BRER2019-011778-495 CALLE TAMPICO Td4t D Ill QaWL
LA QUINTA, CALIFORNIA 92253 DESIGN & DEVELOPMENT DEPARTMENT
BUILDING PERMIT
Permit Type/Subtype: RE -ROOF/
Application Number: BRER2019-0117
Property Address: 77025 AVENIDA FERNANDO
APN: 658240039
Application Description: WINBIGLER /NEW POLYURETHANE ROOF.
Property Zoning:
Application Valuation: $18,505.00
Applicant: FJUN
Z
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q 0 5 20,9 DD
PALMDALE, CA 93550
CITY OF LA QUINTA
DESIGN & DEVELOPMENT DEPARTMENT
VOICE (760) 777-7125
FAX (760) 777-7011
INSPECTIONS (760) 777-7153
Owner:
SUSAN WINBIGLER
P 0 BOX 8766
RANCHO SANTA FE, CA 92253
Contractor:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
(661)273-1336
Llc. No.: 235717
Date: 6/5/2019
LICENSED CONTRACTOR'S DECLARATION WORKER'S COMPENSATION DECLARATION
I hereby affirm under penalty of perjury that I am licensed under provisions of Chapter I hereby affirm under penalty of perjury one of the following declarations:
9 (commencing with Section 7000) of Division 3 of the Business and Professions Code, I have and will maintain a certificate of consent to self -insure for workers'
and my License is in full force and effect. compensation, as provided for by Section 3700 of the Labor Code, for the performance
License Class: B, C39 License No.: 23571 of th o k for which this permit is issued.
t have and will maintain workers' compensation insurance, as required by
Date: Contractor: Section�M of the Labor Code, for the performance of the work for which this permit
is issued. My workers' compensation insurance carrier and policy number are:
OWNER-BU CLARATION Carrier: ARCH INSURANgE COMPANY Policy Number: ZAWC19401702
I hereby affirm under penalty of perju that I am exempt from the Contractor's State I certify that in the performance of the work for which this permit is issued, I
License Law for the following reason (Sec. 7031.5, Business and Professions Code: Any shall not employ any person in any manner so as to become subject to the workers'
City or county that requlres a permit to construct, alter, improve, demolish, or repair compensation laws of California, and agree that, if I should become subject to the
any structure, prior to its issuance, also requires the applicant for the permit to file a workers' compensation provisions of Section 3700 of the Labor Code, I shall forthwith
signed statement that he or she is licensed pursuant to the provisions of the comply with those provisions.
Contractor's State License Law (Chapter 9 (commencing with Section 7000) of Division
3 of the Business and Professions Code) or that he or she is exempt therefrom and the �S
_
basis For the alleged exemption. Any violation of Section 7031.5 by any appNcant :
for a
Date: Applicant
permit subjects the applicant to a civil penalty of not more than five hundred dollars WARNING: FAILURE TO SECURE WORKS �OMFSATIOW COVERAGE IS UNLAWFUL,
($5�) ' AND SHALL SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO
(_) I, as owner of the property, or my employees with wages as their sole ONE HUNDRED THOUSAND DOLLARS ($100,000). IN ADDITION TO THE COST OF
Compensation, wilt do. the work, and the structure Is not intended or offered for sale, COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE,
(Sec. 7044, Business and Professions Code: The Contractors' State License Law does not INTEREST, AND ATTORNEYS FEES.
apply to an owner of propertywho builds or improves thereon, and who does the work
himself or herself through his or her own employees, provided that the improvements APPLICANT ACKNOWLEDGEMENT
are not intended or offered for sale. If, however, the building or improvement is sold IMPORTANT: Application is hereby made to the Building Official for a permit subject to
within one year of completion, the owner-bu)lder will have the burden of proving that the conditions and restrictions set forth on this application.
he or she did not build or improve for the purpose of sale.). 1. Each person upon whose.behaif this application is made, each person at whose
(_) I, as owner of the property, am exclusively contracting with licensed contractors request and for whose benefit work is performed under or pursuant to any permit
to construct the project. (Sec. 7044, Business and Professions Code: The Contractors' issued as a result of this application , the owner, and the applicant, each agrees to, and
State License Law does not apply to an owner of property who builds or improves shall defend, indemn]fy and hold harmless the City of La Quinta, Its officers, agents, and
thereon, and who contracts for the projects with a contractor(s) licensed pursuant to employees for any act or omission related to the work being performed under or
the Contractors' State License Law.). following Issuance of this permit.
