08-1637 (RR)P.O. BOX 1504
78-495 CALLE TAMPICO
LA QUINTA,: CALIFORNIA 92253
BUILDING & SAFETY DEPARTMENT
BUILDING PERMIT
Application Number:
08=00_0016,37
Property Address:
47225 WASHINGTON ST ,
APN:
6437090 -026 -2
-000000 -
Application description:
RE -ROOF
Property. Zoning:
LOW DENSITY RESIDENTIAL
Application valuation:
34870
Applicant:� �
Architect or Engineer: -
---------------------------------------------------
LICENSED CONTRACTOR'S DECLARATION
I hereby affirm under penalty of perjury that I am licensed under provisions of Chapter 9 (commencing with
Section 7000) of Division 3 of the Business and Professionals Code, and my License is in full force and effect.
license Class: B C39 License b.: 35717
Date:dJ Contractor:
OWNER -BUILDER DECLARATION
hereby affirm under penalty of perjury that -I am exempt from the Contractor's State License Law for the
following reason (Sec. 7031 .5, Business and Professions Code: Any city or county that requires a -permit to
construct, alter, improve, demolish, or repair any structure, prior to its issuance, also requires the applicant for the
permit to file a signed statement that he or she is licensed pursuant to the provisions of the Contractor's State
' License Law (Chapter 9 (commencing with Section 70001 of Division 3 of the Business and Professions Code) or
that he or she is exempt therefrom and the basis for the alleged. exemption. Any violation of Section 7031.5 by
any applicant for a permit subjectsthe applicant to a civil penalty of not more than five hundred dollars ($500).:
(_ 1 I, as owner of the property, or my employees with wages as their sole compensation, will do the work, and
'the structure is not intended or offered for sale (Sec: 7044, Business and Professions Code: The
Contractors' State License Law does not apply to an owner of(property who builds or improves thereon,
and who does the work himself or herself through his or her own employees, provided -that the
improvements are not intended or offered for sale. If, however, the building or improvement is sold within
one year of completion, the owner -builder will have the burden of proving that he or she did not build or -
improve for the purpose of sale.).
(_ 1 I, as owner of the property, am exclusively contracting with licensed contractors to construct the project (Sec.
7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of
property who builds or improves thereon, and who contracts for the projects with a contractor(s) licensed
pursuant to the Contractors' State License Law.).
i 1 I am exempt under Sec. B.&P.C. for this reason
Date: Owner:
CONSTRUCTION LENDING AGENCY
I hereby affirm under penalty of perjury that there is a constnirtion lending noenry for the performance of the
work for which this permit is issued (Sec. 3097, Civ. C.).
Lender's Name: -_
Lender's Address: _ �-
LQPERMIT
Owner:
ROMAN CATHOLIC BISHOP OF SB
1201 E HIGHLAND AVE
SAN BERNARDINO, CA 92404
r
Contractor:
WESTERN PACIFIC ROOFING
3462 LA CAMPANA WAY
PALM SPRINGS, CA 92262
(7.60)416-5877
LiC. No.: 235717
VOICE (760) 777-7012
FAX (760) 777-7011
INSPECTIONS (760) 777-7153
Date
9/29/08
------------------------------------------------
WORKER'S COMPENSATION DECLARATION
I hereby affirm under penalty of perjury one of the following declarations: -
_. I have and will maintain a certificate of consent to self -insure for workers' compensation, as provided
for by Section 3700 of the Labor Code, for the performance of the work for which this permit is
issued.
I have and will maintain workers' compensation insurance, as required by Section 3700 of the Labor
Code, for the performance ofithe work for which this permit is issued. My workers' compensation
insurance carrier and policy number are:
Carrier CYPRESS INS Policy Number 33000053308081
I certify that, in the performance of the work for which this permit is issued, 1 shall not employ any
_person in any manner so as to become subject to the workers' compensation laws of California,
and agree that, if I should become subject to the workers' compensation provisions of Section
3700 of the Labor�Code,l�y wit mplprovisions.
— .
_Date: -!)6m,.Applicant
WARNING: FAILURE TO SECURE WORKERS' COMPENSATION COVERAGE IS UNLAWFUL, AND SHALL -
SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO ONE HUNDRED THOUSAND
DOLLARS ($100,000). IN ADDITION TO THE COST OF COMPENSATION, DAMAGES AS PROVIDED FOR IN
SECTION 3706 OF THE LABOR CODE, INTEREST, AND ATTORNEY'S FEES.
APPLICANT ACKNOWLEDGEMENT
IMPORTANT Application is hereby made to the Director of Building and Safety for a permit subject to the
conditions and restrictions set forth on this application.
