BRER2019-017678-495 CALLE TAMPICO
LA QUINTA, CALIFORNIA 92253
Permit Type/Subtype:
Application Number:
Property Address:
APN:
Application Description:
Property Zoning:
Application Valuation:
wity,, 4 �P Q"
DESIGN & DEVELOPMENT DEPARTMENT
BUILDING PERMIT
RE -ROOF/
BRER2019-0176
76900 CALLE MAZATLAN
658161048
LQ TENNIS VILLAS / REROOF EXISITING TILE
$6,728.00
Applicant:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
SEP 2 3 2019
I
CITY OF LA QUINTA
DESIGN & DEVELOPMENT DEPARTMENT
LICENSED CONTRACTOR'S DECLARATION
I hereby affirm under penalty of perjury that I am licensed under provisions of Chapter 9
(commencing with Section 70001 of Division 3 of the Business and Professions Code, and
my License is in full force and effect.
License Class: B. C39 License No.: 235717
Date: — O ✓?—) Contractor:
OWNER-8 R D LARATION
I hereby affirm under penalty of perjury that I am exempt from the Contractor's State
License Law for the following reason (Sec. 7031.5, Business and Professions Code: Any
city or county that requires a permit to construct, alter, improve, demolish, or repair any
structure, prior to its issuance, also requires the applicant for the permit to file a signed
statement that he or she is licensed pursuant to the provisions of the Contractor's State
License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business
and Professions Code) or that he or she is exempt therefrom and the basis for the
alleged exemption. Any violation of Section 7031.5 by any applicant for a permit
subjects the applicant to a civil penalty of not more than five hundred dollars ($500).:
(_) 1, as owner of the property, or my employees with wages as their sole
compensation, will do the work, and the structure is not intended or offered for sale.
(Sec. 7044, Business and Professions Code: The Contractors' State License Law does not
apply to an owner of property who builds or improves thereon, and who does the work
himself or herself through his or her own employees, provided that the improvements
are not intended or offered for sale. If, however, the building or improvement is sold
within one year of completion, the owner -builder will have the burden of proving that he
or she did not build or improve for the purpose of sale.).
(_) I, as owner of the property, am exclusively contracting with licensed contractors to
construct the project. (Sec. 7044, Business and Professions Code: The Contractors' State
License Law does not apply to an owner of property who builds or improves thereon,
and who contracts for the projects with a contractor(s) licensed pursuant to the
Contractors' State License Law.).
(_) I am exempt under Sec. , B,&P.C. for this reason
Date: Owner:
CONSTRUCTION LENDING AGENCY
I hereby affirm under penalty of perjury that there is a construction lending agency for
the performance of the work for which this permit is issued (Sec. 3097, Civ. C.).
Lender's
Lender's Add
VOICE (760) 777-7125
FAX (760) 777-7011
INSPECTIONS (760) 777-7153
Date: 9/23/2019
Owner:
Fifth Place Prop
Contractor:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
(661)273-1336
Llc. No.: 235717
WORKER'S COMPENSATION DECLARATION
I hereby affirm under penalty of perjury one of the following declarations:
I have and will maintain a certificate of consent to self -insure for workers'
compensa as provided for by Section 3700 of the Labor Code, for the performance
of th rk for which this permit is issued.
I have and will maintain workers' compensation insurance, as required by
Section 3700 of the Labor Code, for the performance of the work for which this permit is
issued. My workers' compensation insurance carrier and policy number are:
Carrier: ARCH INSURANCE COMPANY Policy Number: ZAW 194 17 2
I certify that in the performance of the work for which this permit is issued, I
shall not employ any person in any manner so as to become subject to the workers'
compensation laws of California, and agree that, if I should become subject to the
workers' compensation provisions of Section 3700 of the Labor Code, I shall forthwith
comply with those provisions.
Date: � -�S-17 Applicant
WARNING: FAILURE TO SECURE W015�iS' COMPENSATION COVERAGE IS UNLAWFUL,
AND SHALL SUBJECT AN EMPLOYER TO CRIMINAL PENALTIES AND CIVIL FINES UP TO
ONE HUNDRED THOUSAND DOLLARS ($100,000). IN ADDITION TO THE COST OF
COMPENSATION, DAMAGES AS PROVIDED FOR IN SECTION 3706 OF THE LABOR CODE,
INTEREST, AND ATTORNEY'S FEES.