(_) I am exempt under Sec. B.&P.C. for this reason 2 An ermit iss d I f
Date: Owner
CONSTRUCTION LENDING AGENCY
I hereby affirm under penalty of perjury that there is a construction lending agency for
the performance of the work for•which this permit is issued (Sec. 3097, Civ. C.).
Lender's Name:
Lender's Address:
y p Lie as a resu t o this application becomes null and void if work is
not commenced within 180 days from date of issuance of such permit, or cessation of
work for 180 days will subject permit to cancellation.
certify that I have read this application and state that the above information is correct.
I agree to comply with all city and county ordinances and state laws relating to building
:onstruction, and hereby authorize representatives of this city to enter upon the
above -mentioned property for inspection purposes.
)ate: J�_-Signature (Applicant or Agent
Date: 6/5/2019
Application Number:
BRER2019-0117
Property Address:
77025 AVENIDA FERNANDO
APN:
658240039
Application Description:
WINBIGLER/ NEW POLYURETHANE ROOF.
Property Zoning:
Application Valuation:
$18,505.00
Applicant:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALM DALE, CA 93550
Owner:
SUSAN WINBIGLER
P 0 BOX 8766
RANCHO SANTA FE, CA 92253
Contractor:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
(661)273-1336
Llc. No.: 235717
------------------------------ - - - - -- -- ----------------------------------------------------
Detail: REMOVE EXIXITING GRAVEL AND REFOOF WITH POLTUk.ETHANE'FOAM AND* ACRYLIC COATING. 2016 CALIFORNIA ENERGY CODE.
l If�r1"�It
Total Paid for BUILDING STANDARDS ADMINISTRATION BSA: $1.00
DESCRIPTION
ACCOUNT
CITY
AMOUNT
RE -ROOF - EA ADDITIONAL 1,000 SF
101-0000-42404
0
$25.62
DESCRIPTION
ACCOUNT
CITY
AMOUNT
RE -ROOF - FIRST 2,000 SF
101-0000-42404
0
$54.43
DESCRIPTION
ACCOUNT
CITY
AMOUNT
RE -ROOF - FIRST 2,000 SF PC
101-0000-42600
0
$108.87
Total Paid for RE -ROOF: $188.92
DESCRIPTION
ACCOUNT
CITY
AMOUNT
TECHNOLOGY ENHANCEMENT FEE
502-0000-43611
0
$5.00
Total Paid for TECHNOLOGY ENHANCEMENT FEE: $5.00
TOTALS:•4 .92
tea
Qwfra
PERMIT#GF.M ofd,, DMERT —
PLAN LOCATION:
Project Address: %0aS',1q-l/£-vt-£irtiRNO, Project Description: Pool, Remodel, Add't, Elect, Plumb, Mech
APN
. ^J51-4 L' t- n' � L J Pv L v ICE 4-1-#-,f l
Applicant Name:
Address:
M
City, ST, Zip:
Telephone:
Email: Valuation of Project
Property Owner's Name: -CU SAS bpi I " J 15JQSK New Commercial / Tenant Improvements:
Address: P(�, �O�( �� 6 Total Building Vv0 SF
City, ST, Zip �q �JGI?ip S pcv fA- �£ �,06 Construction Type: Occupancy:
Telephone: 4 63 - q ''[ Q �� �o F
Email: /`
78495 CALLE TAMPICO
LA QUINTA, CA 92253
760-777-7000
OFFICE USE ONLY
STATE OF CALIFORNIA
Prescriptive Residential Alterations That Do Not Require HERS Field Verification
CEC-CP1R-ALT-05-E (Revised 04115
CERTIFICATE OF COMPLIANCE
Prescriptive Residential
1Alterations
j�That Do Not Require HERS Field Verification -A470/ -
"QJCCI Name: W f
This compliance document is only ai
with a HERS Provider Data Registry.
ro simpie alterations tryat do not require HERS verification for
RGY COMMISSION
CF1R-ALT-05-E
Page 1 of 3
wnen HtRS verification is required, a CF1R-ALT- 01 shall
Alterations to Space Conditioning Systems shot are exempt from HERS verificotion requirements may use the CF1R-ALT-05 and CF2R- ALT-05 Compliance Documents. Possible exemptions from duct
leakage testing include: less than 40 ft of ducts were added or replaced, • or the existing duct system was insulated with asbestos; or the existing duc¢ system was previously tested and passed by a
HERS Rater. If space conditioning systems are altered and are not exempt from HERS verification, then a CF1R-AL T•02 must be completed and registered with a HERS Provider Data Registry.
