The URL can be used to link to this page

BRER2019-017578-495 CALLE TAMPICO D, VOICE (760) 777-7125 LA QUINTA, CALIFORNIA 92253 FAX (760) 777-7011 DESIGN & DEVELOPMENT DEPARTMENT INSPECTIONS (760) 777-7153 BUILDING PERMIT Date: 9/23/2019 Permit Type/Subtype: RE -ROOF/ Owner: Application Number: BRER2019-0175 Rawls Kendra / Rawls Dan Property Address: 76890 CALLE MAZATLAN APN: 658161049 Application Description: LQ TENNIS VILLAS / 1900SF REROOF EXISTING TILE Property Zoning: Application Valuation: $8,834.00 Applicant: Contractor: WESTERN PACIFIC ROOFING CORP / La \ WESTERN PACIFIC ROOFING CORP 2229 EAST AVENUE Q D L�L� 2229 EAST AVENUE Q PALMDALE, CA 93550 ]DIPALMDALE, CA 93550 SEP 2 3 2019 (661)273-1336 Llc. No.: 235717 CITY OF LA QUINTA --------------------------_------- DESIGN&BEVROPMENTMARTMENF---------------------------------- LICENSED CONTRACTOR'S DECLARATION I hereby affirm under penalty of perjury that I am licensed under provisions of Chapter 9 {commencing with Section 70001 of Division 3 of the Business and Professions Code, and my License is in full force and effect. License Class: B. C39 License No.: 7 7 Date: — Contractor EgE!� OWNER- ILDER DECLARATION I hereby affirm under penalty of perjury that I am exempt from the Contractor's State License Law for the following reason (Sec. 7031.5, Business and Professions Code: Any city or county that requires a permit to construct, alter, improve, demolish, or repair any structure, prior to its issuance, also requires the applicant for the permit to file a signed statement that he or she is licensed pursuant to the provisions of the Contractor's State License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code) or that he or she is exempt therefrom and the basis for the alleged exemption. Any violation of Section 7031.5 by any applicant for a permit subjects the applicant to a civil penalty of not more than five hundred dollars ($500).: (_) 1, as owner of the property, or my employees with wages as their sole compensation, will do the work, and the structure is not intended or offered for sale. (Sec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who does the work himself or herself through his or her own employees, provided that the improvements are not intended or offered for sale. If, however, the building or improvement is sold within one year of completion, the owner -builder will have the burden of proving that he or she did not build or improve for the purpose of sale.). (_) I, as owner ofthe property, am exclusively contracting with licensed contractors to construct the project. (Sec. 7044, Business and Professions Code: The Contractors' State License Law does not apply to an owner of property who builds or improves thereon, and who contracts for the projects with a contractor(s) licensed pursuant to the Contractors' State License Law.). (_) I am exempt under Sec. B.&P.C. for this reason Date: Owner: CONSTRUCTION LENDING AGENCY hereby affirm under penalty of perjury that there is a construction lending agency for the performance of the work for which this permit is issued (Sec. 3097, Civ. C.). Lender's N Lender's Add WORKER'S COMPENSATION DECLARATION I hereby affirm under penalty of perjury one of the following declarations: have and will maintain a certificate of consent to self -insure for workers' compensation, as provided for by Section 3700 of the Labor Code, for the performance of the wo .for which this permit is issued. I have and will maintain workers' compensation insurance, as required by Section 3700 of the Labor Code, for the performance of the work for which this permit is issued. My workers' compensation insurance carrier and policy number are: Carrier: ARCH IN5UFtANCF COMPANX Policy Number: ZAWC19401702 I certify that in the performance of the work for which this permit is issued, shall not employ any person in any manner so as to become subject to the workers' compensation laws of California, and agree that, if I should become subject to the workers' compensation provisions of Section 3700 of the Labor Code, I shall forthwith comply with those provisions. Date: �3-00' Applicant: WARNING: FAILURE TO SECURE WORKER MPENSATION COVERAGE IS UNLAWFUL, AND SHALL SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO ONE HUNDRED THOUSAND DOLLARS ($100,000). IN ADDITION TO THE COST OF COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE, INTEREST, AND ATTORNEY'S FEES. APPLICANT ACKNOWLEDGEMENT IMPORTANT: Application is hereby made to the Building Official for a permit subject to the conditions and restrictions set forth on this application. 