1 . Each person upon whose behalf this application is made, each person at whose request and for
whose benefit work is performed under or pursuant to any permit issued as a result of this application,
the owner, andthe applicant, each agrees to, and shall defend, indemnify and hold harmless the City
of La Quinta, its officers, agents and employees for any act or omission related to the work being
performed under or following issuance of this permit.
2. Any permit issued as a result of this application becomes null and void if work is not commenced
within 180 days from date of issuance of such permit, or cessation of. work for 180 days will subject
permit to cancellation.
I ccrtify thot I hove read this application and stale that the above information Is correct. Lagree to Comply with all
city and county ordinances and state laws relating to building construction, and hereb authorize representatives
of this county t enter upon the above-mentioned property f s�r ses.
Dater Signature (Applicant or Agen
8-00001637
Application Number _ 08-00001637-
Permit
Permit .. RE -.ROOF ,-
Additional desc ." .
Permit Fee 30.00
Plan Check
Fee
00
Issue Date
Valuation
0
Expiration Date,..,". 3/28/09
Qty Unit Charge Per
Extension
BASE
FEE
30.00
------------------------------------------------
Special Notes and Comments `
RE -ROOF INSTALLATION OF NEW TILE
UNDERLAYMENT'(:PARTIAL BUILDING)"PER A.J.
Fee summary Charged
Paid Credited
Due
" Permit Fee Total 30.00
.00•
00
30.00
Plan Check Total 00
�"
.00
00
.00
Grand Total 30.00.
.00 •.00
30.00
LQPERMIT
0
U.WESTERN PACIFIC
Z Roofing Corporation
Since 1949, Lic. #235717
August 5, 2008
Tom Ward . y
St. Francis of Assisi
47225 Washington Street
La Quinta, CA 92253
Subject: 4722 Washington St., La Quinta, CA 92253
Installation of. new tile underlayment on selected rear decks.
Dear Mr. Ward:
Thank you for the opportunity to submit a proposal for the re -roofing at the above referenced property.
We are pleased to submit.our proposal for the work as described below. The scope of work and associated
costs are as follows:
GENERAL'
This proposal and contract is made between 'Western Pacific Roofing. Corp; (contractor) and the person ;
(s) or entity named above (Owner). Unless expressly stated to the contrary, the contractor shall be
responsible for perforining the following:.
DESCRIPTION
A. The general conditions of -this standard construction contract shall form a part of these
specifications with the same force and -.effort as though repeated herein.
B. The Contractor shall furnish all labor, materials, equipment, permits, .contractor's licenses and
insurance 'certifications to perform all operations required as specified. The contractor shall
. provide labor -and material customarily included in work of .the same -nature. to give a quality,
complete job.
C.. If any unforeseen or unexpected conditions: are •encountered during the work, .and the conditions
adversely affect the cost or progress of the work, the contractor will notify the owner immediately,
and the owner will -negotiate a written change -order to resolve the unexpected condition be it for
an increase or decrease to the contract amount.
D. The Contractor shall occupy, .use, and permit others to use the premises only for the purpose of
completing the work to be performed under this contract with the Owner. Contractor is -to be
given all reasonable set-up and staging areas. Due to the limited access, some driveways or,
parking areas may blocked during this construction process.
3462 La Campana Way • Palm Springs, CA 92262'- (760) 416-5877 • Fax (760) 320-89.12
www.westpacroo£com E-mail: wprcps@westpacroo£com
St. Francis of Assis
August 5, 2008
Page 2
E: Contractor's scope of work shall not include the identification, detection, abatement,
encapsulation or removal of asbestos or similar hazardous substances including mold, mildew and
infestation of rodents. If .Contractor encounters any such products, materials* or conditions in the
course. of performing its work, or if such hazardous materials are encountered by any other firm
perforing work at the jobsite and contractor determines that such materials present a hazard to
its employees, contractor shall have the right to discontinue its work and remove its employees
from the jobsite until such products or materials, and any hazards connected therewith, are, located
and abated, encapsulated or removed, or it is determined that no hazard exists ( as the case may
require), and contractor shall receive an extension of time to complete its work hereunder and
compensation for delays encountered as d result of such situation and correction. Due to the
possibility of mold, mildew and rodents being present before, during or after our work;
Contractor's scope of work shall not include the identification, detection or the removal of mold,
mildew and rodents. Owner agrees to hold Contractor harmless, and shall indemnify Contractor
harmless for any mold or rodent related claims in the future.
F. If a dispute shall arise between Contractor and Owner with respect to any matters eor questions
arising out of or relating to this contract or the breach thereof, such dispute shall be decided by
arbitration administered by.and in accordance with the Construction Industry Arbitration Rules
of the American Arbitration Association or through such'arbitration procedures as the parties
may agree. This contract shall be specifically enforceable under the prevailing arbitration law.
