RFP - La Fonda Parking Lot Project No 2018-14
City of La Quinta
Block Wall
PROJECT NO 2018-14
LA FONDA PARKING LOT PROJECT
AGREEMENT FOR CONTRACT SERVICES
THIS AGREEMENT FOR CONTRACT SERVICES (the “Agreement”) is
made and entered into by and between the CITY OF LA QUINTA, (“City”), a
California municipal corporation, and _________________________, a
_________________________ [insert type of business entity, e.g. sole
proprietorship, California Limited Liability Corporation, etc.] (“Contracting
Party”). The parties hereto agree as follows:
1. SERVICES OF CONTRACTING PARTY.
1.1 Scope of Services. In compliance with all terms and conditions
of this Agreement, Contracting Party shall provide those services related to
La Fonda Parking Lot, Project No. 20108-14, as specified in the “Scope of
Services” attached hereto as “Exhibit A” and incorporated herein by this
reference (the “Services”). Contracting Party represents and warrants that
Contracting Party is a provider of first-class work and/or services and
Contracting Party is experienced in performing the Services contemplated
herein and, in light of such status and experience, Contracting Party
covenants that it shall follow industry standards in performing the Services
required hereunder, and that all materials, if any, will be of good quality, fit
for the purpose intended. For purposes of this Agreement, the phrase
“industry standards” shall mean those standards of practice recognized by
one or more first-class firms performing similar services under similar
circumstances.
1.2 Compliance with Law. All Services rendered hereunder shall be
provided in accordance with all ordinances, resolutions, statutes, rules,
regulations, and laws of the City and any Federal, State, or local
governmental agency of competent jurisdiction.
1.3 Wage and Hour Compliance, Contracting Party shall comply with
applicable Federal, State, and local wage and hour laws.
1.4 Licenses, Permits, Fees and Assessments. Except as otherwise
specified herein, Contracting Party shall obtain at its sole cost and expense
such licenses, permits, and approvals as may be required by law for the
performance of the Services required by this Agreement, including a City of
La Quinta business license. Contracting Party and its employees, agents,
and subcontractors shall, at their sole cost and expense, keep in effect at all
times during the term of this Agreement any licenses, permits, and
approvals that are legally required for the performance of the Services
required by this Agreement. Contracting Party shall have the sole obligation
to pay for any fees, assessments, and taxes, plus applicable penalties and
interest, which may be imposed by law and arise from or are necessary for
-
the performance of the Services required by this Agreement, and shall
indemnify, defend (with counsel selected by City), and hold City, its elected
officials, officers, employees, and agents, free and harmless against any
such fees, assessments, taxes, penalties, or interest levied, assessed, or
imposed against City hereunder. Contracting Party shall be responsible for
all subcontractors’ compliance with this Section.
1.5 Familiarity with Work. By executing this Agreement, Contracting
Party warrants that (a) it has thoroughly investigated and considered the
Services to be performed, (b) it has investigated the site where the Services
are to be performed, if any, and fully acquainted itself with the conditions
there existing, (c) it has carefully considered how the Services should be
performed, and (d) it fully understands the facilities, difficulties, and
restrictions attending performance of the Services under this Agreement.
Should Contracting Party discover any latent or unknown conditions
materially differing from those inherent in the Services or as represented by
City, Contracting Party shall immediately inform City of such fact and shall
not proceed except at Contracting Party’s risk until written instructions are
received from the Contract Officer (as defined in Section 4.2 hereof).
1.6 Standard of Care. Contracting Party acknowledges and
understands that the Services contracted for under this Agreement require
specialized skills and abilities and that, consistent with this understanding,
Contracting Party’s work will be held to an industry standard of quality and
workmanship. Consistent with Section 1.5 hereinabove, Contracting Party
represents to City that it holds the necessary skills and abilities to satisfy the
industry standard of quality as set forth in this Agreement. Contracting
Party shall adopt reasonable methods during the life of this Agreement to
furnish continuous protection to the Services performed by Contracting
Party, and the equipment, materials, papers, and other components thereof
to prevent losses or damages, and shall be responsible for all such damages,
to persons or property, until acceptance of the Services by City, except such
losses or damages as may be caused by City’s own negligence. The
performance of Services by Contracting Party shall not relieve Contracting
Party from any obligation to correct any incomplete, inaccurate, or defective
work at no further cost to City, when such inaccuracies are due to the
negligence of Contracting Party.
1.7 Additional Services. In accordance with the terms and
conditions of this Agreement, Contracting Party shall perform services in
addition to those specified in the Scope of Services (“Additional Services”)
only when directed to do so by the Contract Officer, provided that
Contracting Party shall not be required to perform any Additional Services
without compensation. Contracting Party shall not perform any Additional
-
Services until receiving prior written authorization (in the form of a written
change order if Contracting Party is a contractor performing the Services)
from the Contract Officer, incorporating therein any adjustment in (i) the
Contract Sum, and/or (ii) the time to perform this Agreement, which said
adjustments are subject to the written approval of Contracting Party. It is
expressly understood by Contracting Party that the provisions of this Section
shall not apply to the Services specifically set forth in the Scope of Services
or reasonably contemplated therein. It is specifically understood and agreed
that oral requests and/or approvals of Additional Services shall be barred
and are unenforceable. Failure of Contracting Party to secure the Contract
Officer’s written authorization for Additional Services shall constitute a
waiver of any and all right to adjustment of the Contract Sum or time to
perform this Agreement, whether by way of compensation, restitution,
quantum meruit, or the like, for Additional Services provided without the
appropriate authorization from the Contract Officer. Compensation for
properly authorized Additional Services shall be made in accordance with
Section 2.3 of this Agreement.
1.8 Special Requirements. Additional terms and conditions of this
Agreement, if any, which are made a part hereof are set forth in “Exhibit D”
(the “Special Requirements”), which is incorporated herein by this reference
and expressly made a part hereof. In the event of a conflict between the
provisions of the Special Requirements and any other provisions of this
Agreement, the provisions of the Special Requirements shall govern.
2. COMPENSATION.
2.1 Contract Sum. For the Services rendered pursuant to this
Agreement, Contracting Party shall be compensated in accordance with
“Exhibit B” (the “Schedule of Compensation”) in a total amount not to
exceed ______________________________ Dollars ($____________)
(the “Contract Sum”), except as provided in Section 1.7. The method of
compensation set forth in the Schedule of Compensation may include a lump
sum payment upon completion, payment in accordance with the percentage
of completion of the Services, payment for time and materials based upon
Contracting Party’s rate schedule, but not exceeding the Contract Sum, or
such other reasonable methods as may be specified in the Schedule of
Compensation. The Contract Sum shall include the attendance of
Contracting Party at all project meetings reasonably deemed necessary by
City; Contracting Party shall not be entitled to any additional compensation
for attending said meetings. Compensation may include reimbursement for
actual and necessary expenditures for reproduction costs, transportation
expense, telephone expense, and similar costs and expenses when and if
specified in the Schedule of Compensation. Regardless of the method of
-
compensation set forth in the Schedule of Compensation, Contracting Party’s
overall compensation shall not exceed the Contract Sum, except as provided
in Section 1.7 of this Agreement.
2.2 Method of Billing & Payment. Any month in which Contracting
Party wishes to receive payment, Contracting Party shall submit to City no
later than the tenth (10th) working day of such month, in the form approved
by City’s Finance Director, an invoice for Services rendered prior to the date
of the invoice. Such invoice shall (1) describe in detail the Services
provided, including time and materials, and (2) specify each staff member
who has provided Services and the number of hours assigned to each such
staff member. Such invoice shall contain a certification by a principal
member of Contracting Party specifying that the payment requested is for
Services performed in accordance with the terms of this Agreement. Upon
approval in writing by the Contract Officer and subject to retention pursuant
to Section 8.3, City will pay Contracting Party for all items stated thereon
which are approved by City pursuant to this Agreement no later than thirty
(30) days after invoices are received by the City’s Finance Department.
2.3 Compensation for Additional Services. Additional Services
approved in advance by the Contract Officer pursuant to Section 1.7 of this
Agreement shall be paid for in an amount agreed to in writing by both City
and Contracting Party in advance of the Additional Services being rendered
by Contracting Party. Any compensation for Additional Services amounting
to five percent (5%) or less of the Contract Sum may be approved by the
Contract Officer. Any greater amount of compensation for Additional
Services must be approved by the La Quinta City Council, the City Manager,
or Department Director, depending upon City laws, regulations, rules and
procedures concerning public contracting. Under no circumstances shall
Contracting Party receive compensation for any Additional Services unless
prior written approval for the Additional Services is obtained from the
Contract Officer pursuant to Section 1.7 of this Agreement.
3. PERFORMANCE SCHEDULE.
3.1 Time of Essence. Time is of the essence in the performance of
this Agreement. If the Services not completed in accordance with the
Schedule of Performance, as set forth in Section 3.2 and “Exhibit C”, it is
understood that the City will suffer damage.
3.2 Schedule of Performance. All Services rendered pursuant to this
Agreement shall be performed diligently and within the time period
established in “Exhibit C” (the “Schedule of Performance”). Extensions to
the time period specified in the Schedule of Performance may be approved in
writing by the Contract Officer.
