Loading...
06-0101 (RR)P.O. BOX 1504 78-495 CALLE TAMPICO LA QUINTA, CALIFORNIA 92253 Application Number: Property Address: APN: Application description: Property Zoning: Application valuation: Applicant: 6:06=00000101--- -53-815 AVENIDA C-ARRANZA 774-155-015-6 -000000- RE-ROOF COVE RESIDENTIAL 25425 T,d4t 4 4 w Architect or Enginee BUILDING & SAFETY DEPARTMENT BUILDING PERMIT -------------------------------------------------- LICENSED CONTRACTOR'S DECLARATION I hereby affirm under penalty of perjury that I am licensed under provisions of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professionals Code, and my License is in full force and effect. License alas C39 License No.: 810537 �++ Oate: 1 64 Contractor:+ 16 1 OWNER -BUILDER DECLARATION- - I hereby affirm under penalty of perjury that I am exempt from the Contractor's State License Law for the following reason (Sec. 7031 .5, Business and Professions Code: Any city or county that requires a permit to construct, alter, improve, demolish, or repair any structure, prior to its issuance, also requires the applicant for the permit to file a signed statement that he or she is licensed pursuant to the provisions of the Contractor's State License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code) or that he or she is exempt therefrom and the basis for the alleged exemption. Any violation of Section 7031.5 by any applicant for a permit subjects the applicant to a civil penalty of not more than five hundred dollars ($500).: as owner of the property, or my employees with wages as their sole compensation, will do the work, and the structure is not intended or offered for sale (Sec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who does the work himself or herself through his or her own employees, provided that the improvements are not intended or offered for sale. If, however, the building or improvement is sold within one year of completion, the owner -builder will have the burden of proving that he or she did not build or improve for the puipuse of sale.). (_) I, as owner of the property, am exclusively contracting with licensed contractors to construct the project (Sec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who contracts for the projects with a contractor(s) licensed pursuant to the Contractors' State License Law.). I am exempt under Sec. , B.&P.C. for this reason Date: Owner: CONSTRUCTION LENDING AGENCY hereby affirm under penalty of perjury that there is a construction lending agency for the performance of the work for which this permit is issued (Sec. 3097, Civ. C.). Lender's Name: Lender's Address: LQPERMIT Owner: ABRAHAM STEVEN 53815'AVENIDA CARRANZA LA QUINTA, CA 92253 Contractor: ROOF TILE SPECIALTY, INC. P.O. BOX 11257 PALM DESERT, CA 92255 (760)200-0811 Lic. No.: 810537 VOICE (760) 777-7012 FAX (760) 777-7011 INSPECTIONS (760) 777-7153 Date: 1/10/06 WORKER'S COMPENSATION DECLARATION I hereby affirm under penalty of perjury one of the following declarations: _ I have and will maintain a certificate of consent to self -insure for workers' compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. I have and will maintain workers' compensation insurance, as required by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. My workers' compensation insurance carrier and policy number are: Carrier RISK CO Policy Number WC4781792 I certify that, in the performance of the work for which this permit is issued, I shall not employ any person in any manner so as to become subject to the workers' compensation laws of California, and agree that, if I sh ul�^ bject to the workers' compensation provisions of Section 33700 of the Labor ode, I s.. 11 forthcomply with those provisions. Date,) l r Appl`�.- WARNING: FAILURE TO SECURE WORKERS' COMPENSATION COVERAGE IS UNLAWFUL, AND SHALL SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO ONE HUNDRED THOUSAND DOLLARS ($100,000). IN ADDITION TO THE COST OF COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE, INTEREST, AND ATTORNEY'S FEES. APPLICANT ACKNOWLEDGEMENT IMPORTANT Applicatiun is hereby made to the Director of Building and Safety for a permit subject to the conditions and restrictions set forth on this application. 1. Each person upon whose behalf this application is made, each person at whose request and for whose benefit work is performed under or pursuant to any permit issued as a result of this application, the owner, and the applicant, each agrees to, and shall defend, indemnify and hold harmless the City .of La Quinta, its officers, agents and employees for any act or omission related to the work being performed under or following issuance of this permit. 