BRER2019-017478-495 CALLE TAMPICO
LA QUINTA, CALIFORNIA 92253
Permit Type/Subtype:
Application Number:
Property Address:
APN:
Application Description:
Property Zoning:
Application Valuation:
Tit!t 4 a6P Qu'Kro
DESIGN & DEVELOPMENT DEPARTMENT
BUILDING PERMIT
RE -ROOF/
BRER2019-0174
76880 CALLE MAZATLAN
658161050
LQ TENNIS VILLAS / 1900SF REROOF EXISTING TILE
$8,834.00
Applicant: n
WESTERN PACIFIC ROOFING CORP V
2229 EAST AVENUE Q
PALMDALE, CA 93550
Q U
SEP 2 3 2019
CITY OF LA QUINTA
DESIGN & DEVELOPMENT DEPARTMENT
LICENSED CONTRACTOR'S DECLARATION
I hereby affirm under penalty of perjury that I am licensed under provisions of Chapter 9
(commencing with Section 70001 of Division 3 of the Business and Professions Code, and
my License is in full force and effect.
License Class: B. C39 License No.: 235717
Date: '�J—� Cantra[tor
OWNER- ECLARATION
I hereby affirm under penalty of perjury that I am exempt from the Contractor's State
License Law for the following reason (Sec. 7031.5, Business and Professions Code: Any
city or county that requires a permit to construct, alter, improve, demolish, or repair any
structure, prior to its issuance, also requires the applicant for the permit to file a signed
statement that he or she is licensed pursuant to the provisions of the Contractor's State
License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business
and Professions Code) or that he or she is exempt therefrom and the basis for the
alleged exemption. Any violation of Section 7031.5 by any applicant for a permit
subjects the applicant to a civil penalty of not more than five hundred dollars ($500).:
(_) I, as owner of the property, or my employees with wages as their sole
compensation, will do the work, and the structure is not intended or offered for sale.
(Sec. 7044, Business and Professions Code: The Contractors' State License Law does not
apply to an owner of property who builds or improves thereon, and who does the work
himself or herself through his or her own employees, provided that the improvements
are not intended or offered for sale. If, however, the building or improvement is sold
within one year of completion, the owner -builder will have the burden of proving that he
or she did not build or improve for the purpose of sale.).
(_) I, as owner of the property, am exclusively contracting with licensed contractors to
construct the project. (Sec. 7044, Business and Professions Code: The Contractors' State
License Law does not apply to an owner of property who builds or improves thereon,
and who contracts for the projects with a contractor(s) licensed pursuant to the
Contractors' State License Law.).
(_) I am exempt under Sec. B.&P.C. for this reason _
Date:
Owner:
CONSTRUCTION LENDING AGENCY
I hereby affirm under penalty of perjury that there is a construction lending agency for
the performance of the work for which this permit is issued (Sec. 3097, Civ. C.).
Lender's
Lender's Add
VOICE (760) 777-7125
FAX (760) 777-7011
INSPECTIONS (760) 777-7153
Date: 9/23/2019
Owner:
ARTHUR STERN
PO BOX 7425
SANTA MONICA, CA 90406
Contractor:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
(661)273-1336
Llc. No.: 235717
WORKER'S COMPENSATION DECLARATION
I hereby affirm under penalty of perjury one of the following declarations:
I have and will maintain a certificate of consent to self -insure for workers'
compensation, as providers for by Section 3700 of the Labor Code, for the performance
of the a or which this permit is issued.
1 have and will maintain workers' compensation insurance, as required by
Section 3700 of the Labor Code, for the performance of the work for which this permit is
issued. My workers' compensation insurance carrier and policy number are:
Carrier:COMPANY Policy Number: ZAWC19401702
I certify that in the performance of the work for which this permit is issued, I
shall not employ any person in any manner so as to become subject to the workers'
compensation laws of California, and agree that, if I should become subject to the
workers' compensation provisions of Section 3700 of the Labor Code, I shall forth
comply with those provisions.
Date: —,222 _/t Applicant:
WARNING: FAILURE TO SECURE WORKER ' MPE SATION COVERAGE IS UNLAWFUL,
AND SHALL SUBJECTAN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO
ONE HUNDRED THOUSAND DOLLARS ($100,000). IN ADDITION TO THE COST OF
COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE,
INTEREST, AND ATTORNEY'S FEES.