-
3.3 Force Majeure. The time period specified in the Schedule of
Performance for performance of the Services rendered pursuant to this
Agreement shall be extended because of any delays due to unforeseeable
causes beyond the control and without the fault or negligence of Contracting
Party, including, but not restricted to, acts of God or of the public enemy,
fires, earthquakes, floods, epidemic, quarantine restrictions, riots, strikes,
freight embargoes, acts of any governmental agency other than City, and
unusually severe weather, if Contracting Party shall within ten (10) days of
the commencement of such delay notify the Contract Officer in writing of the
causes of the delay. The Contract Officer shall ascertain the facts and the
extent of delay, and extend the time for performing the Services for the
period of the forced delay when and if in the Contract Officer’s judgment
such delay is justified, and the Contract Officer’s determination shall be final
and conclusive upon the parties to this Agreement. Extensions to time
period in the Schedule of Performance which are determined by the Contract
Officer to be justified pursuant to this Section shall not entitle the
Contracting Party to additional compensation in excess of the Contract Sum.
3.4 Term. Unless earlier terminated in accordance with the
provisions in Article 8.0 of this Agreement, the term of this agreement shall
commence on November 7, 2018 and terminate on or about November 30,
2018 (“Initial Term”).
4. COORDINATION OF WORK.
4.1 Representative of Contracting Party. The following principals of
Contracting Party (“Principals”) are hereby designated as being the princi pals
and representatives of Contracting Party authorized to act in its behalf with
respect to the Services specified herein and make all decisions in connection
therewith:
(a)
E-mail:
(b)
E-mail:
(c)
E-mail:
It is expressly understood that the experience, knowledge, capability,
and reputation of the foregoing Principals were a substantial inducement for
-
City to enter into this Agreement. Therefore, the foregoing Principals shall
be responsible during the term of this Agreement for directing all activities of
Contracting Party and devoting sufficient time to personally supervise the
Services hereunder. For purposes of this Agreement, the foregoing
Principals may not be changed by Contracting Party and no other personnel
may be assigned to perform the Services required hereunder without the
express written approval of City.
4.2 Contract Officer. The “Contract Officer” shall be Dianne Hansen,
Management Assistant, or such other person as may be designated in
writing by the City Manager of City. It shall be Contracting Party’s
responsibility to assure that the Contract Officer is kept informed of the
progress of the performance of the Services, and Contracting Party shall
refer any decisions, that must be made by City to the Contract Officer.
Unless otherwise specified herein, any approval of City required hereunder
shall mean the approval of the Contract Officer. The Contract Officer shall
have authority to sign all documents on behalf of City required hereunder to
carry out the terms of this Agreement.
4.3 Prohibition Against Subcontracting or Assignment. The
experience, knowledge, capability, and reputation of Contracting Party, its
principals, and its employees were a substantial inducement for City to enter
into this Agreement. Except as set forth in this Agreement, Contracting
Party shall not contract or subcontract with any other entity to perform in
whole or in part the Services required hereunder without the express written
approval of City. In addition, neither this Agreement nor any interest herein
may be transferred, assigned, conveyed, hypothecated, or encumbered,
voluntarily or by operation of law, without the prior written approval of City.
Transfers restricted hereunder shall include the transfer to any person or
group of persons acting in concert of more than twenty five percent (25%)
of the present ownership and/or control of Contracting Party, taking all
transfers into account on a cumulative basis. Any attempted or purported
assignment or contracting or subcontracting by Contracting Party without
City’s express written approval shall be null, void, and of no effect. No
approved transfer shall release Contracting Party of any liability hereunder
without the express consent of City.
4.4 Independent Contractor. Neither City nor any of its employees
shall have any control over the manner, mode, or means by which
Contracting Party, its agents, or its employees, perform the Services
required herein, except as otherwise set forth herein. City shall have no
voice in the selection, discharge, supervision, or control of Contracting
Party’s employees, servants, representatives, or agents, or in fixing their
number or hours of service. Contracting Party shall perform all Services
-
required herein as an independent contractor of City and shall remain at all
times as to City a wholly independent contractor with only such obligations
as are consistent with that role. Contracting Party shall not at any time or in
any manner represent that it or any of its agents or employees are agents o r
employees of City. City shall not in any way or for any purpose become or
be deemed to be a partner of Contracting Party in its business or otherwise
or a joint venture or a member of any joint enterprise with Contracting
Party. Contracting Party shall have no power to incur any debt, obligation,
or liability on behalf of City. Contracting Party shall not at any time or in
any manner represent that it or any of its agents or employees are agents or
employees of City. Except for the Contract Sum paid to Contracting Party as
provided in this Agreement, City shall not pay salaries, wages, or other
compensation to Contracting Party for performing the Services hereunder for
City. City shall not be liable for compensation or indemnification to
Contracting Party for injury or sickness arising out of performing the
Services hereunder. Notwithstanding any other City, state, or federal policy,
rule, regulation, law, or ordinance to the contrary, Contracting Party and any
of its employees, agents, and subcontractors providing services under this
Agreement shall not qualify for or become entitled to any compensation,
benefit, or any incident of employment by City, including but not limited to
eligibility to enroll in the California Public Employees Retirement System
(“PERS”) as an employee of City and entitlement to any contribution to be
paid by City for employer contributions and/or employee contributions for
PERS benefits. Contracting Party agrees to pay all required taxes on
amounts paid to Contracting Party under this Agreement, and to indemnify
and hold City harmless from any and all taxes, assessments, penalties, and
interest asserted against City by reason of the independent contractor
relationship created by this Agreement. Contracting Party shall fully c omply
with the workers’ compensation laws regarding Contracting Party and
Contracting Party’s employees. Contracting Party further agrees to
indemnify and hold City harmless from any failure of Contracting Party to
comply with applicable workers’ compensation laws. City shall have the
right to offset against the amount of any payment due to Contracting Party
under this Agreement any amount due to City from Contracting Party as a
result of Contracting Party’s failure to promptly pay to City any
reimbursement or indemnification arising under this Section.
4.5 Identity of Persons Performing Work. Contracting Party
represents that it employs or will employ at its own expense all personnel
required for the satisfactory performance of any and all of the Services set
forth herein. Contracting Party represents that the Services required herein
will be performed by Contracting Party or under its direct supervision, and
that all personnel engaged in such work shall be fully qualified and shall be
-
authorized and permitted under applicable State and local law to perform
such tasks and services.
4.6 City Cooperation. City shall provide Contracting Party with any
plans, publications, reports, statistics, records, or other data or information
pertinent to the Services to be performed hereunder which are reasonably
available to Contracting Party only from or through action by City.
5. INSURANCE.
5.1 Insurance. Prior to the beginning of any Services under this
Agreement and throughout the duration of the term of this Agreement,
Contracting Party shall procure and maintain, at its sole cost and expense,
and submit concurrently with its execution of this Agreement, policies of
insurance as set forth in “Exhibit E” (the “Insurance Requirements”) which is
incorporated herein by this reference and expressly made a part hereof.
5.2 Proof of Insurance. Contracting Party shall provide Certificate of
Insurance to Agency along with all required endorsements. Certificate of
Insurance and endorsements must be approved by Agency’s Risk Manager
prior to commencement of performance.
6. INDEMNIFICATION.
6.1 Indemnification. To the fullest extent permitted by law,
Contracting Party shall indemnify, protect, defend (with counsel selected by
City), and hold harmless City and any and all of its officers, employees,
agents, and volunteers as set forth in “Exhibit F” (“Indemnification”) which is
incorporated herein by this reference and expressly made a part hereof.
7. RECORDS AND REPORTS.
7.1 Reports. Contracting Party shall periodically prepare and submit
to the Contract Officer such reports concerning Contracting Party’s
performance of the Services required by this Agreement as the Contract
Officer shall require. Contracting Party hereby acknowledges that City is
greatly concerned about the cost of the Services to be performed pursuant
to this Agreement. For this reason, Contracting Party agrees that if
Contracting Party becomes aware of any facts, circumstances, techniques, or
events that may or will materially increase or decrease the cost of the
Services contemplated herein or, if Contracting Party is providing design
services, the cost of the project being designed, Contracting Party shall
promptly notify the Contract Officer of said fact, circumstance, technique, or
event and the estimated increased or decreased cost related thereto and, if
-
Contracting Party is providing design services, the estimated increased or
decreased cost estimate for the project being designed.
7.2 Records. Contracting Party shall keep, and require any
subcontractors to keep, such ledgers, books of accounts, invoices, vouchers,
canceled checks, reports (including but not limited to payroll reports),
studies, or other documents relating to the disbursements charged to City
and the Services performed hereunder (the “Books and Records”), as shall
be necessary to perform the Services required by this Agreement and enable
the Contract Officer to evaluate the performance of such Services. Any and
all such Books and Records shall be maintained in accordance with generally
accepted accounting principles and shall be complete and detailed. The
Contract Officer shall have full and free access to such Books and Records at
all times during normal business hours of City, including the right to inspect,
copy, audit, and make records and transcripts from such Books and Records.
Such Books and Records shall be maintained for a period of three (3) years
following completion of the Services hereunder, and City shall have access to
such Books and Records in the event any audit is required. In the event of
dissolution of Contracting Party’s business, custody of the Books and
Records may be given to City, and access shall be provided by Contracting
Party’s successor in interest. Under California Government Code
Section 8546.7, if the amount of public funds expended unde r this
Agreement exceeds Ten Thousand Dollars ($10,000.00), this Agreement
shall be subject to the examination and audit of the State Auditor, at the
request of City or as part of any audit of City, for a period of three (3) years
after final payment under this Agreement.