APPLICANT ACKNOWLEDGEMENT
IMPORTANT: Application is hereby made to the Building Official for a permit subject to
the conditions and restrictions set forth on this application.
1. Each person upon whose behalf this application is made, each person at whose
request and for whose benefit work is performed under or pursuant to any permit issued
as a result of this application , the owner, and the applicant, each agrees to, and shall
defend, indemnify and hold harmless the City of La Quinta, its officers, agents, and
employees for any act or omission related to the work being performed under or
following issuance of this permit.
2. Any permit issued as a result of this application becomes null and void if work is not
commenced within 180 days from date of issuance of such permit, or cessation of work
for 180 days will subject permit to cancellation.
I certify that I have read this application and state that the above information is correct.
I agree to comply with all city and county ordinances and state laws relating to building
construction, and hereby authorize representatives of thi tv ente on the above -
mentioned property for inspection purposes. ��
Date: Signature (Applican gent
Date: 9/23/2019
Application Number:
BRER2019-0176
Property Address:
76900 CALLE MAZATLAN
APN:
658161048
Application Description
LQTENNIS VILLAS / REROOF EXISITING TILE
Property Zoning:
Application Valuation:
$6,728.00
Applicant:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
Owner:
Fifth Place Prop
Contractor:
WESTERN PACIFIC ROOFING CORP
2229 EAST AVENUE Q
PALMDALE, CA 93550
(661)273-1336
Llc. No.: 235717
Detail: REMOVE AND RESET ROOF TILES NEW 2 PLY 40# UNDERLAYMENT. PER 2016 CALIFORNIA BUILDING CODES
DESCRIPTION
FINANCIAL INFORMATION
ACCOUNT CITY
AMOUNT
BSAS SB1473 FEE
101-0000-20306 0
$1.00
Total Paid for BUILDING STANDARDS ADMINISTRATION BSA:
$1.00
DESCRIPTION
ACCOUNT
CITY
AMOUNT
RECORDS MANAGEMENT FEE
101-0000-42416
0
$10.00
Total Paid for RECORDS MANAGEMENT FEE:
$10.00
DESCRIPTION
ACCOUNT
CITY
AMOUNT
RE -ROOF - FIRST 2,000SF
101-0000-42404
0
$54.74
Total Paid for RE -ROOF 2019:
$54.74
DESCRIPTION
ACCOUNT
CITY
AMOUNT
TECHNOLOGY ENHANCEMENT FEE
502-0000-43611
0
$5.00
Total Paid for TECHNOLOGY ENHANCEMENT FEE:
$5.00
ca Qwkra
-- CALIYORNIA
Project Address: 2 &,m
APN #:
Applicant Name:
Address:
City, ST, Zip:
Telephone:
Email:
Contractor Name:
Address:
City, St, Zip
Telephone:
Email:
State Lic: 9
City Bus Lic:
Architect/Engineer Name:
Address:
City, St, Zip
Telephone:
Email:
State Lic
City Bus Lic:
IT #
^4,4 �TLrf+�/ Project Description:
A A optpf—
Valuation of Project
New SFD Construction:
Conditioned Space SF
Garage SF
Patio/Porch SF
Fire Sprinklers SF
Construction Occupancy:
Grading:
Bedrooms: I Stories: I # Units:
Property Owner's Name: /2,,4,_ New Commercial /Tenant Improvements:
Address: _ D 3 L��' Total Building
SF
City, ST, Zip fjl L�f}f' fis Construction Type: Occupancy:
Telephone: 2 0 _ 900 _ 8rd
Email: Sfi�'✓ AV,5
1 ,,,��g495 CALLE TAMPICO
A QUINTA, CA 92253
I✓ q 760-777-7000
suIft l -!
OFFICE USE ONLY
# Submittal I Required 1 Received
Plan Sets
Structural Calcs
Truss Calcs
Title 24 Calcs
Soils Report
Grading Plan (PM10)
Landscape Plan
Subcontractor List
Grant Deed
HOA Approval
School Fees
Burrtec Debris Plan
Planning approval
Public Works approval
Fire approval
City Business License
WESTERN- P`ACMC
December 4, ?O1 8
La Quints Tennis `'i11as HOA
do ReiMaage
Attu: Sandy Ivins
75173 Gerald Ford Avenue Suite B-1
Palm Desert, CA 92" 11
Subject: Proposal for New Tile Undlertivment Rwr Systeon
Q
La 131nta Tennis Villas (Vario.us Adiresses)
La Quinta, CA 922533
Dear NLs. Ivins:
Thank you for the opportunity to submit a proposal for the roofing at the above re erenced property.