Alterations that utilize close Cell Spray Polyurethane Foam (ccSPF) with a density of 1.5 to less than 2.5 pounds per cubic foot having an R-value other than 5.8 per inch, or Open Cell Spray
Polyurethane Foam (ocSPF) with a density of 0.4 to less than 1.S pounds per cubic foot having an R-value of 3.5per inch, shall complete and register a CF1R-ALT»01 with a HERS Provider Data
Registry.
If more than one person has responsibility for installation of the items on this certificate, each person shall prepare and sign a certificate applicable to the portion of construction for which they are
responsible. Alternatively, the person with chief responsibility for construction shall prepare and sign this certificate for the entire construction. All applicable Mandatory Measures shall be met.
Temporary labels shall not be removed before verification by the building inspector.
A. c,eneral Information
i
01 Project Name: �t /�J 13
03 Project Location: Oc'� �] {'' �1 ` } N I u �•� �,� �/V r
05 CA City:
07 Zip Code:
09 1 Climate Zone:
11 1 Building Type:
13 Project Scope (Select all that apply):
`,/ I' A C/9
02 Date Prepared: S �C?
04 Building Front Orientation (deg or cardinal):
06 Number of Altered Dwelling Units:
08 Fuel Type:
10 Total Conditioned Floor Area (ft):
12 Slab Area (ft)
❑ B. Insulation ❑ D. & E. Fenestration/Glazing - ADD ❑ G. Space Conditioning System (Heating, Cooling, Duct system) ❑ Lighting
❑✓ C. Roof Replacement ❑ D. & F. Fenestration/Glazing - REPLACE ❑ H. water Heating System ❑ Include Mandatory Measures?
CA Building Energy Efficiency Standards - 2016 Residential Compliance
April 2016
STATE OF CALIFORNIA
Prescriptive Residential Alterations That Do Not Require HERS Field Verification
CEC-CF1 R-ALT-05-E (Revised 04/16)
CERTIFICATE OF COMPLIANCE
Prescriptive Residential Alterations That
^7D[o' Not Require HERS Field Verification
Prpj4n iJime; . _ 1' j L Y£ It +�+ S 1 Y G d C 4 0V
C. Roof Replacement (Prescriptive Alteration, Section 150.2(b)1H)
CF 1R-ALT-05-E
Page 2 of 3
01 02 03 04 05 06 07 08 09 10 11 12 13
Proposed Minimum Required
R-value
Method of CRRC Product Product Deck Initial Solar Aged Solar Thermal SRI Aged Solar Thermal SR(
Compliance Roof Pitch Exception ID Number Type Insulation Reflectance Reflectance Emittance (Optional) Reflectance Emittance (Option
Add -Row Delete ft+suv
NOTES:
• Roof area covered by building integrated photovoltaic panels and solar thermal panels are exempt from the above Cool Roof requirements.
• Liquid field applied coatings must comply with installation criteria from Section 110.8(i)4.
April 2016
CA-$uh6ng Energy Efficiency Standards - 2016 Residential Compliance
SALIFORNIA
Prescriptive Residential Alterations That Do Not Require HERS Field Verification
EC-CFIR-ALT-05-E (Revised 04116) CALIFORNIA ENERGY COMMISSION
CERTIFICATE OF COMPLIANCE CFIR-ALT-05-E
Prescriptive Residential Alterations That Do Not Require HERS Field Verification Page 3 of 3
project Name- t N CA R £ G G £ C /J�.a r Dau Arewred�
l [i �W ..r
r
DOCUMENTATION AUTHOR'S DECLARATION STATEMENT
I. I certify that this Certificate of Compliance documentation is accurate and complete.
D"timenwi n A thor Flame: Documentat uth
1 FIZ
Company
5jgna e:
1)0 1, s,—f !Z PAr- / rr c &0 r1 "'110—
3 [� I A- CAM PAAY,4- w/+_-..,.._-.....��...... .o ., -.,r.,.a.'.