7.3 Ownership of Documents. All drawings, specifications, maps,
designs, photographs, studies, surveys, data, notes, computer files, reports,
records, documents, and other materials plans, drawings, estimates, test
data, survey results, models, renderings, and other documents or works of
authorship fixed in any tangible medium of expression, including but not
limited to, physical drawings, digital renderings, or data stored digitally,
magnetically, or in any other medium prepared or caused to be prepared by
Contracting Party, its employees, subcontractors, and agents in the
performance of this Agreement (the “Documents and Materials”) shall be the
property of City and shall be delivered to City upon request of the Contract
Officer or upon the expiration or termination of this Agreement, and
Contracting Party shall have no claim for further employment or additional
compensation as a result of the exercise by City of its full rights of ownership
use, reuse, or assignment of the Documents and Mater ials hereunder. Any
use, reuse or assignment of such completed Documents and Materials for
other projects and/or use of uncompleted documents without specific written
authorization by Contracting Party will be at City’s sole risk and without
-
liability to Contracting Party, and Contracting Party’s guarantee and
warranties shall not extend to such use, revise, or assignment. Contracting
Party may retain copies of such Documents and Materials for its own use.
Contracting Party shall have an unrestricted rig ht to use the concepts
embodied therein. All subcontractors shall provide for assignment to City of
any Documents and Materials prepared by them, and in the event
Contracting Party fails to secure such assignment, Contracting Party shall
indemnify City for all damages resulting therefrom.
7.4 In the event City or any person, firm, or corporation authorized
by City reuses said Documents and Materials without written verification or
adaptation by Contracting Party for the specific purpose intended and causes
to be made or makes any changes or alterations in said Documents and
Materials, City hereby releases, discharges, and exonerates Contracting
Party from liability resulting from said change. The provisions of this clause
shall survive the termination or expiration of this Agreement and shall
thereafter remain in full force and effect.
7.5 Licensing of Intellectual Property. This Agreement creates a
non-exclusive and perpetual license for City to copy, use, modify, reuse, or
sublicense any and all copyrights, designs, rights of reproduction, and other
intellectual property embodied in the Documents and Materials. Contracting
Party shall require all subcontractors, if any, to agree in writing that City is
granted a non-exclusive and perpetual license for the Documents and
Materials the subcontractor prepares under this Agreement. Contracting
Party represents and warrants that Contracting Party has the legal right to
license any and all of the Documents and Materials. Contracting Party
makes no such representation and warranty in regard to the Documents and
Materials which were prepared by design professionals other than
Contracting Party or provided to Contracting Party by City. City shall not be
limited in any way in its use of the Documents and Materials at any time,
provided that any such use not within the purposes intended by this
Agreement shall be at City’s sole risk.
7.6 Release of Documents. The Documents and Materials shall not
be released publicly without the prior written approval of the Contract Officer
or as required by law. Contracting Party shall not disclose to any other
entity or person any information regarding the activities of City, except as
required by law or as authorized by City.
7.7 Confidential or Personal Identifying Information. Contracting
Party covenants that all City data, data lists, trade secrets, documents with
personal identifying information, documents that are not public records,
draft documents, discussion notes, or other information, if any, developed or
received by Contracting Party or provided for performance of this Agreement
-
are deemed confidential and shall not be disclosed by Contracting Party to
any person or entity without prior written authorization by City or unless
required by law. City shall grant authorization for disclosure if required by
any lawful administrative or legal proceeding, court order, or similar
directive with the force of law. All City data, data lists, trade secrets,
documents with personal identifying information, documents that are not
public records, draft documents, discussions, or other information shall be
returned to City upon the termination or expiration of this Agreement.
Contracting Party’s covenant under this section shall survive the termination
or expiration of this Agreement.
8. ENFORCEMENT OF AGREEMENT.
8.1 California Law. This Agreement shall be interpreted, construed,
and governed both as to validity and to performance of the parties in
accordance with the laws of the State of California. Legal actions concerning
any dispute, claim, or matter arising out of or in relation to this Agreement
shall be instituted in the Superior Court of the County of Riverside, State of
California, or any other appropriate court in such county, and Contracting
Party covenants and agrees to submit to the personal jurisdiction of such
court in the event of such action.
8.2 Disputes. In the event of any dispute arising under this
Agreement, the injured party shall notify the injuring party in writing of its
contentions by submitting a claim therefore. The injured party shall
continue performing its obligations hereunder so long as the injuring party
commences to cure such default within ten (10) days of service of such
notice and completes the cure of such default within forty-five (45) days
after service of the notice, or such longer period as may be permitted by the
Contract Officer; provided that if the default is an immediate danger to the
health, safety, or general welfare, City may take such immediate action as
City deems warranted. Compliance with the provisions of this Section shall
be a condition precedent to termination of this Agreement for cause and to
any legal action, and such compliance shall not be a waiver of any party’s
right to take legal action in the event that the dispute is not cured, provided
that nothing herein shall limit City’s right to terminate this Agreement
without cause pursuant to this Article 8.0. During the period of time that
Contracting Party is in default, City shall hold all invoices and shall, when the
default is cured, proceed with payment on the invoices. In the alternative,
City may, in its sole discretion, elect to pay some or all of the outstanding
invoices during any period of default.
8.3 Waiver. No delay or omission in the exercise of any right or
remedy of a non-defaulting party on any default shall impair such right or
remedy or be construed as a waiver. City’s consent or approval of any act
-
by Contracting Party requiring City’s consent or approval shall not be
deemed to waive or render unnecessary City’s consent to or approval of any
subsequent act of Contracting Party. Any waiver by either party of any
default must be in writing and shall not be a waiver of any other default
concerning the same or any other provision of this Agreement.
8.4 Rights and Remedies are Cumulative. Except with respect to
rights and remedies expressly declared to be exclusive in this Agreement,
the rights and remedies of the parties are cumulative and the exercise by
either party of one or more of such rights or remedies shall not preclude the
exercise by it, at the same or different times, of any other rights or remedies
for the same default or any other default by the other party.
8.5 Legal Action. In addition to any other rights or remedies, either
party may take legal action, at law or at equity, to cure, correct, or remedy
any default, to recover damages for any default, to compel specific
performance of this Agreement, to obtain declaratory or injunctive relief, or
to obtain any other remedy consistent with the purposes of this Agreement.
8.6 Termination Prior To Expiration Of Term. This Section shall
govern any termination of this Agreement, except as specifically provided in
the following Section for termination for cause. City reserves the right to
terminate this Agreement at any time, with or withou t cause, upon thirty
(30) days’ written notice to Contracting Party. Upon receipt of any notice of
termination, Contracting Party shall immediately cease all Services
hereunder except such as may be specifically approved by the Contract
Officer. Contracting Party shall be entitled to compensation for all Services
rendered prior to receipt of the notice of termination and for any Services
authorized by the Contract Officer thereafter in accordance with the
Schedule of Compensation or such as may be approved by the Contract
Officer, except amounts held as a retention pursuant to this Agreement.
8.7 Termination for Default of Contracting Party. If termination is
due to the failure of Contracting Party to fulfill its obligations under this
Agreement, Contracting Party shall vacate any City-owned property which
Contracting Party is permitted to occupy hereunder and City may, after
compliance with the provisions of Section 8.2, take over the Services and
prosecute the same to completion by contract or otherwise, and Contracting
Party shall be liable to the extent that the total cost for completion of the
Services required hereunder exceeds the compensation herein stipulated
(provided that City shall use reasonable efforts to mitigate such damages),
and City may withhold any payments to Contracting Party for the purpose of
setoff or partial payment of the amounts owed City.
-
8.8 Attorneys’ Fees. If either party to this Agreement is required to
initiate or defend or made a party to any action or proceeding in any way
connected with this Agreement, the prevailing party in such action or
proceeding, in addition to any other relief which may be granted, whether
legal or equitable, shall be entitled to reasonable attorneys’ fees; provided,
however, that the attorneys’ fees awarded pursuant to this Section shall not
exceed the hourly rate paid by City for legal services multiplied by the
reasonable number of hours spent by the prevailing party in the conduct of
the litigation. Attorneys’ fees shall include attorneys’ fees on any appeal,
and in addition a party entitled to attorneys’ fees shall be entitled to all other
reasonable costs for investigating such action, taking depositions and
discovery, and all other necessary costs the court allows which are incurred
in such litigation. All such fees shall be deemed to have accrued on
commencement of such action and shall be enforceable whether or not such
action is prosecuted to judgment. The court may set such fees in the same
action or in a separate action brought for that purpose.
9. CITY OFFICERS AND EMPLOYEES; NONDISCRIMINATION.
9.1 Non-liability of City Officers and Employees. No officer, official,
employee, agent, representative, or volunteer of City shall be personally
liable to Contracting Party, or any successor in interest, in t he event or any
default or breach by City or for any amount which may become due to
Contracting Party or to its successor, or for breach of any obligation of the
terms of this Agreement.
9.2 Conflict of Interest. Contracting Party covenants that neither it,
nor any officer or principal of it, has or shall acquire any interest, directly or
indirectly, which would conflict in any manner with the interests of City or
which would in any way hinder Contracting Party’s performance of the
Services under this Agreement. Contracting Party further covenants that in
the performance of this Agreement, no person having any such interest shall
be employed by it as an officer, employee, agent, or subcontractor without
the express written consent of the Contract Officer. Contracting Party
agrees to at all times avoid conflicts of interest or the appearance of any
conflicts of interest with the interests of City in the performance of this
Agreement.