We are pleased to submit our proposal for the work as described below. The scope of work and
associated costs are as follows:
GENERAL
This proposal and contract is made between Western Pacific Roofing Corp. (Contractor) and the
person (s) or entity named above (Owner or Owner's Agent). Unless expressly stated to the
contrary, the contractor shall be responsible for performing the foiiowing:
DESCRIPTIO`v
A. The general conditions of this standard construction contract shall form a part of these
specifications with the same force and effort as though repeated herein.
B. The Contractor shall furnis,a all labor, materials, equipment, permits, contractor's 6; ses
and insurance certifications to perform all operations required as specified The contractor
shall provide labor and material customarily included in work of the same nature to give a
quality, complete job.
C. If any unforeseen or unexpected conditions are encountered during the work, and the
conditions adversely affect the cost or progress of the worst, the contractor will notify the
owner immediately, and the owner will negotiate a written change -order to resolve the
unexpected condition be it for an increase or decrease to the contract amount.
D. The Contractor shall occupy, use, and permit others to use the premises only for the purpose
of completing the work to be performed under this contract with the Owner. Contractor is to
3462 La Campana way • Palm Springs, CA 92262 • (760) 416-5377 • Fax (760) 320-8912
WIVW.westpacroof.com - Contractors License No. 235717 • E-mail: wprcpsCwestpacroof.com
New Roof System
November 6, 2018
Paz,. 2 of5
be given all reasonable set-up and staging areas, Due to the limited access, some driveways
or Parking ar..as may be blocked during his construction process.
E. Contractor's scope of work shall not include tl&,e identification, detection, abatetr�ent,
encapsulation or removal of asbestos or similar hazardous substances including mold,
mildew and infestation of rodents. If Contractor encounters any such products, materials or
conditions in the course of performing its work, or if such hazardous materials are
encountered by any other fmn peg -forming work at the jobsite and contractor determines that
such material"; present a hazard to its employees, contractor shall lea►re the right to
discontinue its work and remove its employers from the jobsite until such products or
materials, and any hazards connected &,=wiith, arc located and abated, encapsulated or
removed, or it is determined that no hazard exists (as the case may require), and contractor
shall receive an extension of time to complete its work hereunder and compensation, for
delays encountered as a result of such situation and correction. Due to the possibility of
mold, mildew and rodents being present before, &ring or after our work. Contractor's
scope of work sLiU not include the identification, detection or the removal of mold, mildew
and rodents. Contractor shall not be responsible for entrapment of rodents dw-ic�g rool�ng or
attempt by Contractor at order of association or homeowner to keep rodents out of unit.
Owner agrees to hold Contractor harp less, and shall indemnify Contractor harmless for any
mold or rodent related claims in the future.
F. If a dispute shall arise between Contractor and Owner with respect to any matters or
questions arising out of or relating to this contract or the breach thereof, such dispute
s'aall be decided by arbitration administered by and in accordance with the Construction
Industry Arbitration Rules of the American Arbitration Association or through such
arbitration procedures as the parties may agree. This contract shall be specifically
enforceable under the prevailing arbitration law. The award rendered by the arbitrators
shalt be final, and judgment may be entered upon it in any Court Laving jurisdiction
thereof.
G. Should suit be brought to enforce or interpret any part of ffids Agreement, the "prevailing
party" shall be entitled to recover, as an element of costs of suit and not as damages,
reasonable attorneys fees to be fixed by the Court. The "prevailing party' shall be entitled
to recover its costs of suit, re;ardlwss of whether such suit proceeds to final judgment.
H. IySCTR.kNCE: Western Pacific Roofing Corp. shall secure, pay the premium for and
keep in force until expiration of this Agreement, worker's compensation insurance, as
well as general Liability and property damage insurance, with limits not less than one
million dollars (S1,000,000,00)per person, two million dollars (S2,000,000.00) per
occurrence, and excess liability coverage totaling ten million dollars (S10,000,000)
aggregate.