=ily/Sta a/£p:
Phone:
�-, ,s-9
RESPONSIBLE PERSON'S DECLARATION STATEMENT
I certify the following under penalty of perjury, under the laws of the State of California,
1. The information provided on this Certificate of Compliance is true and correct.
2. 1 am eligible under Division 3 of the Business and Professions Code to accept responsibility for the building design or system design identified on this Certificate of Compliance (responsible
designer).
3. That the energy features and performance specifications, materials, components, and manufactured devices for the building design or system design identified on this Certificate of
Compliance conform to the requirements of Title 24, Part 1 and Part 6 of the California Code of Regulations.
4. The building design features or system design features identified on this Certificate of Comp once are consistent with -the information provided on other applicable compliance documents,
worksheets, calculations, plans and specifications submitted to the enforcement agency for approval with this building permit application.
5. 1 will ensure that a registered copy of this Certificate of Compliance shall be made available with the building permit(s) issued for the building, and made available to the enforcement agency
for all applicable inspections. I understand that a registered copy of this Certificate of Compliance is required to be included with the documentation the builder provides to the building
owner at occuoancv- ■
Name: el— /L %L
Responsible Designer Signature;
For assistance or questions regarding the Energy Standards, contact the Energy Hotline at: 1-800-772-3300.
CA Building Energy Efficiency Standards - 2016 Residential Compliance
April 2016
WESTERN VA- IFIC'
�� . ltoojFr,w Corporutiore
siw l)49
May 15, 2019
Mrs. Susan Winbigler
PO BOX 8766
Rancho Santa Fe, CA 92067
Subject: Proposal for New Roof System
77025 Avenida Fernando, La Qunita, CA 92253
Dear Mrs. Winbigler:
Thank you for the opportunity to submit a proposal for the roofing at the above referenced property.
We are pleased to submit our proposal for the work as described below. The scope of work and
associated costs are as follows:
GENERAL
This proposal and contract is made between Western Pacific Roofing Corp. (Contractor) and the
person (s) or entity named above (Owner or Owner's Agent). Unless expressly stated to the
contrary, the contractor shall be responsible for performing the following:
DESCRIPTION
A. The general conditions of this standard construction contract shall form a part of these
specifications with the same force and effort as though repeated herein.
B. The Contractor shall furnish all labor, materials, equipment, permits, contractor's licenses
and insurance certifications to perform all operations required as specified. The contractor
shall provide labor and material customarily included in work of the same nature to give a
quality, complete job.
C. If any unforeseen or unexpected conditions are encountered during the work, and the
conditions adversely affect the cost or progress of the work, the contractor will notify the
owner immediately, and the owner will negotiate a written change -order to resolve the
unexpected condition be it for an increase or decrease to the contract amount.
D. The Contractor shall occupy, use, and permit others to use the premises only for the purpose
of completing the work to be performed under this contract with the Owner. Contractor is to
be given all reasonable set-up and staging areas. Due to the limited access, some driveways
or parking areas may be blocked during this construction process.
E. Contractor's scope of work shall not include the identification, detection, abatement,
3462 La Campana Way • Palm Springs, CA 92262 • (760) 416-5877 • Fax (760) 320-8912
www.westpacroof.com • Contractors License No. 235717 • E-mail: wprcps@westpacroof.com
New Roof System
May 15, 2019
Page 2 of 5
encapsulation or removal of asbestos or similar hazardous substances including mold,
mildew and infestation of rodents. If Contractor encounters any such products, materials or
conditions in the course of performing its work, or if such hazardous materials are
encountered by any other firm performing work at the jobsite and contractor determines that
such materials present a hazard to its employees, contractor shall have the right to
discontinue its work and remove its employees from the jobsite until such products or
materials, and any hazards connected therewith, are located and abated, encapsulated or
removed, or it is determined that no hazard exists (as the case may require), and contractor
shall receive an extension of time to complete its work hereunder and compensation for
delays encountered as a result of such situation and correction. Due to the possibility of
mold, mildew and rodents being present before, during or after our work, Contractor's
scope of work shall not include the identification, detection or the removal of mold, mildew
and rodents. Contractor shall not be responsible for entrapment of rodents during roofing or
attempt by Contractor at order of association or homeowner to keep rodents out of unit.
Owner agrees to hold Contractor harmless, and shall indemnify Contractor harmless for any
mold or rodent related claims in the future.
