The URL can be used to link to this page

09-0872 (RR)P.O. BOX 1504 78-495 CALLE TAMPICO LA QUINTA, CALIFORNIA 92253 Application Number: 09-00000872 Property Address: 77120 AVENIDA FERNANDO APN: 658 -240 -001 - Application description: RE -ROOF Property Zoning: LOW DENSITY RESIDENTIAL Application valuation: 18852 Td�v 4 4 Q" Applicant: Architect or Engineer: �I BUILDING & SAFETY DEPARTMENT BUILDING PERMIT LICENSED CONTRACTOR'S DECLARATION I hereby affirm under penalty of perjury that I am licensed under provisions of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professionals Code, and my License is in full force and effect. License Class: R C39 License N .: 235717 ractor: OWNER -BUILDER DECLARATION I hereby affirm under penalty of perjury that I am exempt from the Contractor's State License Law for the following. reason (Sec. 7031 .5, Business and Professions Code: Any city or county that requires a permit to construct, alter, improve, demolish, or repair any structure, prior to its issuance, also requires the applicant for the permit to file a signed statement that he or she is licensed pursuant to the provisions of the Contractor's State License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code) or that he or she is exempt therefrom and the basis for the alleged exemption. Any violation of Section 7031.5 by any applicant for a permit subjects the applicant to a civil penalty of not more than five hundred dollars ($500).: (_ 1 I, as owner of the property, or my employees with wages as their sole compensation, will do the work, and the structure is not intended or offered for sale ISec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who does the work himself or herself through his or her own employees, provided that the improvements are not intended or offered foi sale. If, however, the building or improvement is sold within one year of completion, the owner -builder will have the burden of proving that he or she did not build or improve for the purpose of sale.). (_ 1 1, as owner of the property, am exclusively contracting with licensed contractors to construct the project (Sec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who contracts for the projects with a contractor(s) licensed pursuant to the Contractors' State License Law.). ( 1 I am exempt under Sec. , B.&P.C. for this reason Date: Owner: CONSTRUCTION LENDING AGENCY I hereby affirm under penalty of perjury that there is a construction lending agency for the performance of the work for which this permit is issued ISec. 3097, Civ. C.). Lender's Name: Lender's Address: LQPERPIIT Owner: ANN WALKER 77120 AVENIDA FERNANDO LA QUINTA, CA 92253 VOICE (760) 777-7012 FAX (760) 777-7011 INSPECTIONS (760) 777-7153 Date: 8/14/09 I w u Contractor: tti� WESTERN PACIFIC ROOFING COR AUG i 4 20.39 3462 LA CAMPANA WAY PALM SPRINGS, CA 92262 (760)416-5877 CITY OF LA QU1IWA Lic. No.: 235717 FIWAT�-EPI'EPT ----------------------------------------------- WORKER'S COMPENSATION DECLARATION I hereby affirm under penalty of perjury one of the following declarations: I have and will maintain a certificate of consent to self -insure for workers' compensation, as provided for by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. I have and will maintain workers' compensation insurance, as required by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. My workers' compensation insurance carrier and policy number are: Carrier CYPRESS INS Policy Number 33000053308091 I certify that, in the performance of the work for which this permit is issued, I shall not employ any person in any manner so as to become subject to the workers' compensation laws of California, and agree that, if I should become subject to the workers' compensation provisions of Section 3 00 of the Labor Code, shall fo wit with t se provisions. ate: a icarit: WARNING: FAI URETO RE WORKERS' COMPENSATION COVERAGE IS UNLAWFUL, AND SHALL SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO ONE HUNDRED THOUSAND DOLLARS ($100,000). IN ADDITION TO THE COST OF COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE, INTEREST, AND ATTORNEY'S FEES. APPLICANT ACKNOWLEDGEMENT IMPORTANT Application is hereby made to the Director of Building and Safety for a permit subject to the conditions and restrictions set forth on this application. 