Nesv Roof System
November 6, 2013
Pave 3 of 5
SCOPE OF `VORK
SURFACE PREP.kRATIOi\i
A. Remove the existing tile and set aside.
B. Dama`'ed plywood will be replac-ed at a rate of S65.00 per sheet or portion thereof and
billed separately as a changge-or ler.
C. R-Mse the eYistiil, perimeter metal and Bird Stop.
LN'STALL4TION OF INFEW TILE UNDERLAiY-fiENT
A. Install two layers of 7 40 lily underla�m.ent me-haaically fastened.
B. Install two layers of Nfo&fied Tile Un&rlayment to the low slope roof section.
C. Reuse prima-r flashin;s at roof penetrations.
D. Durino, the re -installation of the tile, supply and install secondary flasLags at all pipe and
vent penetrations. GAs necessary)
E. Re-instafl the tile.
F. Replace broken tile as necessary.
G. Re -install the trim tiles.
H, Leave the project in a broom clean condition.
PRICE DRE A-KI)O`d1i
76330 Calle Mazatlan
$ 8,834.00
76890-76900 Calle Mazatlan
$13,456.00
76936-76940 Calle Nfazatlan
$25,867.00
76942-76946 Calle Mazatlan
$21,344.00
76970-76972 Calle Mazatlan
$13,735.00
76974-76976 Calle Mazatlan
$13,615.00
76978-76932 Calle Mazatlan
$21,344.00
76984-76936 Calle Mazatlan
S13,735.00
76938-76990 Calle Mazatlan
$13,615.00
76992-76994 Calle Mazatlan
$15,324.00
77102-77104 Calle Mazatlan
$21,344.00
77307 Avenida Fernando
$ 8,834.00
77309-77311 Avenida Fernando
$13,615.00
77313-77315 Avenida Fernando
$15,434'00
77317-77319 Avenida Fernando
$15,324.00
77321-77323 Avenida Fernando
$13,615.00
77325-77327 Avenida Fernando
$13,615.00
77329 Avenida Fernando
$ 8,834.00
77331-77333 Avenida Fernando
$15,434.00
77325-77337 Avenida Fernando
$15,434.00
77339-77341 Avenida Fernando
$15,324.00
77343-77345 Avenida Fernando
$15,324,00
77347-77349 Avenida Fernando
S 13,615.00
77351 Avenida Fernando
$ 8,834.00
ka�
New Rod System
November b, 2013
Paz-, 4 of 5
CONTR.kCT AM UNT
Three ;iundred FiRy Five Thousand Four Hundred Forty dine Dollars
S35;,14,9.00
EXCL.[;SCO'mS
No items will be supplied nor work performed that is not specifically stated herein.
PA17 IMNT TERMS
A 10% or $1000.00 deposit, whichever is less, is due with the signed contract. Twice-montwy
Payments until compl-etion of contract, invoices to be paid with 10 days of receipt. No retention to
be held, A,ny remaining baI=cc due frlicMin; corlplti ion to
the invoice. be paid within 15 kys of receipt of
A ten (10) year labor and material warranty will be issued by Western Pacific Roofing upon
completion of the roof and final payment is received. Contractor's work will be warranted by
Contractor in accordance with its standard warranty, which is made a part of this proposal and
contract and incorporated by reference. A copy of the Contractor's standard warranty is attached
or, if not, will be furnished upon request. Contractor SHALL NOT BE LIABLE FOR SPECLkL,
Ili iCIDE,NTAL OR CONSEQUENTUL DAMAGES. The acceptance of this proposal by the
Customer signifies his agreement that this warranty shall be and is the exclusive remedy against
Contractor for all defects in workmanship furnished by Contractor.
The price quoted has been sL-uctured to reflect standards we assume are mutually desired: quality
installation, service reliability and long -term performance. The price may be subject to change 15
days from the date of this proposal.
If you are in accordance with. the conditions herein, pleaRe execute the agreement below
includinz the attached General Terms and Conditions and return both conies to this office. We
will, in turn, sign them and return one copy to you. Thank you for your cooperation in expediting
this contract for your roofing needs.