The award rendered by the arbitrators shall be final, and judgment may be entered upon it in
any Court having jurisdiction thereof.
,G. Should suit be brought to enforce or interpret any part of this Agreement, the "prevailing party"
shall be :entitled to recover, as an:element of costs of suit and not as damages, reasonable
attorneys' fees to be fixed by the Court. The "prevailing party". shall be entitled to recover its costs
of suit, regardless of whether such suit proceeds to final judgment.
SURFACE .PREPARATION
A. Remove existing the and set aside.
B. • Damaged plywood will be replaced at a rate of $65.00 per sheet or portion thereof and billed
separately as a change -order.
INSTALLATION OF A NEW TILE UNDERLAYMENT.
A. Install new edge metal. (Unpainted)
B. Install two layers of #30 felt mechanically fastened.
C. Install new primary and secondary roof jacks at pipe locations.
D. Re -install existing tile.
E. Apply mortar to hip and ridge locations.
F. Install trim tile.
G. Paint roof jacks to match tile. ,
H. Install gutter at rear valley. (To be completed by others)
WESTERN PACIFIC
Roofing Corpnralia
• 'St.'Francis 'of Assisi
August 5, 2008 •.
Page 3 \
-
FLAT ROOF AREA (Rear HVAC well)
A. Broom existing roof clean.
B. Prime roof deck with neoprene primer.
C. Spray 1" polyurethane foam.
D. Base coat.l.5 gallons acrylic coating.
E. Top coat 1.5 ,gallons acrylic coating.
CONTRACT AMOUNT:, $34,870.00(Thirty Four Thousand Eight Hundred Seventy. Dollars) '
EXCLUSIONS: No items will be supplied nor -work performed that is not. specifically stated herein.
PAYMENT TERMS: A Ten Percent (10%) deposit upon approval of the contract. Twice -monthly
payments until. completion of contract. Invoices to be paid with 10,days of receipt. No retention to be
held. Any remaining balance due following completion to be paid within 15 days of receipt of the invoice.
WARRANTY
A Five (5) year>labor and material warranty will be issued by Western Pacific Roofing upori completion
of.the roof and final payment is received. Contractor's work.will be warranted by Contractor in
accordance with its standard warranty, which is made apart of this proposal and contract.and
incorporated by reference. A copy of the Contractor's standard warranty is attached or, if not, will be <` `
furnished upon request. Contractor SHALL NOT BE LIABLE FOR SPECIAL, INCIDENTAL OR
. CONSEQUENTIAL DAMAGES. The acceptance of this proposal by the Customer signifies his -
agreement that this warranty.shall be and is -'the exclusive remedy against Contractor forall defects in,
workmanship furnished by Contractor. `
The price quoted has been structured to reflect standards we assume', are mutually desired: quality , y}
installation, service reliability and long -te'rm performance. The price may be subjecf to change 15 days
from the date of this proposal:
e
If you are in accordance with the conditions herein, please execute the agreement below and return both
copies to this office. We will, in turn, sign them and return one copy to you. Thank .you for your
cooperation in expediting this contract for your roofing needs. x
NOTICE TO OWNER
Contractors are required by law to be licensed and regulated by the Contractor's State License •Board:
Any .questions concerning a contract may be referred to the Registrar, Contractor's State License Board,
P.O. Box 26000, Sacramento, 'CA `95826 or call. 1-800-321-CSLB or www. CSLB: CA. GOV for more
information.
WESTERN PACIFIC
Roofing Corporation - 7 -
. ��"'444111 t
St. Francis•of.Assisi
August 5, 2008
Page 4
LAW REQUIRES ANYONE WHO CONTRACTS TO DO CONSTRUCTION WORK TO BE LICENSED BY THE
CONTRACTORS STATE LICENSE BOARD IN THE LICENSE CATEGORY IN WHICH THE CONTRACTOR 1S
GOING TO BE WORKING IF THE TOTAL PRICE OF THE JOB IS $500 OR MORE (INCLUDING.LABOR AND
MATERIALS).
"LICENSED'CONTRACTORS ARE REGULATED BY LAWS DESIGNED TO PROTECT THE PUBLIC. IF YOU
CONTRACT WITH SOMEONE WHO DOES NOT HAVE A LICENSE, THE CONTRACTORS STATE LICENSE
BOARD MAY BE UNABLE TO ASSIST YOU WITH A COMPLAINT. YOUR ONLY, REMEDY AGAINST AN
UNLICENSED CONTRACTOR MAY BE IN CIVIL COURT, 'AND YOU MAY BE LIABLE FOR DAMAGES
ARISING OUT OF ANY INJURIES TO THE CONTRACTOR OR HIS OR HER EMPLOYEES.