1 . Each person upon whose behalf this application is made, each person at whose request and for whose benefit work is performed under or pursuant to any permit issued as a result of this application, the owner, and the applicant, each agrees to, and shall defend, indemnify and hold harmless the City of La Quinta, its officers, agents and employees for any act or omission related to the work being performed under or following issuance of this permit. 2. Any permit issued as a result of this application becomes null and void if work is not commenced within 180 days from date of issuance of such permit, or cessation of work for 180 days will subject permit to cancellation. I certify that I have read this application and state that the above information is correct. I agree to comply with all city and county ordinances and state laws relating to building construction, and hereby aut ri epresentat. ves of this d / to 9Ater upon a above-mentioned property forPur oses. ate: .f/• nature (Applicant or Agent): �4 • Application Number 09-00000872 Permit . . . RE -ROOF Additional desc . Permit Fee . . . . 30.00 Plan Check Fee .00 Issue Date . . . . Valuation . . . . 0 Expiration Date 2/10/10 Qty Unit Charge Per Extension - BASE FEE 30.00 ---------------------------------------------------------------------------- Special Notes and Comments INSTALLATION OF POLYURETHANE FOAM ROOF SYSTEM. 2007 CODES ---------------------------------------------------------------------------- Other Fees . . . . . . . BLDG STDS ADMIN (SB1473) 1.00 Fee summary Charged` ------------------------------------- Paid Credited -------------------- Due Permit Fee Total 30.00 .00 .00 30.00 Plan Check Total .00 .00 .00 .00 Other Fee Total 1.00 .00 .00 1.00 Grand Total 31.00 .00 .00 31.00 J LQPERIITT 3 i i) WESTERN PACIFIC Joel Walker 24414 Malibu Road Malibu, CA 90265 Roofing Corporation Lic. #235717 Subject: 77120 Ave. Fernando, La Quinta, CA 92253 Installation of a Polyurethane Foam and Coating System. Dear Mr. Walker: Thank you for the opportunity to submit a proposal for the re -roofing at the above referenced property. We are pleased to submit our proposal for the work as described below. The scope of work and associated costs are as follows: GENERAL This .proposal and contract is made between Western Pacific Roofing Corp. (Contractor) and the person (s) or entity named above (Owner). Unless expressly stated to the contrary, the contractor .shall be responsible for performing the following: DESCRIPTION A. The general conditions of this standard construction contract shall form a part of these specifications with the same force and effort as though repeated herein. B. The Contractor shall furnish all labor, materials, egdipment, permits, contractor's licenses and insurance certifications to perform .all operations required as.specified. The contractor shall provide labor and material customarily included in work of the same nature to give a quality, complete job. C. If any unforeseen or unexpected conditions are encountered during the work, and the conditions adversely affect the cost or progress of the work, the contractor will notify the owner immediately, and the owner will . negotiate a .written change -order to resolve the unexpected condition be it for an increase or decrease to the contract amount. D. The Contractor shall occupy, use, and permit others to use the premises only for the purpose of completing the work to be performed under this contract with the Owner. Contractor is to be given all reasonable set-up and .staging areas. Due to the limited access, some driveways or parking areas may be blocked during this construction process. '1469. T.a C'.amnans Wav • Palm 4nrinas,_ CA 92262 • (760) 416-5977 + Fax (760) 320-8912 Joel Walker August 5, 2009 Page 2 E. Contractor's scope of work shall not include the identification, detection, abatement, encapsulation or removal of asbestos or similar hazardous substances including mold, mildew and infestation of rodents. If Contractor encounters any such products, materials or conditions in the course of performing its work, or if such hazardous materials are encountered by any other firm performing work at the jobsite and contractor determines that such materials present a hazard to its employees, contractor shall have the right to discontinue its work and remove its employees from the jobsite until such products or materials, and any hazards connected therewith, are located and abated, encapsulated or removed, or it is determined that no hazard exists ( as the case may require), and contractor shall receive an extension of time to complete its