2. 'Any permit issued as a result of this application becomes null and void if work is not commenced within 180 days from date of issuance of such permit, or cessation of work for 180 days will subject permit to cancellation. I certify that I have read [his application and the above information is correct.. I agree to comply with all city ntatives anc unty ordinances and state laws r ati to bw construction, and hereby authorize represe of this o ri2Yt e�nlAtel�lr upon the above-ment ned p perty for' spectian purposes Date 1\� Signature-(ApplicanLor�Age_ Application Number . . . . . 06-00000101 Permit . . . RE -ROOF Additional desc . .. Permit Fee . . . . 30.00 Plan Check Fee .00 Issue Date . . . . Valuation . . . . 0 Expiration Date 7/09/06 Qty Unit Charge Per Extension BASE FEE 30.00 ---------------------------------------------------------------------------- Special Notes and Comments REROOF. LT WT TILE CLASS "A" MATERIALS Fee summary ----------------- Charged Paid ---------- Credited Due Permit Fee Total ---------- 30.00 ---------- .00 ---------- .00 30.00 Plan Check Total .00 .00 .00 .00 Grand Total 30.00 .00 .00 30.00 1 LQPERMIT Bin # City of La Quinta Building U Safety Division P.O. Box. 1504, 78-495 Calle Tampico La Quinta, CA 922.53 -.(760) 777-7012 Building Permit Application and Tracking Sheet Permit # Project Address: = 3 7(c., n2� Owner's Name: A. P. Number: Address: Legal Description: City, ST, Zip: `}i ►r'i. C. Contractor - f Z Address: Telephone: Project Desc p n: , City, ST, Zip: Telephone: , State Lic. # : City Lie. #: Arch., Engr., Designer: Address: City., ST, Zip: Telephone: State Lic. #: Construction Type: Occupancy: Project type (circle one): New Add'n Alter Repair Demo Name of Contact Person:r Sq. Ft.: #Stories: #Units: Telephone #9f Contact Person: �1 �� Estimated Value of Project: ly APPLICANT: DO NOT WRITE BELOW THIS UNE # Submittal Req'd Recd TRACMG . PERMIT FEES Plan Sets Plan Check submitted Item Amount Structural Calcs. Reviewed, ready for corrections Plan Check Deposit Truss Calcs. Called Contact Person Plan Check Balance Energy Calcs. Plans. picked up Construction Flood plain plan Plans resubmitted Mechanical Grading. plan 2' Review, ready for corrections/issue Electrical Subcontactor List Called Contact Person Plumbing Grant Deed Plans picked up S.M.I. H.O.A. Approval Plans resubmitted Grading IN HOUSE: ''' Review, ready for corrections/issue Developer Impact Fee Planning Approval Called Contact Person A.I.P.P. Pub. Wks. Appr Date of permit issue School Fees Total Permit Fees RTSRoof Tile Specialty, Inc. -Contractors State License # 810537 P.O. Box 11257 Palm Desert, CA 92255 PHONE 760-200-0811 FAX 760-200-0801 IR ; 4 1 9 meq% N j A proposal submitted to: STEVE ABRAHAM Mailing Address: 53-815 CARRANZA, LA QUINTA, CA 92253 Job Address: SAME Phone: 831-1195 , Description of work to be performed: REMOVE EXISTING TILE ROOF AND DISPOSE (UNDERLAYMENT MAY REMAIN). INSTALL NEW PERIMETER METAL FOLLOWED BY 2 LAYERS PEEL & STICK WITH GRANULATED FINISH. INSTALL NEW RIDGE BOARD AND ROOF JACKS. PRIMARY AND SECONDARY PAINTED TO MATCH ROOF. INSTALL U.S. CLAY LT. ROOF TILE TO MANUFACTURES SPECIFICATIONS. FIRST COURSE TO BE 2 PCS MISSION STARTER AND RANDOM BOOSTER WITH MORTAR. IF NOT ACCEPTED IN 30 DAYS THIS PROPOSAL IS NULL AND VOID Note: In keeping with industry standards: 1. This guarantee does not cover any damage to the interior or exterior on which the roof is applied or damage to any contents therein. This guarantee does not cover damage to roof due to any cause beyond our control, including, but not limited to: fire, lightning, windstorm, hailstorm, antennas or other equipment, foot traffic on roof, structural fault or settlement, cracking or other failure of the roof deck, walls or foundation of the building on which the roof is applied. 2. Should it become necessary_ for the roofing contractor to remove and/or reinstall any antennas, cooling, or heating appliances or other equipment, whether or not an additional charge is made for such work, the customer understands that neither RTS (Roof Tile Specialty, Inc.) nor the installer assumes any responsibility for the performance of said equipment. 