1. Each person upon whose behalf this application is made, each person at whose request and for whose benefit work is performed under or pursuant to any permit issued as a result of this application , the owner, and the applicant, each agrees to, and shall defend, indemnify and hold harmless the City of La Quinta, its officers, agents, and employees for any act or omission related to the work being performed under or following issuance of this permit. 2. Any permit issued as a result of this application becomes null and void if work is not commenced within 180 days from date of issuance of such permit, or cessation of work for 180 days will subject permit to cancellation. I certify that I have read this application and state that the above information is correct. I agree to comply with all city and county ordinances and state laws relating to building construction, and hereby authorize representatives of this city to enter upon the` 1171 mentioned property for inspection purposes. -A Date: ��' Signature (Applicant or Age Date: 9/23/2019 Application Number: BRER2019-0175 Property Address: 76890 CALLE MAZATLAN APN: 658161049 Application Description: LQ TENNIS VILLAS / 1900SF REROOF EXISTING TILE Property Zoning: Application Valuation: $8,834.00 Applicant: WESTERN PACIFIC ROOFING CORP 2229 EAST AVENUE Q PALMDALE, CA 93550 Owner: Rawls Kendra / Rawls Dan Contractor: WESTERN PACIFIC ROOFING CORP 2229 EAST AVENUE Q PALMDALE, CA 93550 (661)273-1336 Llc. No.: 235717 Detail: REMOVE AND RESET ROOF TILES NEW 2 PLY 40# UNDERLAYMENT. PER 2016 CALIFORNIA BUILDING CODES DESCRIPTION ACCOUNT CITY AMOUNT BSAS SB1473 FEE 101-0000-20306 0 $1.00 Total Paid for BUILDING STANDARDS ADMINISTRATION BSA: $1.00 DESCRIPTION ACCOUNT CITY AMOUNT RECORDS MANAGEMENT FEE 101-0000-42416 0 $10.00 Total Paid for RECORDS MANAGEMENT FEE: $10.00 DESCRIPTION ACCOUNT CITY AMOUNT RE -ROOF - FIRST 2,000SF 101-0000-42404 0 $54.74 DESCRIPTION ACCOUNT CITY AMOUNT RE -ROOF - FIRST 2,000SF PC 101-0000-42600 0 $109.48 Total Paid for RE -ROOF 2019: S164.22 DESCRIPTION ACCOUNT CITY AMOUNT TECHNOLOGY ENHANCEMENT FEE 502-0000-43611 0 $5.00 Total Paid for TECHNOLOGY ENHANCEMENT FEE: $5.00 W CALIFORM Project Address: '7b576. APN #: Applicant Name: Address: City, ST, Zip: Telephone: Email: G/rL L f MA-Z*r6,4Project Description: T-f Valuation of Project Contractor Name: W EST IR,-j PA C/ -- 6 ?(Vtr New SFD Construction: Address: 3 yio LA GA�y�q,�f} wA� Conditioned Space City, St, Zip jM SPQ�N(,s �aa� Garage Telephone: )6D ` 716 -,ff Patio/Porch Email: (,J �IQc,Jo's WEST /P,4ClZq�f=, G Fire Sprinklers State Lic:ol3s-71 City Bus Lic:000 1,101g3 Architect/Engineer Name: I Construction Address: Grading: City, St, Zip Telephone: Bedrooms: Stories: Email: State Lic: City Bus Lic: �In SF SF SF SF Occupancy: # Units: c R-s +bA- ey Property Owner's Name: L M ��,�-� New Commercial /Tenant Improvements: Address:�? Total Building / SF City, ST, Zip LLASC L 't Construction Type: Occupancy: Telephone: 94 1 g"V Email: 5/}p.l lal t- .� -1 7gl sc�1,0 784 5 CALLE TAMPICO Sd r£ 6-1 LA QUINTA, CA 92253 Pig L n f A r c/j. 760- 777-7000 99a)1 OFFICE USE ONLY --F-- # Submittal I Required Received Plan Sets Structural Calcs Truss Calcs Title 24 Calcs Soils Report Grading Plan (PM10) Landscape Plan Subcontractor List Grant Deed HOA Approval School Fees Burrtec Debris Plan Planning approval Public Works approval Fire approval City Business License �� FACMC ! _ I L _Y I cxg4h� December 4, 2018 La Quinti Tennis Villas [10A c/o ReaBUaage Attn: Saadv Ivins 75178 Gerald Ford Avenue Smite B-1 Palm Desert, CA 9221 11 Subject. Proposal for New Tile Underlay3nent Roof Systems La Quinta Tennis Villas (Various Ad&esses) La Quints, CA 92-9533 Dear NL. [vies: Thank you for the opportunity to submit a proposal for the roofing at the above referenced property. We are pleased to submit our proposal for the work as described below. The scope of work and associated costs are as follows: GFNEKU This proposal and contract is made be'Nveen Western Pacific Roofing Corp. (Contractor} and the person (s) or entity Hamer! above (Owner or Owner's Agent}. Unless expressly stated to the contrary, the