APPLICANT ACKNOWLEDGEMENT
IMPORTANT: Application is hereby made to the Building Official for a permit subject to
the conditions and restrictions set forth on this application.
1. Each person upon whose behalf this application is made, each person at whose
request and for whose benefit work is performed under or pursuant to any permit issued
as a result of this application , the owner, and the applicant, each agrees to, and shall
defend, indemnify and hold harmless the City of La Quinta, its officers, agents, and
employees for any act or omission related to the work being performed under or
following issuance of this permit.
2. Any permit issued as a result of this application becomes null and void if work is not
commenced within 180 days from date of issuance of such permit, or cessation of work
for 180 days will subject permit to cancellation.
I certify that I have read this application and state that the above information is correct.
I agree to comply with all city and county ordinances and state laws relating to building
construction, and hereby authorize representatives of this city to enter upon the above -
mentioned property for inspection purposes.
Dater Signature (Applicant or A
Date: 9/23/2019
Application Number: BRER2019-0174
Property Address: 76880 CALLE MAZATLAN
APN: 658161050
Application Description: LQ TENNIS VILLAS / 1900SF REROOF EXISTING TILE
Property Zoning:
Application Valuation: $8,834.00
Applicant:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
Owner:
ARTHUR STERN
PO BOX 7425
SANTA MONICA, CA 90406
Contractor:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
(661)273-1336
Llc. No.: 235717
Detail: REMOVE AND RESET ROOF TILES NEW 2 PLY 40# UNDERLAYMENT. PER 2016 CALIFORNIA BUILDING CODES
DESCRIPTION
ACCOUNT CITY
AMOUNT
BSAS SB1473 FEE
101-0000-20306 0
$1.00
Total Paid for
BUILDING STANDARDS ADMINISTRATION BSA:
$1.00
DESCRIPTION
ACCOUNT CITY
AMOUNT
RECORDS MANAGEMENT FEE
101-0000-42416 0
$10.00
Total Paid for RECORDS MANAGEMENT FEE:
$10.00
DESCRIPTION
ACCOUNT CITY
AMOUNT
RE -ROOF - FIRST 2,000SF
101-0000-42404 0
$54.74
DESCRIPTION
ACCOUNT CITY
AMOUNT
RE -ROOF - FIRST 2,000SF PC
101-0000-42600 0
$109.48
Total Paid for RE -ROOF 2019:
$164.22
DESCRIPTION
ACCOUNT
CITY
AMOUNT
TECHNOLOGY ENHANCEMENT FEE
502-0000-43611
0
$5.00
Total Paid for TECHNOLOGY ENHANCEMENT FEE:
$5.00
t1
a
Project Address:
APN #:
Applicant Name:
Address:
City, ST, Zip:
Telephone:
Email:
Contractor Name: Ul£$ rE12n/ Pq,G,f G A
Address: 3 `/6 a 1-4- c4mP wA
City, St, Zip PAZ�i -5 62T^ r
Telephone: 0- �1/6
Email: iLVPAG/OS W r aLl�J� LQ
State Lic: 3's City Bus Lic:
nIN('
Property Owner's Name:cj aLin L
Address: 0,0 - (� b -� 3
City, ST, Zip LikS ` -
Telephone. � a
Email:
rT # 13QR1 q., (?
Project Description:
VA) P 2 GA I'vi -ivsrf I(/,
77 G Fi
Valuation of Project $ d. 92 �1 1-90
New SFD Construction:
Conditioned Space SF
Garage SF
Patio/Porch SF
Fire Sprinklers SF
I u,R- QA
tft!- New Commercial / Tenant Improvements:
Total Building L190 SF
Construction Type: Occupancy:
&- /Z 0 o i-�
78495 CALLE TAMPICO
LA QUINTA, CA 92253
760-777-7000
OFFICE USE ONLY
# , Submittal 1, Required Received
Plan Sets
Structural Calcs
Truss Calcs
Title 24 Calcs
Soils Report
Grading Plan (PM10)
Landscape Plan
Subcontractor List
Grant Deed
HOA Approval
School Fees
Burrtec Debris Plan
Planning approval
Public Works approval
Fire approval
City Business License
�� PAS
�it�:0. r'•r=1
December 4, 2018
La Quinn Tennis Villas HOA
c/o ReiBELaage
Ate: Sandy Ivins
75178 CeLLald Ford Avenue Suite B-1
Palm Desert, CA 92" It
Subject. PIMPosal for New Tile Underlaym- ent Roof Syste;n
La Qliinta Tennis Villas (Various Addresses)
La Quinta, CA 922333
Dear iV1,s. Reins:
Thank you for the opportunity to submit a proposal for the roofing. at the above referenced property.