No officer or employee of City shall have any financial interest,
direct or indirect, in this Agreement nor shall any such officer or employee
participate in any decision relating to this Agreement which effects his
financial interest or the financial interest of any corporation, partnership or
association in which he is, directly or indirectly, interested, in violation of
any State statute or regulation. Contracting Party warrants that it has not
-
paid or given and will not pay or give any third party any money or other
consideration for obtaining this Agreement.
9.3 Covenant against Discrimination. Contracting Party covenants
that, by and for itself, its heirs, executors, assigns, and all persons claiming
under or through them, that there shall be no discrimination against or
segregation of, any person or group of persons on account of any
impermissible classification including, but not limited to, race, color, creed,
religion, sex, marital status, sexual orientation, national origin, or ancestry
in the performance of this Agreement. Contracting Party shall take
affirmative action to ensure that applicants are employed and that
employees are treated during employment without regard to their race,
color, creed, religion, sex, marital status, sexual orientation, national origin,
or ancestry.
10. MISCELLANEOUS PROVISIONS.
10.1 Notice. Any notice, demand, request, consent, approval, or
communication either party desires or is required to give the other party or
any other person shall be in writing and either served personally or sent by
prepaid, first-class mail to the address set forth below. Either party may
change its address by notifying the other party of the change of address in
writing. Notice shall be deemed communicated forty-eight (48) hours from
the time of mailing if mailed as provided in this Section.
To City:
CITY OF LA QUINTA
Attention: Steve Howlett
Facilities Director
78-495 Calle Tampico
La Quinta, California 92253
To Contracting Party:
10.2 Interpretation. The terms of this Agreement shall be construed
in accordance with the meaning of the language used and shall not be
construed for or against either party by reason of the authorship of this
Agreement or any other rule of construction which might otherwise apply.
10.3 Section Headings and Subheadings. The section headings and
subheadings contained in this Agreement are included for conv enience only
and shall not limit or otherwise affect the terms of this Agreement.
10.4 Counterparts. This Agreement may be executed in counterparts,
each of which shall be deemed to be an original, and such counterparts shall
constitute one and the same instrument
-
10.5 Integrated Agreement. This Agreement including the exhibits
hereto is the entire, complete, and exclusive expression of the
understanding of the parties. It is understood that there are no oral
agreements between the parties hereto affecting this Agreement and this
Agreement supersedes and cancels any and all previous negotiations,
arrangements, agreements, and understandings, if any, between the parties,
and none shall be used to interpret this Agreement.
10.6 Amendment. No amendment to or modification of this
Agreement shall be valid unless made in writing and approved by
Contracting Party and by the City Council of City. The parties agree that this
requirement for written modifications cannot be waived and that any
attempted waiver shall be void.
10.7 Severability. In the event that any one or more of the articles,
phrases, sentences, clauses, paragraphs, or sections contained in this
Agreement shall be declared invalid or unenforceable, such invalidity or
unenforceability shall not affect any of the remaining articles, phrases,
sentences, clauses, paragraphs, or sections of this Agreement which are
hereby declared as severable and shall be interpreted to carry out the intent
of the parties hereunder unless the invalid provision is so material that its
invalidity deprives either party of the basic benefit of their bargain or
renders this Agreement meaningless.
10.8 Unfair Business Practices Claims. In entering into this
Agreement, Contracting Party offers and agrees to assign to City all rights,
title, and interest in and to all causes of action it may have under Section 4
of the Clayton Act (15 U.S.C. § 15) or under the Cartwright Act (Chapter 2,
(commencing with Section 16700) of Part 2 of Division 7 of the Business and
Professions Code), arising from purchases of goods, services, or materials
related to this Agreement. This assignment shall be made and become
effective at the time City renders final payment to Contracting Party without
further acknowledgment of the parties.
10.9 No Third Party Beneficiaries. With the exception of the specific
provisions set forth in this Agreement, there are no intended third -party
beneficiaries under this Agreement and no such other third parties shall have
any rights or obligations hereunder.
10.10 Authority. The persons executing this Agreement on behalf of
each of the parties hereto represent and warrant that (i) such party is duly
organized and existing, (ii) they are duly authorized to execute and deliver
this Agreement on behalf of said party, (iii) by so executing this Agreement,
such party is formally bound to the provisions of this Agreement, and
(iv) that entering into this Agreement does not violate any provision of any
-
other Agreement to which said party is bound. This Agreement shall be
binding upon the heirs, executors, administrators, successors, and assigns of
the parties.
[SIGNATURES ON FOLLOWING PAGE]
-
IN WITNESS WHEREOF, the parties have executed this Agreement as of
the dates stated below.
CITY OF LA QUINTA,
a California Municipal Corporation
FRANK J. SPEVACEK, City Manager
City of La Quinta, California
Dated: _____
CONTRACTING PARTY:
By:
Name:
Title:
ATTEST:
MONIKA RADEVA, City Clerk
La Quinta, California
By:
Name:
Title:
APPROVED AS TO FORM:
WILLIAM H. IHRKE, City Attorney
City of La Quinta, California
Last revised summer 2017
Exhibit A
Scope of Services
1. Services to be Provided:
Demolition of a portion of the existing boundary wall and building a
new portion of boundary wall along the new property line, provide
support/bracing for the side walls throughout constructions, minor
grading, replacing gravel, and all other incidentals needed to complete
Project No, 2018-14 located at the corner of Avenida La Fonda and
Desert Club Drive. (Please read Details in Section “D” Special
Requirements).
Item
No.
Description Qty Unit Unit
Price
(Dollars)
Item total
(Dollars)
1
Provide support/bracing for side
walls, demolish and remove
designated portion of existing
block wall and gate; remove
debris.
1
LF
$
$
2
Construct Precision Block site
wall, (precision block to match
existing) as shown in CLQ
standard plan S-1.1LQ and as
modified on sheet one.
116
LF
$
$
3
Grade out existing ground 1:4
slope as needed on all sides of
the completed wall. Existing
gravel to be pushed aside, grade
subsoil and spread rock over sub
grade to the satisfaction of the
City. (Any additional rock
needed to be provided by City).
1
LS
$
$
TOTAL:
$
$
Proposal Amount of the Items above must be filled in and completed. It is
understood that the quantities shown are estimates and the Contractor is
responsible to verify quantities prior to submitting a proposal. Final
payment will be based upon actual work performed, subject to such
adjustments and alterations as elsewhere provided herein.
Contractor is responsible for mobilization which includes expenditures for all
preparatory work and operations, including but not limited to, those costs
necessary for the movement of personnel, equipment, supplies, and
incidentals to the project site; for the establishment of all facilities necessary
to work on the project; and for all other work and operations which must be
performed or cost incurred prior to beginning work on the various contract
items on the project site as well as the related demobil ization costs
anticipated at the completion of the project.
The proposal submitted shall include adequate sheeting, shoring and
bracing, or equivalent method, for the protection of life and limb in trenches
and open excavation, which shall conform to applicable safety orders. The
Contractor warrants that its action does not convey tort liability to the City,
its consultants, and their employees, agents, and subconsultants.
REMOVAL OF EXISTING MASONRY SITE WALL / CONSTRUCTION
SITE SECURITY FENCING
Construction site fencing will be installed by the City prior to the existing
masonry site wall being removed to secure the individual property from the
work area and from intrusion from the outside.
The removal of existing masonry site wall shall include the removal of
existing masonry as designated in the plans, associated footings, gate, gate
footings, and leftover debris.
Removal of existing wall shall be scheduled and performed so that positive
access control is maintained at all times. The fence shall be secured at the
base to ensure access outside the yard is unattainable through the
temporary fence.
Concurrent with the commencement of the removal operation, the
Contractor shall erect a temporary fence to block access to the private
property.
All costs associated with the removal of the existing masonry wall shall be
included in the linear foot price for “Demolish and Remove Designated
Portion of Existing Site Wall” and shall include full compensation for all labor,
material, equipment, tools, and incidentals necessary, and as required by
the City Engineer.
On removal of the "Construction Site Security Fencing," after the new wall is
constructed, Contractor is responsible to backfill any fence post holes.
STRUCTURE EXCAVATION AND BACKFILL
Excavated footings shall not be left open or uncovered at any time or left
unattended for any period of time. At the end of each shift any portion of
excavated footing that has been dug and not poured with concrete shall be
completely covered with plywood to protect against unwanted entry of
people and animals. In lieu of plywood the entire area can be fenced with
temporary fence panels that are 6 foot in height provided they are secured
in place and encompass the entire area exposed with open trench, and there
are no gaps or openings large enough to allow a person or animal to pass
onto the other side of the fencing and be exposed to the open trench hazard.
The Contractor shall minimize the limits of excava tion on the private
property side of the site wall and all backfill shall be placed and compacted
by means of access from City street side of the site wall. Compacted fill
should be placed in maximum 8 inch lifts (loose) and compacted to a
minimum of 90% of ASTM D1557 maximum dry density at optimum
moisture 2%.
All loose material existing at the bottom of the trench after digging has been
completed shall be removed to the depth of foundation shown on the plans
before placing concrete in the trench.
Any imported borrow materials required for structural backfill of the
proposed site wall shall be tested for corrosive properties prior to placement.
Imported borrow material if needed, shall have non -corrosive properties and
shall conform to Section 300-3.5 of the State Standard Specifications.