contractor shall be responsible for performing the following: DESCRIPTTIO A. The general conditions of this standard construction contract shall form a part of these specifications with the same force and effort as though repeated herein. B. The Contractor shall furnish all labor, materials, equipment, permits, contractor's licenses and insurance certifications to perform all operations required as specified. The contractor shall provide labor and material customarily included in work of the same nature to give a quality, complete job. C. If any unforeseen or unexpected conditions are encountered during the work, and the conditions adversely affect the cost or progress of the work, the contractor will notify the owner immediately, and the owner will negotiate a written change -order to resolve the unexpected condition be it for an increase or decrease to the contract amount. D. The Contractor shall occupy, use, and permit others to use the premises only for the purpose of completing the work to be performed under this contract with the Owner. Contractor is to 3462 La Campana Way • Palm Springs, CA 92262 • (760) 416-5377 • Fax (760) 320-8912 wnvw.westpacroof.com • Contractors License No. 235717 • E-mail: wprcps@westpacroof.com New Roof Syst-m November 6, 2018 Page 2 of 5 be given all reasonable sat -up and staging areas. Due to the Bruited access, some driveways or Parking areas may be blocked during this construction process. E. Contractor's scope of work shall not include the identification, detection, abatement, en. capsulation or removal of asbestos or similar hazardous substances including mold, m-Mew and infestation of rodents. If Contractor encounters any such products, materials or conditions in the coursc of performing its work, or if such hazardous materials are encountered by any other E=' performing work at the jobsite and contractor determines that such materials present a !hazard to its employees, contractor shall have the right to discontinue its work and remove its employers ,from the jobsite until such products or materials, and any hazards. connected therewith, are located and abated, encapsulated or removed, or it is determined that no hazard exists (as: the case may require), and contactor shah receive an extension of time to complete its work hereunder and compensation For delays encountered as a result of such situation and corr,-tion_ Due to the possibility of mold, mildew and rodents being present before, firing or after our work, Contractor's scope of woes shall not include the identification, detection or the removal ofrnold, mildew and rodents. Contractor shall not be responsible for entrapment of rodents dw-ing roofing or attempt by Contractor at order of association or homeowner to ksep rodents out of runt. Owner agrees to hold Contactor harmless, and shall indemnify Contractor harmless for any mold or rodent related claims in the future. F. If a dispute shall arse between Contractor and Owner with respect to any matters or questions arising out of or relating to this contract or t`te breach thereof, such dispute shall be decided by arbitration administered by and in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association or through such arbitration procedures as the parties may agree. This contract shall be specifically enforceable under the prevailing arbitration law. The award rendered by the arbitrators shall be final, and judgg-rient may be entered upon it in any Court having jurisdiction thereof. G. Should suit be brought to enforce or interpret any part of this Agreement, the "prevailing party" shall be entitled to recover, as an element of costs of suit and not as damages, reasonable attorneys' fees to be fixed by the Court. The "prevailing party' shall be entitled to recover its costs of suit, regardless of whether such suit proceeds to final judgment. H. INSMkNCE: Western Pacific Roofing Corp. shall secure, pay the premium for and ke,:p in force until expiration of this Agreement, worker's compensation insurance, as well as general liability and property damage insurance, with limits not less than one million dollars (51,000,000.00) per person, two million dollars (52,000,000.00) per occurrence, and excess liability coverage totaling ten million dollars (310,000,000) aggregate. T-1 "C' AAR, New Roos System November 6, 20 t 3 Pave 3 of 5 SCOPE OF `VORK SURFACE PREPAF