"YOU MAY CONTACT THE. CONTRACTORS STATE LICENSE BOARD TO FIND OUT IF THIS
CONTRACTOR HAS A VALID LICENSE. THE BOARD HAS COMPLETE INFORMATION ON THE HISTORY
OF LICENSED CONTRACTORS, INCLUDING ANY POSSIBLE SUSPENSIONS, REVOCATIONS,.JUDGMENTS,
AND CITATIONS. THE BOARD HAS OFFICES THROUGHOUT CALIFORNIA. PLEASE CHECK THE
GOVERNMENT PAGES OF THE WHITE PAGES FOR'THE OFFICE NEAREST YOU OR CALL- 1-800-321—CSLB
OR WWW.CSLB. CA. GOV FOR MORE INFORMATION:"
ACKNOWLEDGMENT: Owner acknowledges that he/she has read and received a legible copy'.of .this
agreement including all terms and standard provisions before any work is performed and that he/she has
read.and received a legible copy of every other document that owner has signed during this negotiation.
Uwe hereby .acknowledge under the penalty of perjury that Uwe am/are -the legal owners and am/are
authorized to sign this contract as an agent of the legal owner.
ACCEPTANCE: The4bove prices, specifications and conditions are satisfactory and are hereby accepted.
You are authorized to do the work as -specified. Payment will be as outlined above. You, the buyer may
cancel this transaction at any time prior to .midnight of the third business day after the date of this
transaction.. See the attached Notice of Cancellation for.an explanation of this right. Owner has the right to
require contractor to have a performance and payment bond at Owner=s expense. "
See other attached documents.
ST. FRANCIS OF ASSISI WESTERN TACIFIC ROOFING, CORP. '
Contractors License # 235717
j0er or Owner's Agent Ronald R. Winkle
c
_August 5,2008
Date Date - -
WESTERN PACIFIC ROOFING HAS THE RIGHT TO RESCIND THIS CONTRACT WITHIN FIFTEEN DAYS OF ACCEPTANCE. THIS
AGREEMENT IS NOT BINDING UNTIL ACCEPTED BY THE OFFICE MANAGEMENT AT 3.462 LA CA' MPANA WAY, PALM SPRINGS,
• CA 92262. NO CHANGES OR ADDITIONS .TO THIS AGREEMENT SHALL BE EFFECTIVE UNTIL APPROVED BY WESTERN PACIFIC
MANAGEMENT.
MANAGERS ACCEPTANCE c DATE v w`�v� `
WESTERN PACIFIC -
Roofing Corporation +
Bin #
City, of La Quinta
Building & Safety Division
P.O. Box 1504, 78-495 Calle Tampico
La Quinta, CA 92253 - (760) 777-7012
Building Permit Application and Tracking Sheet
Permit #
Project Address:
A. P. Number:
Owner's Name:737 /l/4,✓Cts a f- ,3
Address:
Legal Description:
City, ST, Zip: 9z ZJ-3
Contractor: G'` oA`
Telephone:
x�+ c7
Address:
14,. t
Project Description:
City, ST, Zip: a /i►'r z
Telephone: 76a- 3K` sy77
`
State Lie. # : Z.3�7/�
City Lie. #:
Arch., Engr., Designer:
Address:
City, ST, Zip:
Telephone: -
State Lie. #:
Name of Contact Person:
Construction Type: Occupancy:
Project type (circle one): New Add'n Alter Repair Demo
Sq. Ft.: 5-40,j
#Stories:
# Units:
Telephone # of Contact Person: Estimated Value of Project:
APPLICANT: DO NOT. WRITE BELOW THIS LINE
to
Submittal
Req'd
Reed
TRACKING
PERMIT FEES
Plan Sets
Plan Check submitted
Item
Amount
Structural Cafes.
Reviewed, ready for corrections
Plan Check Deposit
Truss Cafes.
Called Contact Person
Plan Check.Balance
Energy Cafes.
Plans picked up
Construction
Flood plain plan
Plans resubmitted
Mechanical
Grading plan
2"d Review, ready for correctionsfissue
Electrical
Subcoatactor List
Called Contact Person
Plumbing
Grant Deed
Plans picked up
S.M.I.
H.O.A. Approval
Plans resubmitted
Grading
IN HOUSE:-
''d. Review, ready for correctioWissue
Developer Impact Fee
Planning Approval
Called Contact Person
A.I.P.P.
Pub. Wks. Appr
Date of permit issue
School Fees
Totai Permit Fees