from
Consultant's insurance agent to this effect is acceptable. A certificate of insurance
and/or additional insured endorsement as required in these specifications applicable to
the renewing or new coverage must be provided to City within five (5) days of the
expiration of coverages.
17. The provisions of any workers' compensation or similar act will not limit
the obligations of Consultant under this agreement. Consultant expressly agrees not to
use any statutory immunity defenses under such laws with respect to City, its
employees, officials and agents.
18. Requirements of specific coverage features or limits contained in this
section are not intended as limitations on coverage, limits or other requirements nor as
a waiver of any coverage normally provided by any given policy. Specific reference to a
given coverage feature is for purposes of clarification only as it pertains to a given issue,
and is not intended by any party or insured to be limiting or all-inclusive.
19. These insurance requirements are intended to be separate and distinct
from any other provision in this agreement and are intended by the parties here to be
interpreted as such.
20. The requirements in this Section supersede all other sections and
provisions of this Agreement to the extent that any other section or provision conflicts
with or impairs the provisions of this Section.
21. Consultant agrees to be responsible for ensuring that no contract used
by any party involved in any way with the project reserves the right to charge City or
Consultant for the cost of additional insurance coverage required by this agreement.
Any such provisions are to be deleted with reference to City. It is not the intent of City
to reimburse any third party for the cost of complying with these requirements. There
shall be no recourse against City for payment of premiums or other amounts with
respect thereto.
Consultant agrees to provide immediate notice to City of any claim or loss against
Consultant arising out of the work performed under this agreement. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to monitor the
handling of any such claim or claims if they are likely to involve City.
6.0 RECORDS AND REPORTS.
6.1 Reports. Consultant shall periodically prepare and submit to the Contract
Officer such reports concerning Consultant's performance of the services required by
this Agreement as the Contract Officer shall require.
6.2 Records. Consultant shall keep such books and records as shall be
necessary to perform the services required by this Agreement and enable the Contract
Officer to evaluate the cost and the performance of such services. Books and records
pertaining to costs shall be kept and prepared in accordance with generally accepted
accounting principals. The Contract Officer shall have full and free access to such
books and records at all reasonable times, including the right to inspect, copy, audit,
and make records and transcripts from such records.
6.3 Ownership of Documents. Originals of all drawings, specifications, reports,
records, documents and other materials, whether in hard copy or electronic form, which
are prepared by Consultant, its employees, subcontractors and agents in the
performance of this Agreement, shall be the property of City and shall be delivered to
City upon termination of this Agreement or upon the earlier request of the Contract
Officer, and Consultant shall have no claim for further employment or additional
compensation as a result of the exercise by City of its full rights of ownership of the
documents and materials hereunder. Consultant shall cause all subcontractors to
assign to City any documents or materials prepared by them, and in the event
Consultant fails to secure such assignment, Consultant shall indemnify City for all
damages suffered thereby.
In the event City or any person, firm or corporation authorized by City reuses said
documents and materials without written verification or adaptation by Consultant for the
specific purpose intended and causes to be made or makes any changes or alterations
in said documents and materials, City hereby releases, discharges, and exonerates
Consultant from liability resulting from said change. The provisions of this clause shall
survive the completion of this Contract and shall thereafter remain in full force and
effect.
6.4 Release of Documents. The drawings, specifications, reports, records,
documents and other materials prepared by Consultant in the performance of services
under this Agreement shall not be released publicly without the prior written approval of
the Contract Officer or as required by law. Consultant shall not disclose to any other
entity or person any information regarding the activities of City, except as required by
law or as authorized by City.
7.0 ENFORCEMENT OF AGREEMENT.
7.1 California Law. This Agreement shall be construed and interpreted both as
to validity and to performance of the parties in accordance with the laws of the State of
California. Legal actions concerning any dispute, claim or matter arising out of or in
relation to this Agreement shall be instituted in the Superior Court of the County of
Riverside, State of California, or any other appropriate court in such county, and
Consultant covenants and agrees to submit to the personal jurisdiction of such court in
the event of such action.
7.2 Disputes. In the event of any dispute arising under this Agreement, the
injured party shall notify the injuring party in writing of its contentions by submitting a
claim therefore. The injured party shall continue performing its obligations hereunder so
long as the injuring party commences to cure such default within ten (10) days of
service of such notice and completes the cure of such default within forty-five (45) days
after service of the notice, or such longer period as may be permitted by the Contract
Officer; provided that if the default is an immediate danger to the health, safety and
general welfare, City may take such immediate action as City deems warranted.