3. RTS (Roof Tile Specialty, Inc.) does not assume any responsibility for corrections of existing code violations or for the repair of any existing defects unless specified in estimate and proposal. Total Cost: $25,425.00 Terms paid on completion unless otherwise specified in the contract. If not accepted in thirty days this proposal is invalid. Extra $55.00 per sheet of plywood if needed Acceptance: You are hereby authorized to furnish all contents written in the contract to complete work mentioned in the proposal contract for which Uwe agree to pay the amount mentioned, in said proposal, and according to terms thereof, (initial). If a leakage, caused by defects in workmanship, occurs within TEN years from date of application, we will repair defects free of charge. Installation: It is understood that by the acceptance of this proposal you authorize RTS (Roof Tile specialty, Inc.) to make the installation; to issue work orders with specifications shown herein and to pay our charge for such installation. You agree to pay the amount specified herein, which will cover the price of said materials and labor charge: This estimate is based on a complete job and any surplus material remains property of RTS (Roof Tile specialty, Inc.). Verbal understanding and agreements with representatives shall not be binding unless set forth herein. There shall be no liabilities for delays in, or failure to complete, deliver or installation of all or any of the herein mentioned merchandise, if due'to fire, strikes, war, government regulations or any cause beyond our contract. Any changes made by you in specifications herein, necessitating additional materials or labor shall not be included or covered by this proposal, but shall be provided for under separate and additional order from you. . (initial) Arbitration of Disputes: Any controversy or claim arising out of or relating to this contract, or the breach thereof, shall settled by arbitrator in accordance with the applicable Construction Industry Arbitrator Rules of the American Arbitration Association which are in effect at the time the demand for arbitration is filed. A judgment award based upon the evidence presented by the party(ies) who do (does) appear and participate. Notwithstanding Contractor's right to arbitrate, contractor does not waive any of, its' lien. rights. 1n. the event of default by client in payment of the amount due hereunder, client agrees to pay reasonable attorneys' fee's and cost incurred in connection with collection of said amounts whether or not suit is filed. 1.5% per month and/or an annual percentage of 18.0% will be charged on all past due accounts. Contractor's are required by law to be licensed and regulated by the Contractor's State Board. Any questions concerning a contractor may be referred to the register of the board whose address is: Contractors State Licenses Board, 9835 Goathe Road, Sacramento, CA 95827: Mailing address: P.O. Box 26000, Sacramento, CA, 95826. The above prices, specifications and conditions are satisfactory and are hereby accepted. Owner's Signature. (or authorized representative) n Contractor's Signature _ _ .__. --_----_�"_-.__..- .- _ _.-...._._.___.-_ Date: Date: Notice (Section 7019-- Contractors License Law) "Under the Mechanics' Lien Law, any contractor, subcontractor, laborer, material man or/other person who helps to improve your property and is not paid for this labor, service or material, has a right to enforce his claim against your property. Under the law you may protect yourself against such claims by filing bcforc commencing such work of improvement, an original contract for the woik of improvements of a modification, thereof, in the office of the county.where the property is situated and requiring that a contractor's payment bond be. recorded in such ()trice, Said bond shall he in an amount not lets than fifty Percent (5(1%n) of tile corE�t-sact price and shall, in addition to any conditions for the performance of Lr e conlract, be conditioned for the payment in full of the claims of all persons Rumi-shk-ug labor service, equipment or materials for the work described in said CpntraCt." Notice "Under the Mechanics Lien law any contractors, subcontractor, laborer, supplier or other persons who helps to improve your property but is not paid for his work or supplies, has a right to enforce a claim against your property. This means that, after a court hearing, your property could be sold by a court