Payment for earthwork, including but not necessarily limited to grading,
excavation, removal and recompaction outside the footings, disposal,
compaction, backfill, structural backfill, trenching, and trench protectio n
shall be included in the linear foot price for “Construct Precision Block Site
Wall,” and no additional compensation will be allowed therefore.
Payment for earthwork, including but not necessarily limited to re -contouring
the areas on either side of the wall to insure proper drainage and a 1:4 slope
shall be included in the lump sum price for “Replace Gravel and Grade Out
1:4 Slope as Needed, to the Satisfaction of the City,” and no additional
compensation will be allowed therefore.
REINFORCED CONCRETE
Minimum concrete and reinforcement strengths shall be as indicated on the
plans. The class of concrete shall be 520 -C-3250. Reinforcing bars shall
conform to ASTM Designation A615.
All cement to be used or furnished shall be Type II low alkali Portland
cement conforming to ASTM 150.
The Contractor shall furnish a Certificate of Compliance signed by the
manufacturer identifying the cement and confirming compliance.
The Contractor shall determine the mix proportions of concrete specified on
the Plans by its 28-day compressive strength within the minimum cement,
maximum size coarse aggregate limitations.
A compressive strength test shall consist of the average strength of four (or
as many as the City requests) cylinders fabricated from a single load of
concrete, except that if any cylinder shows evidence of improper handling,
molding, or testing, it shall be discarded and the strength test shall consist
of the strength of the remaining cylinder.
The City will determine the frequency of sampling. The Contractor shall
afford all reasonable access, without charge, for the procurement of samples
of fresh concrete at time of placement.
Concrete aggregate shall be composed of gravel, crushed rock, or a blended
mixture. All concrete aggregate shall be washed before delivery to the
batching plant.
Payment for all reinforced concrete, including but not necessarily limited to
forming, bar reinforcing steel, pouring, finishing, washout pits, excavation,
backfill, compaction, and curing shall be included in the linear foot price for
“Construct Precision Block Site Wall,” and no additiona l compensation will be
allowed therefore.
SITE WALL (MASONRY BLOCK)
Masonry Site Wall Construction as shown on the plans shall conform to these
Specifications. Site walls shall be supported on concrete spread footings as
shown on the plans. Unless otherwise shown on the plans, the site wall
Layout Line shall be the vertical face of the wall along the property line.
The site wall shall be constructed with the running bond masonry block
pattern. The block shall be precision type and the color of the block shall
match the existing adjoining wall. The Contractor shall submit a sample prior
and have it approved prior to placing the order.
Site wall masonry unit stems shall be constructed with joints of Portland
cement mortar. Wall Stems shall be constructed with hand laid block. Wall
Stems shall not be constructed with pre-assembled panels.
Reinforcing bars shall conform to ASTM Designation: A615.
Concrete masonry units shall be hollow, load bearing, conforming to ASTM
Designation: C 90, normal weight classification, Type II. Standard or open-
end units may be used. Open-end units, if used, shall not reduce the spacing
of the bar reinforcement as shown on the plans.
The masonry units shall be blocks of nominal size and texture and uniform
color. Samples of masonry units for wall construction shall be submitted for
approval prior to placing an order. The 28 calendar days of cure time will
not be counted as contract working days and shall be clearly shown within
the Contractor’s CPM baseline schedule.
All units shall be sound and free of cracks or other defects that would
interfere with the proper placing of the unit or impair the strength or
permanence of the construction. Units may have minor cracks incidental to
the usual method of manufacture, or minor chipping resulting from
customary methods of handling in shipment and delivery. Where units are to
be used in exposed wall construction, the faces that are to be exposed shall
be free of chips, cracks or other imperfections when viewed from 20 feet,
except that not more than 5 percent of a shipment may have slight cracks or
small chips not larger than 1 inch.
Expansion joint filler shall conform to ASTM Designation: D 1751 or ASTM
Designation: D 2000 2AA-805. Expansion Joints and block steps shall be
located to match existing locations, where applicable, at full block or half
block intervals. The Contractor shall adjust the location of the expan sion
joints or block steps as shown on the plans to meet this objective. Expansion
joint or block step location adjustments shall be made with the nearest half -
block increment to the distance or station shown on the plans. No additional
compensation for any adjustment to the plans for locating expansion joints
or block steps shall be made.
Payment for all site wall masonry block, including but not necessarily limited
to the items of work outlined within Sections “Mortar”, “Grout”,
“Construction Methods”, shop drawings, scaffolding, covering the wall, bar
reinforcing steel, masonry cap, openings, mechanical couplers (if used),
excavation, backfill, and disposal of excess material shall be included in the
linear foot price for “Construct Precision Block Site Wall,” and no additional
compensation will be allowed therefore.
The linear foot quantities for the “Construct Precision Block Site Wall” shall
be measured from horizontal measurements conducted in the field along the
layout line.
MORTAR
Portland cement mortar shall not be colored.
Splashing water over the top of the mortar is not permissible. Harsh mortar,
mortar that has begun to stiffen or harden due to hydration, shall be thrown
out. Mortar must be used within one hour after the initial water has been
added to the dry ingredients at the job site, and at no time after the
introduction of water into the mix be re-tempered.
Mortar shall be Spec Mix Type ‘S’ Preblended Masonry Mortar as
manufactured by E-Z Mix, Inc., conforming to proportions and requirements
of ASTM C270, or Spec Mix IWR Masonry Mortar as manufactured by E-Z
Mix, Inc., conforming to property requirements of ASTM C270.
GROUT
Aggregate for grout used to fill masonry units shall consist of fine aggreg ate
and coarse aggregate conforming to the provisions in Section 90 -2.02,
"Aggregates," of the State Standard Specifications. At least 20 percent of
the aggregate shall be coarse aggregate. The Contractor shall determine
the grading except that 100 percent of the combined grading shall pass the
1/2 sieve.
Grout shall conform to ASTM C476, with an 8-11-inch slump, and shall have
a minimum compressive strength at 28 days of 2000 psi.
CONSTRUCTION METHODS
Construction of reinforced concrete masonry unit wall stems with Portland
cement mortar joints shall conform to the following:
a. Concrete masonry unit construction shall be true and plumb in the
lateral. Bond beam units or recesses for horizontal reinforcement shall
be provided.
b. Low lift grouting method will be employed. The wall is constructed in
4’-0" increments (eight block courses). Prior to grouting horizontal and
vertical and
embedded items, if any, are positioned. It is important that sufficient
time is allowed for the mortar joints to set and be able to withstand
the grout pressure.
c. Grout is poured into all reinforced cells, to a height approximately 1 -
1/2" above or below the last mortared bed joint. The last lift is poured
to the top of the wall.
d. Vertical cells to be filled must align vertically to maintain a continuous
unobstructed cell area not less than 1 -1/2 x 2". Horizontal beams to
be grouted should be isolated horizontally with metal lath or special
concrete block units to prevent the grout from flowing into cells that
should be void. Paper shall not be used for the purpose; however, 30
pound felt may be used if it does not extend into the mortar joint.
e. Between grout pours, a horizontal construction joint shall be formed by
stopping all the wythes at the same elevation and with the grout
stopping a minimum of 1-1/2" below a mortar joint, except at the top
of a wall. Where bond beams occur, stop the grout pour a minimum of
1/2" below the top of the masonry.
f. Mortar joints shall be approximately ½” wide. Walls and cross we bs
forming cells to be filled with grout shall be fully bedded in mortar to
prevent leakage of grout. All head and bed joints shall be solidly filled
with mortar for a distance in from the face of the wall or unit not less
than the thickness of the longitudinal fare shells. Head joints shall be
shoved tight.
g. Mortared joints around cells to be filled shall be placed so as to
preserve the unobstructed vertical continuity of the grout filling. Any
overhanging mortar or other obstruction or debris shall be removed
from the inside of such cells.
h. Reinforcement shall be securely held in position at top and bottom
with either wire ties or spacing devices and at intervals not exceeding
192 bar diameters. Wire shall be 16-gage or heavier. Wooden,
aluminum, or plastic spacing devices shall not be used.
i. Splices in vertical reinforcement will be allowed only where shown on
the plans.
j. Only those cells containing reinforcement and those shown on the
plans shall be filled solidly with grout. All grout in the cells shall be
consolidated at the time of placement by vibrating and re -consolidated
after excess moisture has been absorbed but before plasticity is lost.
Slicing with a trowel is not acceptable.
k. If the total height of grout to be placed exceeds 6 feet, the grout shall
be placed in 4-foot maximum height lifts. The grout placement shall
proceed in lifts until the full height of the section is placed. A minimum
waiting period between placing of lifts shall be limited to the time
required to obtain initial consolidation of grout, but shall be not less
than 30 minutes.
l. A construction joint is required at the top of the top course to permit
placement of the mortar cap. The mix design for the mortar cap shall
be as approved by the City Engineer.
m. Construction joints shall be made in grout when the placing of grout in
grout filled cells is stopped for more than one hour. The construction
joint shall be ½” below the top of the last course filled with grout.
n. Bond beams shall be continuous. The top of unfilled cells under
horizontal bond beams shall be covered with metal or plastic lath.
o. When fresh masonry joins masonry that is partially or totally set, the
contact surface shall be cleaned, roughened and lightly wetted.
p. Surface of the concrete on which the masonry walls are to be placed
shall be roughened and cleaned, exposing the stone aggregate, and
shall be flushed with water and allowed to dry to a surface dry
condition immediately prior to laying the masonry units.
q. Where masonry unit cutting is necessary, all cuts shall be made with a
masonry saw to neat and true lines. Masonry units with excessive
cracking or chipping of the finished exposed surfaces will not be
acceptable.
r. Masonry shall be protected as provided for concrete structures in
Section 90-8 of the State of California Department of Transportation
Standard Specifications.
s. During erection, all cells shall be kept dry in inclement weather by
covering partially completed walls. The covering shall be waterproof
fabric, plastic or paper sheeting, or other approved material. Wooden
boards and planks are not acceptable as covering materials. The
covering shall extend down each side of masonry walls approximately
2 feet.
t. Splashes, stains or spots on the exposed faces of the wall shall be
removed.
u. All masonry joints must be tooled.