Compliance with the provisions of this section shall be a condition precedent to
termination of this Agreement for cause and to any legal action, and such compliance
shall not be a waiver of any party's right to take legal action in the event that the dispute
is not cured, provided that nothing herein shall limit City's right to terminate this
Agreement without cause pursuant to Section 7.8.
7.3 Retention of Funds. City may withhold from any monies payable to
Consultant sufficient funds to compensate City for any losses, costs, liabilities, or
damages it reasonably believes were suffered by City due to the default of Consultant in
the performance of the services required by this Agreement.
7.4 Waiver. No delay or omission in the exercise of any right or remedy of a non
defaulting party on any default shall impair such right or remedy or be construed as a
waiver. City's consent or approval of any act by Consultant requiring City's consent or
approval shall not be deemed to waive or render unnecessary City's consent to or
approval of any subsequent act of Consultant. Any waiver by either party of any default
must be in writing and shall not be a waiver of any other default concerning the same or
any other provision of this Agreement.
7.5 Rights and Remedies are Cumulative. Except with respect to rights and
remedies expressly declared to be exclusive in this Agreement, the rights and remedies
of the parties are cumulative and the exercise by either party of one or more of such
rights or remedies shall not preclude the exercise by it, at the same or different times, of
any other rights or remedies for the same default or any other default by the other party.
7.6 Legal Action. In addition to any other rights or remedies, either party may
take legal action, at law or at equity, to cure, correct or remedy any default, to recover
damages for any default, to compel specific performance of this Agreement, to obtain
injunctive relief, or to obtain any other remedy consistent with the purposes of this
Agreement.
7.7 Termination Prior To Expiration Of Term. This section shall govern any
termination of this Agreement, except as specifically provided in the following Section
7.8 for termination for cause. City reserves the right to terminate this Agreement at any
time, with or without cause, upon thirty (30) days' written notice to Consultant. Upon
receipt of any notice of termination, Consultant shall immediately cease all services
hereunder except such as may be specifically approved by the Contract Officer.
Consultant shall be entitled to compensation for all services rendered prior to receipt of
the notice of termination and for any services authorized by the Contract Officer
thereafter in accordance with the Schedule of Compensation or such as may be
approved by the Contract Officer, except as provided in Section 7.3.
7.8 Termination for Default of Consultant. If termination is due to the failure of
Consultant to fulfill its obligations under this Agreement, City may, after compliance with
the provisions of Section 7.2, take over work and prosecute the same to completion by
contract or otherwise, and Consultant shall be liable to the extent that the total cost for
completion of the services required hereunder exceeds the compensation herein
stipulated (provided that City shall use reasonable efforts to mitigate such damages),
and City may withhold any payments to Consultant for the purpose of setoff or partial
payment of the amounts owed City as previously stated in Section 7.3.
7.9 Attorneys' Fees. If either party commences an action against the other party
arising out of or in connection with this Agreement, the prevailing party shall be entitled
to recover reasonable attorneys' fees and costs of suit from the losing party.
8.0 CITY OFFICERS AND EMPLOYEES; NONDISCRIMINATION.
8.1 Non -liability of City Officers and Employees. No officer or employee of City
shall be personally liable to Consultant, or any successor in interest, in the event or any
default or breach by City or for any amount which may become due to Consultant or to
its successor, or for breach of any obligation of the terms of this Agreement.
8.2 Conflict of Interest. No officer or employee of City shall have any personal
interest, direct or indirect, in this Agreement nor shall any such officer or employee
participate in any decision relating to the Agreement which affects his or her personal
interest or the interest of any corporation, partnership or association in which she or he
is, directly or indirectly, interested, in violation of any State statute or regulation.
Consultant warrants that it has not paid or given and will not pay or give any third party
any money or general consideration for obtaining this Agreement.
8.3 Covenant against Discrimination. Consultant covenants that, by and for
itself, its heirs, executors, assigns, and all persons claiming under or through them, that
there shall be no discrimination against or segregation of, any person or group of
persons on account of race, color, creed, religion, sex, marital status, national origin or
ancestry in the performance of this Agreement. Consultant shall take affirmative action
to insure that applicants are employed and that employees are treated during
employment without regard to their race, color, creed, religion, sex, marital status,
national origin or ancestry.