F. If a dispute shall arise between Contractor and Owner with respect to any matters or
questions arising out of or relating to this contract or the breach thereof, such dispute
shall be decided by arbitration administered by and in accordance with the Construction
Industry Arbitration Rules of the American Arbitration Association or through such
arbitration procedures as the parties may agree. This contract shall be specifically
enforceable under the prevailing arbitration law. The award rendered by the arbitrators
shall be final, and judgment may be entered upon it in any Court having jurisdiction
thereof.
G. Should suit be brought to enforce or interpret any part of this Agreement, the "prevailing
party" shall be entitled to recover, as an element of costs of suit and not as damages,
reasonable attorneys' fees to be fixed by the Court. The "prevailing party" shall be entitled
to recover its costs of suit, regardless of whether such suit proceeds to final judgment.
H. INSURANCE: Western Pacific Roofing Corp. shall secure, pay the premium for and
keep in force until expiration of this Agreement, worker's compensation insurance, as
well as general liability and property damage insurance, with limits not less than one
million dollars ($1,000,000.00) per person, two million dollars ($2,000,000.00) per
occurrence, and excess liability coverage totaling ten million dollars ($10,000,000)
aggregate.
WL5TFFLN PACMC
k..�1� r.o�wwne
New Roof System
May 15, 2019
Page 3 of 5
SCOPE OF WORK
SURFACE PREPARATION
A. Loose gravel to be removed by vacuuming.
B. Damaged plywood sheathing will be replaced at a rate of $65.00 per sheet or portion
thereof and billed separately as a change -order.
C. Prime the prepared roof area with black primer.
D. Installed new perimeter edge metal. (Unpainted)
APPLICATION OF POLYURETHANE FOAM AND COATING
A. Urethane insulation shall be spray -applied to a minimal thickness of 1" (plus or minus
'/4"). Only 3 lb. density foam will be used in this application. Additional foam will be
added to the low areas to help minimize ponding. Some ponding will remain.
B. Coating shall be applied in a minimum of two separate coats.
1. The base coat shall be applied at a rate of 1.50 gallons per 100 square feet.
2. The top coat shall be applied at a rate of 1.50 gallons per 100 square feet, yielding
a total system thickness for all coats of 22-24 TOTAL DRY MILS. Top coat color
to be white.
3. Embed ceramic granules in the wet top coat material at a rate of 50 pounds per
100 square feet.
4. All foam is to be coated. Coating shall extend up and over all foamed vent pipes
and terminated a minimum of 2" above the foam, creating a neat appearance, self -
terminating flashing.
NOTE #1: Replace 2 large and 1 small AC Pans. Replace (7) 2" drain couplings at seven drains.
CONTRACT AMOUNT
Eighteen Thousand Five Hundred Five Dollars
$18,505.00
EXCLUSIONS
No items will be supplied nor work performed that is not specifically stated herein.
PAYMENT TERMS
A 10% or $1000.00 deposit, whichever is less, is due with the signed contract. Invoices to be paid
with 10 days of receipt. No retention to be held. Any remaining balance due following completion
to be paid within 15 days of receipt of the invoice.
WARRANTY
WESTERN PACC
RnM7.V ['wr.w4.tl
New Roof System
May 15, 2019
Page 4 of 5
A five (5) year labor and material warranty will be issued by Western Pacific Roofing upon
completion of the roof and final payment is received. Contractor's work will be warranted by
Contractor in accordance with its standard warranty, which is made a part of this proposal and
contract and incorporated by reference. A copy of the Contractor's standard warranty is attached
or, if not, will be furnished upon request. Contractor SHALL NOT BE LIABLE FOR SPECIAL,
INCIDENTAL OR CONSEQUENTIAL DAMAGES. The acceptance of this proposal by the
Customer signifies his agreement that this warranty shall be and is the exclusive remedy against
Contractor for all defects in workmanship furnished by Contractor.
The price quoted has been structured to reflect standards we assume are mutually desired: quality
installation, service reliability and long -term performance. The price may be subject to change 15
days from the date of this proposal.
If you are in accordance with the conditions herein, please execute the agLeement below
including the attached General Terms and Conditions and return both copies to this office. We
will, in turn, sign them and return one copy to you. Thank you for your cooperation in expediting
this contract for your roofing needs.