Wall construction can be done in wet weather providing rain does not fall on
the masonry materials or on the freshly laid walls. The cement, units and
sand should be covered to keep them dry. They should also be stored off the
ground so there is no migration of moisture from the ground to the
materials. Walls should be protected from rain for 24 to 48 hours, depending
on the temperature, so that the mortar is fully set, and bond has occurred.
The common practice of laying a heavy board on top of the wall at
the end of the workday does not keep the work protected and can
cause the masonry underneath to sag or bow out of position.
Traffic control and the traffic plan shall conform to the following:
a. The traffic control plan shall indicate the traffic control
requirements for the different types of work to be performed. The
Contractor shall be responsible for the preparation of plans as
necessary for specific items of work. These plans shall be
approved by the City Engineer prior to the Contractor commencing
any work.
b. All traffic controls and safety devices, equipment and materials,
including but not limited to, cones, delineators, flashing warning
lights, barricades, high level warning devices (flag trees), flags,
signs, makers, portable barriers, flashing arrow signs, electronic
changeable message signs and markings shall be provided and
maintained in “like new” condition.
c. The Contractor shall furnish and properly install, construct, erect,
use, and continuously inspect and maintain, twenty -four (24)
hours per day, seven (7) days a week, all said devices, equipment
and materials and all temporary and permanent pedestrian and
driving surfaces as necessary to provide for the safety and
convenience of, and to properly warn, guide, control, regulate,
channelize, and protect the vehicular traffic, pedestrian traffic,
project workers, and the public throughout the entire limits of the
work activity and beyond said limits as necessary to include area
affecting or affected by the work, from the start of work to the
completion of the work.
DUST CONTROL:
Dust control shall include, but is not limited to the following:
1) Maintain dust control at all times by watering, including
developing a water supply, and furnishing and placing all water
required for work done in the contract.
2) Provide means to prevent track out onto public streets.
3) Contractor shall notify the City to make arrangements for street
sweeping of material tracked onto public streets as needed.
Notification
The Contractor shall notify the City, local authorities, and utility companies,
of his intent to begin work at least five days before work is to begin. The
Contractor shall cooperate with local authorities relative to handling traffic
through the area including coordinating with trash collection, school bus
schedules, public transportation and emergency activities.
Three days before work is to begin, the Contractor shall provide
written notice of intent to begin work to all adjacent properties. The
written notice will be approved by the City prior to issuance and
shall include at least the following information: brief description of
the improvements, the name, address and phone number of the
Contractor, and the date and time work is to begin and finish.
Contractor shall update and repost the information in the event the
work is rescheduled. The City shall notify Frontier when the work
will begin prior to construction.
Contractor is responsible to repair/replace any damage of existing irrigation
during demolition/construction. Irrigation: All pipe 3” and smaller shall be
Schedule 40 PVC Type 1, Grade 1 pipe. All plastic pipes will bear the
following markings: the manufacturers name, nominal pipe size or
schedules. Contractor is responsible to re-align irrigation away from
concrete footings, connect to the existing system, and ensure irrigation
coverage to the trees.
The proposal submitted shall include adequate sheeting, shoring and
bracing, or equivalent method, for the protection of life and limb in trenches
and open excavation, which shall conform to applicable safety orders. The
Contractor warrants that its action does not convey tort liability to the City,
its consultants, and their employees, agents, and subconsultants.
Means and methods required to perform the wo rk are to be determined by
Contractor.
2. Performance Standards:
Contactors are required to provide high-quality service for the specified
items in accordance with the best standards of practice and specifications
per the plan sheet. Services include responsibility to furnish at his/her own
expense all transportation, tools, equipment, fuel, labor, materials, supplies,
supervision and services necessary for satisfactory performance of the work.
ADDENDUM TO AGREEMENT
Re: Scope of Services
If the Scope of Services include construction, alteration, demolition,
installation, repair, or maintenance affecting real property or structures or
improvements of any kind appurtenant to real property, the following apply:
1. Prevailing Wage Compliance. If Contracting Party is a contractor
performing public works and maintenance projects, as described in this
Section 1.3, Contracting Party shall comply with applicable Federal, State,
and local laws. Contracting Party is aware of the requirements of California
Labor Code Sections 1720, et seq., and 1770, et seq., as well as California
Code of Regulations, Title 8, Sections 16000, et seq., (collectively, the
“Prevailing Wage Laws”), and La Quinta Municipal Code Section 3.12.040,
which require the payment of prevailing wage rates and the performance of
other requirements on “Public works” and “Maintenance” projects. If the
Services are being performed as part of an applicable “Public works” or
“Maintenance” project, as defined by the Prevailing Wage Laws, and if
construction work over twenty-five thousand dollars ($25,000.00) and/or
alterations, demolition, repair or maintenance work over fifteen thousand
dollars ($15,000.00) is entered into or extended on or after January 1, 2015
by this Agreement,, Contracting Party agrees to fully comply with such
Prevailing Wage Laws including, but not limited to, requirements related to
the maintenance of payroll records and the employment of apprentices.
Pursuant to California Labor Code Section 1725.5, no contractor or
subcontractor may be awarded a contract for public work on a “Public works”
project unless registered with the California Department of Industrial
Relations (“DIR”) at the time the contract is awarded. If the Services are
being performed as part of an applicable “Public works” or “Maintenance”
project, as defined by the Prevailing Wage Laws, this project is subject to
compliance monitoring and enforcement by the DIR. Contracting Party will
maintain and will require all subcontractors to maintain valid and current
DIR Public Works contractor registration during the term of this Agreement.
Contracting Party shall notify City in writing immediately, and in no case
more than twenty-four (24) hours, after receiving any information that
Contracting Party’s or any of its subcontractor’s DIR registration status has
been suspended, revoked, expired, or otherwise changed. It is understood
that it is the responsibility of Contracting Party to determine the correct
salary scale. Contracting Party shall make copies of the prevailing rates of
per diem wages for each craft, classification, or type of worker needed to
execute the Services available to interested parties upon request and shall
post copies at Contracting Party’s principal place of business and at the
project site, if any. The statutory penalties for failure to pay prevailing wage
or to comply with State wage and hour laws will be enforced. Contracting
Party must forfeit to City TWENTY-FIVE DOLLARS ($25.00) per day for each
worker who works in excess of the minimum working hours when
Contracting Party does not pay overtime. In accordance with the provisions
of Labor Code Sections 1810 et seq., eight (8) hours is the legal working
day. Contracting Party also shall comply with State law requirements to
maintain payroll records and shall provide for certified records and
inspection of records as required by California Labor Code Section 1770 et
seq., including Section 1776. In addition to the other indemnities provided
under this Agreement, Contracting Party shall defend (with counsel selected
by City), indemnify, and hold City, its elected officials, officers, employees,
and agents free and harmless from any claim or liability arising out of any
failure or alleged failure to comply with the Prevailing Wage Laws. It is
agreed by the parties that, in connection with performance of the Services,
including, without limitation, any and all “Public works” (as defined by the
Prevailing Wage Laws), Contracting Party shall bear all risks of payment or
non-payment of prevailing wages under California law and/or the
implementation of Labor Code Section 1781, as the same may be amended
from time to time, and/or any other similar law. Contracting Party
acknowledges and agrees that it shall be independently responsible for
reviewing the applicable laws and regulations and effectuating compliance
with such laws. Contracting Party shall require the same of all
subcontractors.
2. City is responsible for removal, relocation, or protection of
existing main or trunkline utilities to the extent s uch utilities were not
identified in the invitation for bids or specifications. City shall reimburse
Contracting Party for any costs incurred in locating, repairing damage not
caused by Contracting Party, and removing or relocating such unidentified
utility facilities. Contracting Party shall not be assessed liquidated damages
for delay arising from the removal or relocation of such unidentified utility
facilities.
3. Trenches or Excavations. Pursuant to California Public Contract
Code Section 7104, in the event the work included in this Agreement
requires excavations more than four (4) feet in depth, the following shall
apply:
(a) Contracting Party shall promptly, and before the following
conditions are disturbed, notify City, in writing, of any: (1) material that
Contracting Party believes may be material that is hazardous waste, as
defined in Section 25117 of the Health and Safety Code, that is required to
be removed to a Class I, Class II, or Class III disposal site in accordance
with provisions of existing law; (2) subsurface or latent physical conditions
at the site different from those indicated by information about the site made
available to bidders prior to the deadline for submitting bids; or (3) unknown
physical conditions at the site of any unusual na ture, different materially
from those ordinarily encountered and generally recognized as inherent in
work of the character provided for in the Agreement.