9.0 MISCELLANEOUS PROVISIONS
9.1 Notice. Any notice, demand, request, consent, approval, communication
either party desires or is required to give the other party or any other person shall be in
writing and either served personally or sent by prepaid, first-class mail to the address
set forth below. Either party may change its address by notifying the other party of the
change of address in writing. Notice shall be deemed communicated forty-eight (48)
hours from the time of mailing if mailed as provided in this section.
To City:
CITY OF LA QUINTA
Attention: Thomas P. Genovese
City Manager
78-495 Calle Tampico
P.O. Box 1504
La Quinta, California 92247-1504
To Consultant:
RBF Consulting
Attention: Brad Donais, P.E.
Project Manager
74-130 Country Club Drive, Suite 201
Palm Desert, CA 92260-1655
9.2 Integrated Agreement. This Agreement contains all of the agreements of the
parties and all previous understanding, negotiations and agreements are integrated into
and superseded by this Agreement.
9.3 Amendment. This Agreement may be amended at any time by the mutual
consent of the parties by an instrument in writing signed by both parties.
9.4 Severability. In the event that any one or more of the phrases, sentences,
clauses, paragraphs, or sections contained in this Agreement shall be declared invalid
or unenforceable by a valid judgment or decree of a court of competent jurisdiction,
such invalidity or unenforceability shall not affect any of the remaining phrases,
sentences, clauses, paragraphs, or sections of this Agreement which are hereby
declared as severable and shall be interpreted to carry out the intent of the parties
hereunder.
9.5 Authority. The persons executing this Agreement on behalf of the parties
hereto warrant that they are duly authorized to execute this Agreement on behalf of said
parties and that by so executing this Agreement the parties hereto are formally bound to
the provisions of this Agreement.
IN WITNESS WHEREOF, the parties have executed this Agreement as of the
dates stated below.
CITY OF LA QUINTA a California municipal corporation
1,4 ,
Thomas P. denovese, City Manager Date
ATTEST:
APPROVED AS TO FORM:
M. Katherine Jen City Attorney
CONE
By:
Name:
Title:
Date:
Brad Donais, P.E.
Senior Associate/Project Manager
8//) !(D-)
Last Revised 8-14-07
Exhibit A
Scope of Services
Consultant's scope of work to related to Citywide Monumentation - Survey, Project No.
2007-15 is attached and made a part of this agreement.
Last Revised 8-14-07
Exhibit B
Schedule of Compensation
Payment shall be on a "Fixed Fee" basis in accordance with the Consultants
Schedule of Compensation attached herewith for the work tasks performed in
conformance with Section 2.2 of the Agreement. Total compensation for all work under
this contract shall not exceed Twenty-eight Thousand Three Hundred Fifty Dollars
($28.350.00) except as specified in Section 1.6 - Additional Services of the Agreement.
Last Revised 8-14-07
Exhibit C
Schedule of Performance
The term of this agreement shall commence on August 1, 2007 and terminate on
December 31, 2007.
Last Revised 8-14-07
Exhibit D
Special Requirements
None.
2
ti
CF`M OF "rNtiv
PROJECT NO. 2007-15
PROFESSIONAL SERVICES AGREEMENT:
CITYWIDE MONUMENTATION SURVEY
CONSULTANT: RBF Consulting
Attention: Brad Donais, P.E., Project Engineer
74-130 Country Club Drive, Suite 201
Palm Desert, CA 92260-1655
CONTRACT AMENDMENT NO. 1
Pursuant to the terms of the original Contract Agreement, you are hereby
directed to make the herein described changes or do the following described
work not included in the plans and specifications for this Contract. Unless
otherwise stated all work shall conform to the terms, general conditions, and
special provisions of the Contract.
DESCRIPTION OF CHANGE
This contract amendment authorizes RBF Consulting to expand its existing
scope of work to include the placement of additional survey monuments and
benchmarks in accordance with RBF Consulting's Additional Work Request
Number 1, dated September 24, 2007, which is attached and made part of
this contract amendment.
Previous Contract Amount Thru Contract Amendment No. -0- $28,350.00
Add this Amendment $12,550.00
Revised Contract Total 540'900.00
The contract completion date is not affected by Contract Amendment No. 1.
Submitted 1 Date:
By: ,�. 4— w
0
Date: 111�/O 7