We are pleased to submit our proposal for the work as described below. The scope of work- and
associated costs are as follows:
GENERAL
This proposal and contract is made between Western pacific Roofing Corp. (Contractor) and the
person (s) or entity named above (Owner or Owner's Agent). Unless expressly stated to the
contrary, the contractor shall be responsible for performing the fallowing:
DESCRIPTION
A. The general conditions of this standard construction contract shall form a part of these
specifications with the same force and effort as though repeated herein-
B. The Contractor shall furnish all labor, materials, equipment, permits, contractor's lic'enses
and insurance certifications to perform all operations required as specified. The contractor
shall provide labor and material customarily included in work of the same nature to give a
quality, complete job.
C. If any unforeseen or unexpected conditions are encountered during the work, and the
conditions adversely affect the cost or progress of the work, the contractor will notify the
owner immediately, and the owner wilI negotiate a written change -order to resolve the
unexpected condition be it for an increase or decrease to the contract amount.
D. The Contractor shall occupy, use, and permit others to use the premises only for the purpose
of completing the work to be performed under this contract with the Owner. Contractor is to
3462 La Campana way • Palm Springs, CA 92262 • (760) 416-5377 • Fax (760) 320-8912
w"vw.westpacroof.com • Contractors License No. 235717 • E-mail: wprcps@westpacroof..com
New hoof System
November 6, 2018
Page 2 of i
be given all reasonable set-up and staging areas. Due to the limited access, some driveways
or Parking areas may be b[ock:d during this construction process.
E. Contractor's scope of wort shall not include the identification, detection, abatement,
encapsulation or removal of asbestos or similar hazardous substances including mold,
mildew and infestation of rodents. If Contractor encounters any such products, materials or
conditions in the course of perf'onning its work, or if such hazardous materials are
encountered by any otfher farm performing work at the jobsite and contractor determines that
such matenaU present a hazard to its employees, contractor shall have the right to
discontinue its work and remove its employees from the jobsite until such products or
materials, and any hazar4- connected therewith, are located and abated, encapsulated or
removed, or it is determined that no hazard exists (as the case may require), and contractor
shall receive an extension of time to complete its work hereunder and compensation for
delays encountered as a result of such situation and correction_ Due to the possibility of
mold, mildew and rodents being Present before, during or after our work. Contractor's
scope of worst shall not include the identification, detection or the removal of mold, mildew
and rodents. Contractor shall not be responsible for entrapment of rodents during roofing or
attempt by Contractor at order of association or homeowner to keep rodents out of unit.
Owner agrees to hold Contractor harmless, and shall indemrdfy Contractor harmless for anv
mold or rodent related claims in the fi Vure.
F. If a dispute shall arse between Contractor and Owner with respect to any matters or
questions arising out of or relating to this contract or t+he breach thereof, such dispute
shall be decided by arbitration administered by and in accordance with the Construction
Industry Arbitration Rules of the American Arbitration Association or through such
arbitration procedures as the parties may agree. This contract shall be specifically
enforceable under the prevailing arbitration law. The award rendered by the arbitrators
shall be final, and judgment may be entered upon it in any Court having jurisdiction
thereof.
G. Should suit be brought to enforce or interpret any part of this Agreement, the "prevailing
party" shall be entitled to recover, as an element of costs of suit and not as damages,
reasonable attorneys' fees to be fixed by the Court. The "prevailing party" shall be entitled
to recover its costs of suit, regardless of whether such suit proceeds to final judgment.
H. E SURk CE: Western Pacific Roofing Corp. shall secure, pay the premium for and
keep in force until expiration of this Agreement, worker's compensation insurance, as
well as general liability and property damage insurance, with limits not less than one
million dollars ($1,000,000.00) per person, two million dollars ($2,000,000.00) per
occurrence, and excess liability coverage totaling ten million dollars ($10,000,000)
aggregate.
New Roo System
November 6, 2018
Pave 3 of 5
SCOPE OF WORK
SURFACE PREPARATION
A. Remove the existing tile and set aside.
B. Damaged pinvood will be replaced at a rate of 565.00 per sheet or portion thereof and
billed separately as a change -order.