work hereunder and compensation for delays encountered as a result of such situation and correction. Due to the possibility of mold, mildew and rodents being present before, during or after our work, Contractor's scope of work shall not include the identification, detection or the removal of mold, mildew and rodents. Owner agrees to hold Contractor harmless, and shall indemnify Contractor harmless for any mold or rodent related claims in the future. F. If a_dispute shall arise between Contractor and Owner with respect to any matters or questions arising out of or relating -to this contract or the breach thereof, such dispute shall be decided by arbitration administered by and in accordance with the Construction Industry .Arbitration Rules of the American Arbitration Association or through such arbitration procedures as the parties may agree. This contract shall be specifically enforceable under the prevailing arbitration law. The award rendered by the arbitrators shall'be final, and judgment may be entered upon it in any Court having jurisdiction thereof. G. Should suit be brought to enforce or interpret any part of this Agreement, the "prevailing party" shall be entitled to recover; .as an element of costs of suit and not as damages, reasonable attorneys' fees to be fixed by the Court. The "prevailing party" shall be entitled to recover its costs of suit, regardless of whether.such suit proceeds to final judgment. SURFACE PREPARATION A. Remove loose gravel by vacuuming and broom1 9- B. Damaged sheathing will be replaced at a rate of $65.00 per sheet or portion thereof. C. Prime roof deck with neoprime primer. D. Replace existing t -top vents. APPLICATION OF POLYURETHANE FOAM AND COATING A. Urethane shall be insulation shall be spray -applied to a minimal thickness of 1" (plus or minus 1/4") Additional foam will be added to the .low areas to help minimize ponding. Some ponding will remain. B. Coating shall be applied in a minimum of two separate coats. 1. The base coat shall be applied at a rate of 1.50 gallons per 100 square feet. 2. The top coat shall be applied at a rate of 1.50 gallons per 100 square feet, yielding a total system thickness for all coats of 22-24 TOTAL DRY MILS. Top coat .color to be Light Grey. 3. Embed ceramic granules 'in the wet top coat material at a rate of 50 pounds per 100 square feet. wEs�luv rac>Flc Roofing CorporoSon Joel Walker August 5, 2009 Page 3 4. All foam is to be coated. Coating shall extend up and over all foamed vent pipes and terminated a minimum of 2" above the foam, creating a neat appearance, self -terminating flashing. CONTRACT AMOUNT:. $18,852.00 (Eighteen Thousand Eight Hundred Fifty Two Dollars) NOTE #1: The HVAC units must be disconnected and re -installed during the re -roofing process. This work is to be completed by others and is NOT included in the contract amount. EXCLUSIONS: No items will be supplied nor work performed that is not specifically stated herein. PAYMENT TERMS: A One Thousand Dollar ($1,000.00) deposit upon approval of the contract. Twice -monthly payments until completion of contract. Invoices to be paid with 10 days of receipt. No retention to be held. Any remaining balance due following completion to be paid within 15 days of receipt of the invoice. WARRANTY A Five (5) year labor and material warranty will be issued by Western Pacific Roofing upon completion of the roof and final payment is received. Contractor's work will be warranted by Contractor in accordance with its standard warranty, which is made a part of this proposal and contract and incorporated by reference. A copy of the Contractor's standard warranty is attached or, if not, will be furnished upon. request. Contractor SHALL NOT BE LIABLE FOR SPECIAL, INCIDENTAL OR CONSEQUENTIAL DAMAGES. The acceptance of.this proposal by the Customer signifies his agreement that this warranty shall be and is the exclusive remedy against Contractor for all defects in workmanship furnished by Contractor. The price quoted has been structured. to reflect standards we assume are mutually desired: quality installation, service reliability and long -term performance. The price may be subject to change 15 days from the date of this proposal. If you are in accordance with the conditions herein, please execute the agreement below and return both copies to this office. We will; in turn, sign them and return one copy to you. Thank you for your cooperation in expediting this contract for your roofing needs. NOTICE TO OWNER Contractors are required by law to be licensed and regulated 'by the Contractor's State License .Board. Any questions concerning a contract may be referred to the Registrar, Contractor's State License Board, P.O. Box 26000, Sacramento, CA 95826 or call 1-800-321-CSLB or www. CSLB. CA. GOV for more information. 