NOTICE TO O VV-ER
Contractan are required by law to be Licensed and regulated by the Contractor's State
License &ard. Any questions concerning a contract may be referred to the Registrar,
Contractor's State License Board, P.O. Box 26000, Sacramento, CA 95825 or call 1-800-.32 1-
CSLB or wmv. CSLB. CA. GOV for more information.
►"}p
New R ocf System
November 6, 2013
Pane 5 of5
LAW REQLMES A_ti-"OBE WHO CO-NTRACTS TO DO COIiSTRtiCTIO`i WORK TO BE LiCntiSE'D By
T'ME COrT&kCTORS STATE LICENSE BOA1W U� T91 UCK SE CATEGORY C� 111I1CH THE
CONT&ACCOR IS GOPiG TO BE NVORIt';G LF TIE TOTAL FRIC>! OF THE JOB LS S_00 OR MORE
(LtiCLU-IDWG LABOR kND NUTERIALS).
"LICENSED CO-NTRACTORS ARE MGLLATED BY LAWS DESIGNED TO PROTECT THE PUBLIC. IF
YOU CONTRACT %'TTEI SO 4CEO'NE W00 DOES NDT 1WT A LICEtiSE, T®E CG-N_ C-,CTORS STATE
LICENSE SO RD NLkY BE LNABLE TO ASSLST YOC UM A CO:MPLALN-T. Y[3UEL flNT Y' EiENW[)
:#G.iL1iST AY [iyi IC SED CONTRACTOR y' AY BE 0 MIL COOT, A21M YOU NEAY BF, LIABLE
FOR DkILAGES ARL G OI.-I' OF ANY DUL-t.i.E.S TO TIR CONTVACTOR OR 'EMS OR EMR
EMPLOYEES.
"YOU, KW CONTACT THE CONTRACTORS STATE LICENSE BOARD TO FLNI) (Xt IF TMS
CONTRACTOR HAS A VALID LICENSE. THE BOA} HAS COMPLETE V4FO&NLAT1().,N ON My
STORY OF LICENSED COiNTRACTORS, C CLUDD G A.YY po sswLE Si:SPEmfo.'45,
REVOC IRONS, TL"DG- NTS, A_1D CITATIONS. THE BOARD HAS OF'FTCES i'Q$OU LT
CALIF'0&1LL PLE.Y,SE CRECK TEE GO'�'EIiNAF,ENT PAGES OF THE 1111 'l-E PAGES FOR THE
OF'I+'ICE NEAREST YOu OR CALL 1-800-321-CSLB OR t 1,M..CSLB.C.4.fnv FOR NLORF
LNFOR ATIO��i.„
ACKNOWLEDGMENT. Owner aA:uovv1cd9" that helshc hi read and received a legfble copy of
this agreement including all terms and standard proszsions before any work is geTformed and that
helshe ho read and received a ld%lbla copy of every other document that owner has signed during
this negotadion. Uwe hereby ack-no vledae under the penalty of perjury that Uwe ar.�/are the Ie-al
owners and ani/are authorized to sign this contract as an a"ent of the legal owner.
ACCEPTA-NCE: The above prices, specifications and conditions are satisfactory and are hereby
accepted. You are authorized to do the work as spet'i&d. Payment will be as outlined abovE. You,
the buyer way cancel this transaction at any time prior to miduight of the third business day after the
dite of thb transaction. Owner has tote right to regWre contractor to have a performance and
Payment band at Owner's expense.
La Quinta Tennis Villas RA `NESTER' PACIT IC P OOFT iG CORP.
Contractors License 9 235717
Owner or Owner's Agent
Title Date
Authorized Agent — Jack Power
Pro'ect Nfanazer
Title Date
WESTERN PACIFIC ROOFING CORP. HAS THE RIGHT TO RESCLND THIS CONTRACT WITHIN FIFTEEN DAYS OF ACCEPTANCE.
THIS AGREEMENT IS NOT BIND[i\IG UNTIL ACCEPTED BY THE OFFICE MANAGEMENT AT 3462 LA CAMPANA WAY, PAI..�[
SPRNGS, CA 92262. NO CHANGES OR ADDITIONS TO THIS AGREELfENT SHALL BE EFFECTNT UNT1 APPROVED BY WESTERN
PACIFIC ROOFNG CORP. MANAGEMENT.
MANAGERS ACCEPTANCE: DATE