C. Reuse the existing perimeter metal and Bird Stop.
NSTALLATION OF NEW TILL UNDERi-,AYMENT
A. Install two lavers of r 40 the underla►ment me-4anically &stened.
B. Install two layers of Modified Tile Underiayment to the low slope roof section.
C. Reuse primary (lashings at roof penetrations.
D. During &,e re-iastaliatiou of the tile, supply and install secondary flaSLuggS at all pipe and
vent penetrations. (As necessary)
E. Re -install the tile.
F. Replace broken tile as necessary.
G. Re -install the trim tiles.
H. Leave the project in a broom clean condition.
PRICE BRE aJCDONV
76380 Calle Mazatlan
S 8,834.00
76890-76900 Calle Mazatlan
$13,456.00
76936-76940 Calle Mazatlan
$25,867.00
76942-76946 Calle Mazatlan
521,344.00
76970-76972 Calle Mazatlan
$13,735.00
76974-76976 Calle Mazatlan
$13,615.00
76978-76932 Calle Mazatlan
$21,344.00
76984-76936 Calle Mazatlan
$13,735.00
76988-76990 Calle Mazatlan
$13,615.00
76992-76994 Calle Mazatlan
$15,324.00
7 7102-77104 Calle Mazatlan
$21,344.00
77307 Avenida Fernando
S 8,834.00
77309-77311 Avenida Fernando
$13,615.00
77313-77315 Avenida Fernando
$15,434.00
77317-77319 Avenida Fernando
$15,324.00
77321-77323 Avenida Fernando
$13,615.00
77323-77327 Avenida Fernando
$13,615.00
77329 Avenida Fernando
S 8,834.00
77331-77333 Avenida Fernando
$15,434.00
77325-77337 Avenida Fernando
$15,434.00
77339-77341 Avenida Fernando
S 15,324.00
77343-77345 Avenida Fernando
$15,324.00
77347-77349 Avenida Fernando
$13,615.00
77351 Avenida Fernando
S 8,834.00
New Roci Svstem
November 5, 2013
Pa?.- 4 of
CONiTR_kCT A_MOU T
nree Iniundred Fifty Five Taeusand Four Hundred Forty Ni ine Dollars
53-5;,449,00
E XCL. [; S[O'N S
No items will be suppii.ed nor work performed that is not specifically stated herein.
PAI E,N'T TERMS
A 10% or fl000.00 deposit, whichever is less, is due wit. the signed contract. Twice-monHv
payments until comp Lcdon of contract. Invoices to be paid with 10 days of receipt. No retention, to
be h4a!d. Any re:na.ining balance due following completion to be paid within 15 days of receipt of
the irn.oice.
WARR -N-f V
A ten (10) year labor and material warranty will be issued by Western Pacific Roof upon
completion of the roof and final payment is received. Contractor's work will be warranted by
Contractor in accordance with its standard warranty, which is mad,- a part of this proposal and
contract and incorporated by reference. A copy of the Contractor's standard warranty is attached
or, if not, wii.1 be hu-nished upon request_ Contractor SHALL Ni OT BE LLkBLE FOR SI'EGIU,
MIDEINTAL OR GONSEQC]ENTLU DA.NLkGES. The acceptance of this proposal by the
Customer signifies his agreement that this warranty shall be and is the exclusive remedy against
Contractor for all defects in workmanship furnished by Contractor.
The price quoted has been structured to reflect standards we assume are mutually desired: quality
installation, service reliability and long -term performance. The price may be subject to change 15
days from the date of this proposal.
If you are in accordance with. the conditions herein, Please execute the agreement below
inctudinq the attached General Terms and Conditions and retum both conies to this office. We
will, in turn, sign them and return one copy to you. Thank you for your cooperation in expediting
this contract for your roofing needs.
NOTICE TO OWNER
Contractan are required by law to be licensed and regulated by the Contractor's State
License lt3oard. Any questions concerning a contract may be referred to the Registrar,
CO.'ltrIlctOr's State License Board, P.O. Box 25000, Sacramento, CA 95826 or call 1-300-321-
CSLB or mv3uCSLB.CA.G0Vfor more information.