'AreWESTERN PACIFIC Roofing C -P -460n Joel Walker August 5, 2009 Page 4 LAW REQUIRES ANYONE WHO CONTRACTS TO DO CONSTRUCTION WORK TO BE LICENSED BY THE CONTRACTORS STATE LICENSE BOARD IN THE LICENSE CATEGORY IN WHICH THE CONTRACTOR IS GOING TO BE WORKING IF THE TOTAL PRICE OF THE JOB IS $500 OR MORE (INCLUDING LABOR AND MATERIALS). "LICENSED CONTRACTORS ARE REGULATED BY LAWS DESIGNED TO PROTECT THE PUBLIC. IF YOU CONTRACT WITH SOMEONE WHO DOES NOT HAVE A LICENSE, THE CONTRACTORS STATE LICENSE BOARD MAY BE UNABLE TO ASSIST YOU WITH A COMPLAINT. YOUR ONLY REMEDY AGAINST AN UNLICENSED CONTRACTOR MAY BE IN CIVIL COURT, AND YOU MAY BE LIABLE FOR DAMAGES ARISING OUT OF ANY INJURIES TO THE CONTRACTOR OR HIS OR HER EMPLOYEES. "YOU MAY CONTACT THE CONTRACTORS STATE LICENSE BOARD TO FIND OUT IF THIS CONTRACTOR HAS A VALID LICENSE. THE BOARD HAS COMPLETE INFORMATION ON THE HISTORY OF LICENSED CONTRACTORS, INCLUDING ANY POSSIBLE SUSPENSIONS, REVOCATIONS, JUDGMENTS, AND CITATIONS. THE BOARD HAS OFFICES THROUGHOUT CALIFORNIA. PLEASE CHECK THE GOVERNMENT PAGES OF THE WHITE PAGES FOR THE OFFICE NEAREST YOU OR CALL 1-800-321-CSLB OR WWW.CSLB.CA.GOV FOR MORE INFORMATION." ACKNOWLEDGMENT: Owner acknowledges that he/she has read and received a legible copy of this agreement including all terms and standard provisions before any work is performed and that he/she has read and received -a legible copy of every other document that owner has signed during this negotiation. Uwe hereby acknowledge under the penalty of perjury that Uwe .am/are the legal owners and am/are authorized to sign.this contract as an agent of the legal owner. ACCEPTANCE: The above prices, specifications. and conditions are satisfactory and are hereby accepted. You are .authorized to do the work as specified. Payment will be as outlined .above. You, the buyer may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction. See the attached Notice of Cancellation for an explanation of this right. Owner has .the right to require contractor to have a performance and payment bond at Owner -s expense. See other attached documents. JOEL WALKER Owner or Owner's Agent Date WESTERN PACIFIC ROOFING, CORP. Contractors License # 235717 Z'6 &J("� onald R Winkle August 5, 2009. Date WESTERN PACIFIC ROOFING HAS THE RIGHT TO RESCIND THIS CONTRACT WITHIN FIFTEEN DAYS OF ACCEPTANCE. THIS AGREEMENT IS NOT BINDING UNTIL ACCEPTED BY THE OFFICE MANAGEMENT AT 3462 LA CAMPANA WAY, PALM SPRINGS, CA 92262. NO CHANGES OR ADDITIONS TO THIS AGREEMENT SHALL BE EFFECTIVE UNTIL APPROVED BY WESTERN PACIFIC MANAGEMENT. MANAGERS ACCEPTANCE:DATE ,3/ 7-W WESTERN PACIFIC Are oofi Rng Comonmon JJ Permit # a- 6k �� {Pro &EAddress: 1 � % / ZU City Of La QuJnta Building &r Safety Division P.O. Box 1504, 78-495 Calle Tampico La Quinta, CA 92253 - (760) 777-7012 Building Permit Application and Tracking Sheet A. P. Number: AddressesZo A, -r— ��t,•tcr v Legal. Description:CAST Zi Contractor: �o � t � o ri P ns�$n .Y�,. + • �� ,. ,. Address:lffj t MZ Proect D`escnption: City, ST, Zip: ,e /n. S ` 2 Z G Z --1�u TAila fiv - ti of Low•-� Telephone: �3'P%7° -7( - Y/6 ..,.:• , :.;'s�'�%�:`?z F ' /� . State Lic. # :Z 3 r7 /'7 Arch., Engr., Designer. City Lic. #: Address: City., ST, Zip: Telephone: State Lic. #:+,� Name of Contact Person: .fi p; Construction Type: Occupancy: '1 n ; , Project type (circle one): New Add'n Alter Repair Demo Sq. Ft_:#Stories: # Units: Telephone # of Contact Person: # Submittal Req'd EstimatedVilue fo eject: APPLICANT: DO. NOT WRITE. BELOW THIS LINE Recd TRACIG NGFElectrical ��arSZ PERMIT FEES Plan Sets . Plan Check submitted Amount Structural Cales. Reviewed, ready for corrections Deposit Truss Cales. Called Contact Person Balance. Title 24 Calcs. Plans picked up n Flood plain plan Plans resubmitted Grading plan 2pd Review, ready for correctioustissue Subcontactor List Called Contact Person Grant Deed Plans picked up. S.M.1. H.O.A. Approval Plans resubmitted Grading IN HOUSE:- M Review,.ready for correctionstiissue Developer Impact Fee Planning Approval Called Contact Person A.I.P.P. Pub. Wks. Appr Date of permit issue School Fees Total Permit Fees