kTIOi\i A. Remove the existing tile and set aside. B. Dama;ed plywood will be rep[aced at a rate of 565.00 per, sheet or portion thereof and billed separately as a change -order. C. Passe the existing perimeter metal and Bird S top. LN'STALLATIOiV OF INEW TILE UNDER%,AYMDNT A. Install two laye:-s of #r 44 tile underlavment medically fastened. B. Install two layers of tilodified Tile Underlay-ment to the low slope roof section. C. ReL;se primary fiashings at roof penetrations. D. Duriag the re -installation of the tile, Supply and install secondary iiasLags at all pipe and vent penetrations. (As necessar/) E. Re -install the tile. F. Replace broken tile as necessary. G. Re -install tre trim tips. H. Leave the project in a broom clean condition. PRICE BRE a-fMONN1i 76330 Calle ?Mazatlan 76390-76900 Calle Mazatlan 76936-76940 Calle Mazatlan 76942-76946 Calle Mazatlan 76970-76972 Calle Mazatlan 76974-76976 Calle Mazatlan 76978-76932 Calle Mazatlan 7698=4'-76936 Calle Mazatlan 76933-76990 Calle Mazatlan 76992-76994 Calle Mazatlan 7 7102-77104 Calle Mazatlan 77307 Avenida Fernando 77309-77311 Avenida Fernando 77313-77315 Avenida Fernando 77317-77319 Avenida Fernando 77321-77323 Avenida Fernando 77325-77327 Avenida Fernando 77329 Avenida Fernando 77331-77333 Avenida Fernando 77325-77337 Avenida Fernando 77339-7734I Avenida Fernando 77343-77345 Avenida Fernando 77347-77349 Avenida Fernando 77351 Avenida Fernando S 8,334.00 S 13,456.00 S25,867.00 S21,344.00 $13,735.00 $13,615.00 $21,344.00 $13,735.00 $13,615.00 $15,324.00 $21,344.00 $ 8,834.00 $13,615.00 $15,434.00 $15,324.00 $13,615.00 $13,615.00 $ 8,834.00 $15,434.00 $15,434.00 $15,324.00 $15,324,00 S13,615.00 $ 8,834.00 New Rock System November 6, 2013 Pave 4 oft CONTKkCT A_`NIOL"I T Three hundred Fift-� Five Thousand Four Hundred Fort;r dine Dollars S355,449,o0 EXCL CS(0'4S No items will be suppled nor work performed that is not specifically stated herein. PAI_IE,)T TERMS A 10% or S 1000.00 deposit, IvEchever is less, is due with the sided contract. Twice-mor&dy payments until compl:tion of contract. fiivo ices to be paid with 10 days of receipt. No retention to be held. A_ y remaining bala:.c_ d►ce fohowir_g completion to be paid within i days of receipt of the invoice. WARRA'VTY A ten (10) year labor and material warranty will be issued by Western Pacific Roof . upon completion of the roof and final par-ment is received. Contractor's work will be warranted by Contractor in accordance with its standard warranty, which is made a part of this proposal and contract atd incorporated by reference. A copy of the Contractor's standard warranty is attached or, if not, will be furnished upon request. Contractor SHALL NOT BE LLkBLE FOR SPECLAL., NCDDEyTA,L OR CO'SEQUENTLA-L DANL4GES. The acceptance of this proposal by the Customer signifies his agreement that this warranty shall be and is the exclusive remedy against Contractor for all defects in workmanship furnished by Contractor. The price quoted bas been structured to reflect standards we assume are mutually desired: quality installation, service reliability and long -term performance. The price may be subject to change 15 days from the date of this proposal. LE you are in accordance with the conditions herein, Please execute the agreement below including tape attached General Terms and Conditions and return both cooies to this office. We will, in turn, sign them and return one copy to you. Thank you for your cooperation in expediting this contract for your roofing needs. itiOTICE TO O`Y-NTR Contractors are required by law to be licensed and regulated by the Contractor's State License Bard. Arty questions concernin; a contract may be referred to the Registrar, Contractor's State License Board, P.O. Box 26000, Sacramento, CA 95826 or call 1-300-321- CSLB or,v,vw.CSLB.CA. GOVfor more information. JAIPW��-_ - - 11i i _� mac: - - - - - _r..f �- �.:.�N- ��.• �`�-,w.��..r_ _ _ _ - - _ - _� :ice_' �-- .r- _ �~F - _ - - _ _ - ;�� _ =� �-�r��-�,�;� •--��." � .tom =' _ " - _ _ _ - - - -'=�• . = - - - _ _ - - _ -- - ""- .- � .. _ =ram __ •. - _ - .. - .. - yr' _- - 4 -- _ _- _ _ - - ._ - " •--� - - - - _ - _ - _ -- -. - -•" - - _ -� :,;ter-y --- - _- '- _- --_ .- -- "-- _ - _ _ 'fir ==�r�-��r-•� �" - - - - --..,v�>: � - �^� ~-_ _ - - - - _ _-- - _--- _=. -_ � — _ ..• z.•"I r+�'.S rye �� _ �i ^��+G:.z�-: •�' - _ �,�� '�, =_' -_ -