(b) City shall promptly investigate the conditions, and if it
finds that the conditions do materially so differ, or do involve hazardous
waste, and cause a decrease or increase in Contracting Party’s cost of, or
the time required for, performance of any part of the work shall issue a
change order per Section 1.8 of the Agreement.
(c) in the event that a dispute arises between City and
Contracting Party whether the conditions materially differ, or involve
hazardous waste, or cause a decrease or increase in Contracting Party’s cost
of, or time required for, performance of any part of the work, Contracting
Party shall not be excused from any scheduled completion date provided for
by this Agreement, but shall proceed with all work to be performed under
this Agreement. Contracting Party shall retain any and all rights provided
either by contract or by law which pertain to the resolution of disputes and
protests between the contracting Parties.
4. Safety. Contracting Party shall execute and maintain its work so
as to avoid injury or damage to any person or property. In carrying out the
Services, Contracting Party shall at all times be in compliance with all
applicable local, state, and federal laws, rules and regulations, and shall
exercise all necessary precautions for the safety of employees appropriate to
the nature of the work and the conditions under which the work is to be
performed. Safety precautions as applicable shall include, but shall not be
limited to: (A) adequate life protection and lifesaving equipment and
procedures; (B) instructions in accident prevention for all employees and
subcontractors, such as safe walkways, scaffolds, fall protection ladders,
bridges, gang planks, confined space procedures, trenching and shoring,
equipment and other safety devices, equipment and wearing apparel as are
necessary or lawfully required to prevent accidents or injuries; and
(C) adequate facilities for the proper inspection and maintenance of all
safety measures.
5. Liquidated Damages. Since the determination of actual damages
for any delay in performance of the Agreement would be extremely difficult
or impractical to determine in the event of a breach of this Agreement,
Contracting Party shall be liable for and shall pay to City the sum of One
Thousand dollars ($1,000.00) as liquidated damages for each working day of
delay in the performance of any of the Services required hereunder, as
specified in the Schedule of Performance. In addition, liquidated damages
may be assessed for failure to comply with the emergency call out
requirements, if any, described in the Scope of Services. City may withhold
from any moneys payable on account of the Services performed by
Contracting Party any accrued liquidated damages.
Exhibit B
Schedule of Compensation
With the exception of compensation for Additional Services, provided for
in Section 2.3 of this Agreement, the maximum total compensation to be
paid to Contracting Party under this Agreement is
_______________________________($_____________) (“Contract Sum”).
The Contract Sum shall be paid to Contracting Party in one lump sum on
completion of the work tasks performed and properly invoiced by
Contracting Party in conformance with Section 2.2 of this Agreement.
Exhibit C
Schedule of Performance
Contracting Party shall complete all services identified in the Scope of
Services, Exhibit A of this Agreement, in accordance with the Project
Schedule below:
Expected Project Start Date: November 26, 2018
Project Completion Date: On or before, December 20, 2018
Exhibit D
Special Requirements
Contractor shall possess a valid Class A (General Contractor) or a
combination of C21 (Demolition) C29 (Masonry Contractor) C12 (Grading) at
the time the bid is submitted.
Exhibit E
Insurance Requirements
E.1 Insurance. Prior to the beginning of and throughout the duration
of this Agreement, the following policies shall be maintained and kept in full
force and effect providing insurance with minimum limits as indicated below
and issued by insurers with A.M. Best ratings of no less than A-VI:
Commercial General Liability (at least as broad as ISO CG 0001)
$1,000,000 (per occurrence)
$2,000,000 (general aggregate)
Must include the following endorsements:
General Liability Additional Insured
General Liability Primary and Non-contributory
Commercial Auto Liability (at least as broad as ISO CA 0001)
$1,000,000 (per accident)
Personal Auto Declaration Page if applicable
Workers’ Compensation
(per statutory requirements)
Must include the following endorsements:
Workers Compensation with Waiver of Subrogation
Workers Compensation Declaration of Sole Proprietor if
applicable
Contracting Party shall procure and maintain, at its cost, and
submit concurrently with its execution of this Agreement, Commercial
General Liability insurance against all claims for injuries against persons or
damages to property resulting from Contracting Party’s acts or omissions
rising out of or related to Contracting Party’s performance under this
Agreement. The insurance policy shall contain a severability of interest
clause providing that the coverage shall be primary for losses arising out of
Contracting Party’s performance hereunder and neither City nor its insurers
shall be required to contribute to any such loss. An endorsement evidencing
the foregoing and naming the City and its officers and employees as
additional insured (on the Commercial General Liability policy only) must be
submitted concurrently with the execution of this Agreement and approved
by City prior to commencement of the services hereunder.
Contracting Party shall carry automobile liability insurance of
$1,000,000 per accident against all claims for injuries against persons or
damages to property arising out of the use of any automobile by Contracting
Party, its officers, any person directly or indirectly employed by Contracting
Party, any subcontractor or agent, or anyone for whose acts any of them
may be liable, arising directly or indirectly out of or related to Contracting
Party’s performance under this Agreement. If Contracting Party or
Contracting Party’s employees will use personal autos in any way on this
project, Contracting Party shall provide evidence of personal auto liability
coverage for each such person. The term “automobile” includes, but is not
limited to, a land motor vehicle, trailer or semi-trailer designed for travel on
public roads. The automobile insurance policy shall contain a severability of
interest clause providing that coverage shall be primary for losses arising out
of Contracting Party’s performance hereunder and neither City nor its
insurers shall be required to contribute to such loss.
Professional Liability or Errors and Omissions Insurance as
appropriate shall be written on a policy form coverage specifically designed
to protect against acts, errors or omissions of the Contracting Party and
“Covered Professional Services” as designated in the policy must specifically
include work performed under this agreement. The policy limit shall be no
less than $1,000,000 per claim and in the aggregate. The policy must “pay
on behalf of” the insured and must include a provision establishing the
insurer’s duty to defend. The policy retroactive date shall be on or before
the effective date of this agreement.
Contracting Party shall carry Workers’ Compensation Insurance in
accordance with State Worker’s Compensation laws with employer’s liability
limits no less than $1,000,000 per accident or disease.
Contracting Party shall provide written notice to City within ten
(10) working days if: (1) any of the required insurance policies is
terminated; (2) the limits of any of the required polices are reduced; or
(3) the deductible or self-insured retention is increased. In the event any of
said policies of insurance are cancelled, Contracting Party shall, prior to the
cancellation date, submit new evidence of insurance in conformance with
this Exhibit to the Contract Officer. The procuring of such insurance or the
delivery of policies or certificates evidencing the same shall not be construed
as a limitation of Contracting Party’s obligation to indemnify City, its officers,
employees, contractors, subcontractors, or agents.
E.2 Remedies. In addition to any other remedies City may have if
Contracting Party fails to provide or maintain any insurance policies or policy
endorsements to the extent and within the time herein require d, City may,
at its sole option:
a. Obtain such insurance and deduct and retain the amount of
the premiums for such insurance from any sums due under this Agreement.
b. Order Contracting Party to stop work under this Agreement
and/or withhold any payment(s) which become due to Contracting Party
hereunder until Contracting Party demonstrates compliance with the
requirements hereof.
c. Terminate this Agreement.
Exercise of any of the above remedies, however, is an alternative
to any other remedies City may have. The above remedies are not the
exclusive remedies for Contracting Party’s failure to maintain or secure
appropriate policies or endorsements. Nothing herein contained shall be
construed as limiting in any way the extent to which Contracting Party may
be held responsible for payments of damages to persons or property
resulting from Contracting Party’s or its subcontractors’ performance of work
under this Agreement.
E.3 General Conditions Pertaining to Provisions of Insurance Coverage
by Contracting Party. Contracting Party and City agree to the following with
respect to insurance provided by Contracting Party:
1. Contracting Party agrees to have its insurer endorse the third
party general liability coverage required herein to include as additional
insureds City, its officials, employees, and agents, using standard ISO
endorsement No. CG 2010 with an edition prior to 1992. Contracting Party
also agrees to require all contractors, and subcontractors to do likewise.
2. No liability insurance coverage provided to comply with this
Agreement shall prohibit Contracting Party, or Contracting Party’s
employees, or agents, from waiving the right of subrogation prior to a loss.
Contracting Party agrees to waive subrogation rights against City regardless
of the applicability of any insurance proceeds, and to require all contractors
and subcontractors to do likewise.
3. All insurance coverage and limits provided by Contracting Party
and available or applicable to this Agreement are intended to apply to the
full extent of the policies. Nothing contained in this Agreement or any other
agreement relating to City or its operations limits the application of such
insurance coverage.
4. None of the coverages required herein will be in compliance with
these requirements if they include any limiting endorsement of any kind that
has not been first submitted to City and approved of in writing.
5. No liability policy shall contain any provision or definition that
would serve to eliminate so-called “third party action over” claims, including
any exclusion for bodily injury to an employee of the insured or of any
contractor or subcontractor.
6. All coverage types and limits required are subject to approval,
modification and additional requirements by the City, as the need arises.
Contracting Party shall not make any reductions in scope of coverage (e.g.
elimination of contractual liability or reduction of discovery period) that may
affect City’s protection without City’s prior written consent.
7. Proof of compliance with these insurance requirements,
consisting of certificates of insurance evidencing all of the coverages
required and an additional insured endorsement to Contracting Party’s
general liability policy, shall be delivered to City at or prior to the execution
of this Agreement. In the event such proof of any insurance is not delivered
as required, or in the event such insurance is canceled at any time and no
replacement coverage is provided, City has the right, but not the duty, to
obtain any insurance it deems necessary to protect its interests under this or
any other agreement and to pay the premium. Any premium so paid by City
shall be charged to and promptly paid by Contracting Party or deducted from
sums due Contracting Party, at City option.