A 0 F �—� I iT= N FFk-I " i''
New F,Ocf System
November 6, 2013
Pate 5 oF5
LAW REQUIRES A.Nr`1"0'rE WHO CUNMUCTS TO DO CO-NSTRUCTION WORK TO BE LICLNSED BY
THE COi+TRACTORS STATE LICENSE BOARD 17i IM L(Cn-SE CATEGORY E.N NVMCft THE
CONTRACTOR #S GOLVG TO BE WOREa G EF THE TOTAL PRICE OF 'IMF JOB IS SS00 OR MORE'
(I CLLMG LABOR AM) NfATERULS).
"UCE:rSED CONTRACTORS ARE REGULATED By L.A%'S DESIGNER TO i'ROTECT THE PLBL.IC. IF
YOE; CONTRACT %VTTH SOMEONE LY$0 DOES NOT HAVE A LICL-NSE, TEM CONTRACTORS STATE
LICENSE BOARD NWY 8E UNABLE TO ASSLST VOC UTM A CO_N[pi.ALti"T. YOLK 0`+� Y ERE�IEDY
AG.A L�iST A.�i UNLICENSED COiMTR_kCTOR ti[AY BE Df CPTL COURT, A.N`D YOGI Z%L kY BE LLtBLE
FOR DA.'U►GES ARLSV G OLT OF A-N[Y L`JLRMS TO TEM CO-'N-MACTOR OR MS OR gER
"YOU iNLkY COtiTACT ME CONTRACTORS STATE LICENSE BOARD TO }FL`1) OLT IF THIS
CONTRACTOR UAS A V.Ua3 LICENSE. TIC BOARJD H.AS COMPLETE VFOFU ATION ON THE
SLSTORY OF LIC0SED CONTRACTORS, OCLLDUG ANFY POSSIDLE SUSP!!.iSIO-N-s,
REV'OCA'TO iS, JLI3GIN[E-NTS, A-N-D MATTONS. THE ]BOARD HAS OFFICES TUROCGHOLT
CAL1FO&'nL PLEASE CHECK TEM G04ER-1-3,RENT PAGES OF TL4E IX rTE PAGES FOR THE
OFFTCE NF-A.REST YOU OR CALL 1-800-321-CSLB OR 1VWW.CSL3.C4.f- FOR N P,E
UFOR,NLATIO�ti."
ACf0;MVtE1)G-N E.%j'T: Owner ackno► K&-,s that helshe has read and received a ltagibie copy of
this a-reeaeent including aI3 terms and standard PTOVisions before any work is pe formed and that
htlshe his read and received a le5bie copy of every othex doc�rnertt that owner has si;ned d�nrina
this negotiation. rhve hereby aeimowledge under tie penalty of perjury that V*,ve am/are the ItTal
owners and am/are authorized to sin'n this contract as an a;ent of the legal owner.
ACCEPTk CE: The above prices, specirications and conditions are satisfactory and are hereby
.accepted. You are authorized to do the work as speci;� & Payment will be as outlined above. You,
the buyer may cancel this transaction at anv time prior to rnidni?ht of the third business day after the
dice of this transaction. Owner has the right to require contractor to have a performance and
payment band at Owner's expense.
La Quinta Tennis Villas HOA WESTERN PACIFIC ROOFING CORP.
Contractors License 91-35717
Owner or Owner's Agent Authorized Ao ent - lack Power
Pro'ect tiiana�er
Title Date Title
Date
WESTERN PACIFIC ROOFING CORP. HAS THE RIGHT TO R-eSCLND THIS CONTRACT 66TTHLv FIFTEEN DAYS OF ACCEPTANCE.
THIS AGREF-MENT IS NOT BINDING UNTIL ACCEPTED BY THE OFFICE !MANAGEMENT AT 3462 LA CAMPANA WAY, P.AL.�I
SPRINGS, CA 92262. NO CHANGES OR ADDITIONS TO THIS AGREEMENT SHALL BE EFFECTIVE UNTIL. APPROVED BY WESTERN
PACIFIC ROOFING CORP. (MANAGEMENT.
MAAINA.GERS ACCEPTANCE: DATE
- - - - r�r'�'•'"y=•-�'�-:pie=�.< -' � "fir i-_: � _Ax
- -- -'.� • y�� „'tip.' _ _ — _ _ � - _ - _ _ - -71
_ µA�,.S=.ti.C�s � - Lam'; •L _-- -. � --_ -- --_ = ���- - _ - -- -
,ter:-•_-- _ _ _ _ ___ _ �-�.���--= ':_- _ ���f�=��-- - _ _-��_ _ __ _ - - - _ - - � - -_