NOTICE TO OWNER
Contractors are required by law to be licensed and regulated by the Contractor's State
License Board. Any questions concerning a contract may be referred to the Registrar,
Contractor's State License Board, P.O. Box 26000, Sacramento, CA 95826 or call 1-800-321-
CSLB or www.CSLB.CA.GOVfor more information.
LAW REQUIRES ANYONE WHO CONTRACTS TO DO CONSTRUCTION WORK TO BE LICENSED BY
THE CONTRACTORS STATE LICENSE BOARD IN THE LICENSE CATEGORY IN WHICH THE
CONTRACTOR IS GOING TO BE WORKING IF THE TOTAL PRICE OF THE JOB IS $500 OR MORE
(INCLUDING LABOR AND MATERIALS).
"LICENSED CONTRACTORS ARE REGULATED BY LAWS DESIGNED TO PROTECT THE PUBLIC. IF
YOU CONTRACT WITH SOMEONE WHO DOES NOT HAVE A LICENSE, THE CONTRACTORS STATE
LICENSE BOARD MAY BE UNABLE TO ASSIST YOU WITH A COMPLAINT. YOUR ONLY REMEDY
AGAINST AN UNLICENSED CONTRACTOR MAY BE IN CIVIL COURT, AND YOU MAY BE LIABLE
FOR DAMAGES ARISING OUT OF ANY INJURIES TO THE CONTRACTOR OR HIS OR HER
EMPLOYEES.
"YOU MAY CONTACT THE CONTRACTORS STATE LICENSE BOARD TO FIND OUT IF THIS
CONTRACTOR HAS A VALID LICENSE. THE BOARD HAS COMPLETE INFORMATION ON THE
HISTORY OF LICENSED CONTRACTORS, INCLUDING ANY POSSIBLE SUSPENSIONS,
REVOCATIONS, JUDGMENTS, AND CITATIONS. THE BOARD HAS OFFICES THROUGHOUT
CALIFORNIA. PLEASE CHECK THE GOVERNMENT PAGES OF THE WHITE PAGES FOR THE
OFFICE NEAREST YOU OR CALL 1-800-321-CSLB OR 2M-CSLB.CA.G I1 FOR MORE
INFORMATION."
ACKNOWLEDGMENT: Owner acknowledges that he/she has read and received a legible copy of
this agreement including all terms and standard provisions before any work is performed and that
A0rR\W_UrMN PACIFIC
N•whns ra+r•ri„M�
MAY--24-a019 e?158A FROM:
T0:17603ROegia F 1
Nlew Rool'Symetll
May K 2019
Pager 5 or 3
ACKNOWLEDGMENT. Owner acknnwledt cs that 110she has read and received H legible copy of
this agreement including all terms and standard provisions before any work is performed and that
helshe has read and received a legible Copy, of every other document that owner has signed during
thiq n%sotlation. llwe hereby acknowledge under the penany of perjury that Ilwe amlure the legal
owners and umlr,ere autherixed to sign this contract as an agent of the legal owner.
ACCEPTANCE: The above prices, specifications antl conditions are catisfartory and are hereby
accepted, You are authorimxi to 4o the work as specified. 1 AYI lent will he as outlined above. You,
the buyer MAY cancel this Iransaction at ally time prior to midnight of the third business day after the
dote 4W this transaction. Owner has the right to require contmetor to have a performance and
Payment bond at Owner's expense.
Mrs, Susan Winbigler
� .�
p�vner car (7wner'S Agent
Title otC
WESTERN PACIFIC ROOFING
COn"Oof i Llocust JO 2 357 17
Authnrix Ag t ¢ Mr.
I�
/4-�;
Title Dale —
WESTERN PACIFIC R(A)FIN0 ( )KP 11AS [HE It1G111 IU ItLSCIND IIUS LONIKALI WIMIN FIFTEEN DAYS OF AC EPTANCF
CHIS AOREWIENT 1S NO'r BINDING UNTII. Accr.•Prco BY THE OFFICE MANA(WMFNT AT 3E61 1 A CAMVANA WAY PAI M
SPRIN05. CA 92262 NO CHANGNS OR ADDrrI0N3 TO T1II$ AGRGEMF,NT SHALI, IJF. Fr1:I:CT1VE I.NI11, APPROVI�D NY WEST"f,RN
PACIFIC RO()rINGCORP MANAGL'MLNT
MANAI-ARS ACCGPTANCr DATE
cVtn'KR.V Pw(x'F'FC