8. It is acknowledged by the parties of this agreement that all
insurance coverage required to be provided by Contracting Party or any
subcontractor, is intended to apply first and on a primary, non -contributing
basis in relation to any other insurance or self-insurance available to City.
9. Contracting Party agrees to ensure that subcontractors, and any
other party involved with the project that is brought onto or involved in the
project by Contracting Party, provide the same minimum insurance coverage
required of Contracting Party. Contracting Party agrees to monitor and
review all such coverage and assumes all responsibility for ensuring that
such coverage is provided in conformity with the requirements of this
section. Contracting Party agrees that upon request, all agreements with
subcontractors and others engaged in the project will be submitted to City
for review.
10. Contracting Party agrees not to self-insure or to use any self-
insured retentions or deductibles on any portion of the insurance required
herein (with the exception of professional liability coverage, if required) and
further agrees that it will not allow any contractor, subcontractor, Architect,
Engineer or other entity or person in any way involved in the performance of
work on the project contemplated by this agreement to self-insure its
obligations to City. If Contracting Party’s existing coverage includes a
deductible or self-insured retention, the deductible or self -insured retention
must be declared to the City. At that time the City shall review options with
the Contracting Party, which may include reduction or elimination of the
deductible or self-insured retention, substitution of other coverage, or other
solutions.
11. The City reserves the right at any time during the term of this
Agreement to change the amounts and types of insurance required by giving
the Contracting Party ninety (90) days advance written notice of such
change. If such change results in substantial additional cost to the
Contracting Party, the City will negotiate additional compensation
proportional to the increased benefit to City.
12. For purposes of applying insurance coverage only, this
Agreement will be deemed to have been executed immediately upon any
party hereto taking any steps that can be deemed to be in furtherance of or
towards performance of this Agreement.
13. Contracting Party acknowledges and agrees that any actual or
alleged failure on the part of City to inform Contracting Party of non -
compliance with any insurance requirement in no way imposes any
additional obligations on City nor does it waive any rights hereunder in this
or any other regard.
14. Contracting Party will renew the required coverage annually as
long as City, or its employees or agents face an exposure from operations of
any type pursuant to this agreement. This obligation applies whether or not
the agreement is canceled or terminated for any reason. Termination of this
obligation is not effective until City executes a written statement to that
effect.
15. Contracting Party shall provide proof that policies of insurance
required herein expiring during the term of this Agreement have been
renewed or replaced with other policies providing at least the same
coverage. Proof that such coverage has been ordered shall be submitted
prior to expiration. A coverage binder or letter from Contracting Party’s
insurance agent to this effect is acceptable. A certificate of insurance and an
additional insured endorsement is required in these specifications applicable
to the renewing or new coverage must be provided to City within five
(5) days of the expiration of coverages.
16. The provisions of any workers’ compensation or similar act will
not limit the obligations of Contracting Party under this agreement.
Contracting Party expressly agrees not to use any statutory immunity
defenses under such laws with respect to City, its employees, officials, and
agents.
17. Requirements of specific coverage features or limits contained in
this section are not intended as limitations on coverage, limits or other
requirements nor as a waiver of any coverage normally provided by any
given policy. Specific reference to a given coverage feature is for purposes
of clarification only as it pertains to a given issue, and is not intended by any
party or insured to be limiting or all-inclusive.
18. These insurance requirements are intended to be separate and
distinct from any other provision in this Agreement and are intended by the
parties here to be interpreted as such.
19. The requirements in this Exhibit supersede all other sections and
provisions of this Agreement to the extent that any other sec tion or
provision conflicts with or impairs the provisions of this Exhibit.
20. Contracting Party agrees to be responsible for ensuring that no
contract used by any party involved in any way with the project reserves the
right to charge City or Contracting Party for the cost of additional insurance
coverage required by this agreement. Any such provisions are to be deleted
with reference to City. It is not the intent of City to reimburse any third
party for the cost of complying with these requirements. There shall be no
recourse against City for payment of premiums or other amounts with
respect thereto.
21. Contracting Party agrees to provide immediate notice to City of
any claim or loss against Contracting Party arising out of the work performed
under this agreement. City assumes no obligation or liability by such notice
but has the right (but not the duty) to monitor the handling of any such
claim or claims if they are likely to involve City.
Exhibit F
Indemnification
F.1 Indemnity for the Benefit of City.
a. Indemnification for Professional Liability. When the law
establishes a professional standard of care for Contracting Party’s Services,
to the fullest extent permitted by law, Contracting Party shall indemnify,
protect, defend (with counsel selected by City), and hold harmless City and
any and all of its officials, employees, and agents (“Indemnified Parties”)
from and against any and all claims, losses, liabilities of every kind, nature,
and description, damages, injury (including, without limitation, injury to or
death of an employee of Contracting Party or of any subcontractor), costs
and expenses of any kind, whether actual, alleged or threatened, including,
without limitation, incidental and consequential damages, court costs,
attorneys’ fees, litigation expenses, and fees of expert consultants or expert
witnesses incurred in connection therewith and costs of investigation, to the
extent same are caused in whole or in part by any negligent or wrongful act,
error or omission of Contracting Party, its officers, agents, employees or
subcontractors (or any entity or individual that Contracting Party shall bear
the legal liability thereof) in the performance of professional services under
this agreement. With respect to the design of public improvements, the
Contracting Party shall not be liable for any injuries or property damage
resulting from the reuse of the design at a location other than that specified
in Exhibit A without the written consent of the Contracting Party.
b. Indemnification for Other Than Professional Liability. Other
than in the performance of professional services and to the full extent
permitted by law, Contracting Party shall indemnify, defend (with counsel
selected by City), and hold harmless the Indemnified Parties from and
against any liability (including liability for claims, suits, actions, arbitration
proceedings, administrative proceedings, regulatory proceedings, losses,
expenses or costs of any kind, whether actual, alleged or threatened,
including, without limitation, incidental and consequential damages, court
costs, attorneys’ fees, litigation expenses, and fees of expert consultants or
expert witnesses) incurred in connection therewith and costs of
investigation, where the same arise out of, are a consequence of, or are in
any way attributable to, in whole or in part, the performance of this
Agreement by Contracting Party or by any individual or entity for which
Contracting Party is legally liable, including but not limited to officers,
agents, employees, or subcontractors of Contracting Party.
c. Indemnity Provisions for Contracts Related to Construction
(Limitation on Indemnity). Without affecting the rights of City under any
provision of this agreement, Contracting Party shall not be required to
indemnify and hold harmless City for liability attributable to the active
negligence of City, provided such active negligence is determined by
agreement between the parties or by the findings of a court of competent
jurisdiction. In instances where City is shown to have been actively
negligent and where City’s active negligence accounts for only a percentage
of the liability involved, the obligation of Contracting Party will be for that
entire portion or percentage of liability not attributable to the active
negligence of City.
d. Indemnification Provision for Design Professionals.
1. Applicability of this Section F.1(d). Notwithstanding
Section F.1(a) hereinabove, the following indemnification provision shall
apply to a Contracting Party who constitutes a “design professional” as the
term is defined in paragraph 3 below.
2. Scope of Indemnification. When the law establishes a
professional standard of care for Contracting Party’s Services, to the fullest
extent permitted by law, Contracting Party shall indemnify and hold
harmless City and any and all of its officials, employees, and agents
(“Indemnified Parties”) from and against any and all losses, liabilities of
every kind, nature, and description, damages, injury (including, without
limitation, injury to or death of an employee of C ontracting Party or of any
subcontractor), costs and expenses, including, without limitation, incidental
and consequential damages, court costs, reimbursement of attorneys’ fees,
litigation expenses, and fees of expert consultants or expert witnesses
incurred in connection therewith and costs of investigation, to the extent
same are caused by any negligent or wrongful act, error or omission of
Contracting Party, its officers, agents, employees or subcontractors (or any
entity or individual that Contracting Party shall bear the legal liability
thereof) in the performance of professional services under this agreement.
With respect to the design of public improvements, the Contracting Party
shall not be liable for any injuries or property damage resulting from the
reuse of the design at a location other than that specified in Exhibit A
without the written consent of the Contracting Party.
3. Design Professional Defined. As used in this
Section F.1(d), the term “design professional” shall be limited to licensed
architects, registered professional engineers, licensed professional land
surveyors and landscape architects, all as defined under current law, and as
may be amended from time to time by Civil Code § 2782.8.
F.2 Obligation to Secure Indemnification Provisions. Contracting
Party agrees to obtain executed indemnity agreements with provisions
identical to those set forth herein this Exhibit F, as applicable to the
Contracting Party, from each and every subcontractor or any other person or
entity involved by, for, with or on behalf of Contracting Party in the
performance of this Agreement. In the event Contracting Party fails to
obtain such indemnity obligations from others as required herein,
Contracting Party agrees to be fully responsible according to the terms of
this Exhibit. Failure of City to monitor compliance with these requirements
imposes no additional obligations on City and will in no way act as a waiver
of any rights hereunder. These obligations to indemnify and defend City as
set forth in this Agreement are binding on the successors, assigns or heirs of
Contracting Party and shall survive the termination of this Agreement.