officer and the proceeds of the sale used to satisfy the indebtedness. This can happen even if you have paid you own contractor -in full, if the subcontractor, laborer, or supplier remains unpaid." i94''GK 3 Ci[g[lC 6V '<. µrdlL'6 ' Yo., my cancel the Agreement or offer referred to above anytime prior to midnight of the third day (excluding Sunday) after the day , ,ou signed the agreement or offer. If you cancel and you have already Fiiade, mina payment In rhe, setter, lire sotier is to va1;441 but ": � n a... ay N+.. lflcr < _ _, ._ � _^ :, : -a < ; :•waae tsuaa au. 1'i si i C; iCe'a�i 1✓ ice) urvi 'ria neaC, vut «r i;u i'ai�,i rrcuy trw waa� r ^^rr :: �!.a*'on iry iraiiing a •signed and dated statement to the -seller at the ..,. �. �._.__ ' ' �'.•«• ••,. •'.. .. • �... ..,r .. r;trtE Y.nia:ri,++ 2: !4'rP,nn?-i i at to -fl 9lle stiitprnp.nt .rtifw.d rn-.0 i a V TY?Ari(�At�-'li`11 V;1 ' i',iy rflA'ifi�'P,.TP,,f tlt QPU. F Tn,ie,r the. Califarnia 1! -chanics Lien Law, any contractor, subcontractor, laborer, supplier or outer persons who help to improve. your --e,.y ex[: 'i iec,16. (,r itF ease r:rS:rR+[ie.Ee ip5 SULNr'il'tes, eeaS rrgltt. tR3 GIiRFrc a S''.$ie`a it��ibitts� ya -F •rr �.�i'5`•i�l�.� eel:, :.re`:,r.F� ic.:}s'.r . ;�Q /., __ ..._.__:__. -.- •....-_._»L_ __/�1____ __._�. _P.—„__A 41,, _•_ "_J_ _X11 ”"-"'"'v% � •'"-- is":rir_a.c� .�w;:.as ,>u =e<;<u :>� � : <•<r_:G r- :: aceu<x :s«� e_<_ S>a+rvsr:: <s:: v< : —ice i.ra++<: c+: — xG_c<� �ce _ cca.«. G<u«_- _ .<ws �--_-c::�rjry c even if you have POW your own contractor in full, .if the. subcontractor, laborer, or supplier remains unpaid To preserve your right to iI lliii 64,I 4 your prt-qp'; i,, +"'nitilD k.1'iaii:S::S+ttij?, -il. E+lyf.,vttlr:rl;itxs, or #1'E t;:rial.>rapplics are 'regiiffe(1:tiD'prOv7dE.'you Vv:iiea r -,..:.1-.-F:.,- 1T..4:.- f)/•_.-.,-.F>._..T..:..._�___..._.-.__.-..1.. .... _.;. ��..:aa.•-::.a., e''<s r: _ ..�:-:::r: ••_[ •:ret.-•. ,. .. _...:.. ._.•--_ ..<-.._. -_. _, .. :..... t-..... -_ _.. -.._ .. .:. ... ...•,-. Preliminary Notice is not.a lien against your property, its,purpose: is to notify you of persons who may have..a right to file a lien against �ieiiy Fi `iuey are. not paid., (Generally, the maximun►,timo allowed fur.fillog a elS im, or ls4•nn aw-vust )'ok rwoi-si r ty, is ett'rlra`oy.t`' ick.1• To Insure Extra Protection For Yourself and Your Property Yeii $on 1. Require that payments be made directly to subcontractors and material suppliers through a joint control. 'Any' joint control agreement should include the addendum approved by the Register of Contractors. help to insure that all persons due payment are actually paid. �. After making payments on any completed phase of the project, and before making any fuuther payments, require your Contractor ...-,....... .... -e is _ ...-_i.. .i i. c... _. ... _-E ... ... .. ...f ........... ...... ...F E. -F- ,. .. .. _.. .... of the work for which payment was made.. On projects involvingunconditionallien releases, the persons signing these releases lose the right to file a claim against your. property. In?. other types• of construction this protection:: may stil4 be important, but Wray . Applicable Law This Agreement, and all the rights and obligations -of the parties under this Agreement, shall be governed by. the law of the State of California. Consequential Damages . 'Buyer shall not -be entitled to .recover any .incident or consequential damages:as'that term is defined in Commercial Code Section 2715. In the event of litigation arising outof this Agreement, or the performance or interpretation: thereof, the court will award reasonable attorney's fees .to the. prevailing party.. This Agreement is full and final .Agreement of the parties and no written or oral communication between the parties before the F9ti;i.i9 if�n of the Agreemeirt will modify or amend the Agreement. "f'he Agreement maybe modified only by a written document signed a..Agerated Damages aural damages caused by such a breach are difficult and impractical to determine and include, among other things, administrative c�,is f;,r lyillirtg; �cco�ttrting fflr::nnd a�llectittg pall clue paytneats. Accordingly, buyer agrees to pay seller liquidated past damages as delinquency/service charges on all accounts past due at the rate of. 1.5% per.month, annual percentage of 19.0A/a until paid -in full- This agreement to be a reasonable method for fixing seller's damage- so rising.