31116 OBR & Released BondsOUTSTANDING BOND REPORT
Name: CP Development
Tract No. 31116
Date of Contract: March 18, 2005
Required Bond Amounts:
Grading
$182,080
PM10
$ 69,900
Off -Site:
Streets (Washington)
$104,880
performance/labor & materials
Sidewalk (Wash. & Miles)
$ 71,570
same
Landscaping (Parkway)
$ 49,900
same
Traffic Signal @ Washington
& Seeley
$125,000
same
Standard 10% Contg.
$ 35,140
same
Prof. Fees Design
$ 38,650
same
Prof. Fees Const.
$ 38,650
same
No Plans Contg.
$ 38,650
same
On -Site:
Rough Grading
$ 63,120
same
Water
$176,780
same
Sewer
$138,1 10
same
Streets
$301,290
same
Utilities
$155,000
same
Storm Drain
$260,340
same
Landscaping
$165,920
same
Monumentation
$ 7,500
performance only
Standard 10% Contg.
$126,810 / $126,060
Prof. Fees Design
$139,490 / $138,660
Prof. Fees Const.
$139,490 / $138,660
No Plans Contg.
$139,490 / $138,660
PM10 (dust control)
$ 10,540
Outstanding Bonds and Bond Company: Travelers Casualty and Surety and
Insurance Company of the West
Amount:
$182,080
$ 69,900
$502,440 (P)
$377,830 (R)
$ 35,135 (W)
$502,440 (L&M)
$1,813,340 (P)
$ 791,279 (R)
$ 126,056 (W)
Bond No.
104351623
104351624
2137548
same
213754803
same
2137547
same
213754702
$1,802, 600 (L&M) same
$ 7,540 6373465
$ 3,000 (cash deposit in Finance)
Date Cancelled/Released:
Released 5/5/10
Released 5/5/10
Replaced w/rider 1 1 /20/08 Released 1/10/2011
Replaced w/warranty 5/5/10 Released 5/5/2010
Released 4/18/201 1
Released 1 /10/1 1
Replaced w/rider 11 /20/08 Released 1/10/2011
Replaced w/warranty 5/5% Released 5/5/2010
Released 4/18/201 1
Released 1 /10/1 1
Released 5/5/10
Released by check 1 1 /6/09
Tit'y 4 Zfv Q91A&
MEMORANDUM
To: Veronica J. Montecino, CMC, City Clerk
From: Ed Wimmer, Development Services Principal Engineer
Via: imothy R. Jonasson, P.E., Public Works Director /City Engineer
Date: April 6, 2011
Subject: Release of Warranty Securities for Parcel Map No. 31 1 16,
Centre Pointe
Please release the following warranty securities held in your files for the
above referenced parcel. The improvements were accepted by City Council
on March 16, 2010.
The warranty amounts and the address to the developer and surety company
are as follows:
PARCEL No. 31116
Warranty Bond No.
Warranty Amount
213754803 off -site
$35,135
213754 02 on -site
$126,056
Developer: Mr. Richard Oliphant
CP Development La Quinta, LLC
77-564 Country Club Drive, Suite 100
Palm Desert, CA 92211
Surety Company: Insurance Company of the West
11455 El Camino Real
San Diego, CA 92130-2045
Cc: Project File I, Parcel Map No. 31116
T:\Tracts_Parcel Maps_SP\30000-39999\31116\internal correspondence\Release of Warranty Security memo PM
31116.doc
P.O. Box 1504
LA QUINTA, CA 92247-1504
78-495 CALLE TAMPICO
LA QUINTA, CA 92247-1504
January 10, 2011
CP DEVELOPMENT LA QUINTA, LLC
Richard Oliphant
77-564 Country Club Drive, Suite 100
Palm Desert, CA 92211
Re: Parcel Map 31116
Dear Mr. Oliphant:
OFFICE OF THE CITY CLERK
(760) 777-7103
FAX (760) 777-7107
Per authorization from the Public Works Department, the City Clerk's Office hereby
releases Labor & Materials Bonds/Riders 2137548 and 2137547 in the respective
amounts of $502,440 and $1,802,600.
If you have any questions, please call me at (760) 777-7002.
Sincerely,
CA)JQkL41-
PHYLLIS MANLEY, Deputy City Clerk
City of La Quinta, California
cc: Tim Jonasson, Public Works Director/City Engineer
Insurance Company of the West
File
T4ht 4 4a Q941�t&
MEMORANDUM
To: Veronica J. Montecino, CMC, City Clerk
From: Ed immer, Development Services Principal Engineer
Via: Timothy R. Jonasson, P.E., Public Works Director/ City Engineer
Date: January 3, 2011
Subject: Release of Labor & Materials Securities for Parcel Map No.
31116, Centre Pointe
Please release the following Labor & Materials securities held in your files for
the above referenced parcel. The off -site and on -site improvements were
accepted by City Council on March 16, 2010.
The Labor & Materials security amounts and the address to the developer
and Surety Company are as follows:
PARCEL No. 31116
Labor and Materials Bond No.
Bond Amount
2137548 (off -site)
$502,440
2137547 (on -site)
$1 ,802,600
Developer: Mr. Richard Oliphant
CP Development La Quinta, LLC
77-564 Country Club Drive, Suite 100
Palm Desert, CA 92211
Surety Company: Insurance Company of the West
11455 El Camino Real
San Diego, CA 92130-2045
Cc: Project File I, Parcel Map No. 31116
Page 1 of 1
Tity/ 4 4a"
P.O. Box 1504
LA QUINTA, CA 92247-1504
78-495 CALLE TAMPICO
LA QUINTA, CA 92247-1504
May 5, 2010
CP DEVELOPMENT LA QUINTA, LLC
Richard Oliphant
77-564 Country Club Drive, Suite 100
Palm Desert, CA 92211
Re: Parcel Map 31116
Dear Mr. Oliphant:
OFFICE OF THE CITY CLERK
(760) 777-7103
FAX (760) 777-7107
Per authorization from the Public Works Department, the City Clerk's Office has
received warranty bonds in the amounts of $35,135 and $126,056 and hereby
releases Performance Bonds/Riders 2137548 and 2137547 in the respective amounts
of $377,830 and $791,279.
If you have any questions, please call me at (760) 777-7002.
Sincer y
1 0
VERONICAj. MONTECINO, City Clerk
City of La Quinta, California
cc: Tim Jonasson, Public Works Director/City Engineer
Insurance Company of the West
File
Tiht 4 Zi� QuiK&
MEMORANDUM
To: Veronica J. Montecino, CMC, City Clerk
From: Ed Wimmer, Development Services Principal Engineer
Via: �ki m othy R. Jonasson, P.E., Public Works Director/ City Engineer
Date: April 30, 2010
Re: Release of Performance Securities and Retain Warranty
Securities for Parcel Map No. 31 1 16, Centre Pointe
Please release the following Performance securities held in your files for the
above referenced project. The off -site and on -site improvements were
accepted by City Council on March 16, 2010.
The security amounts and the address to the surety company are as follows:
Parcel No. 31116
Type of Bond
Bond No.
Performance Amount
Performance (off -site)
2137548
$377,830
Performance (on -site)
2137547
$791,279
Please retain the attached Warranty securities.
Parcel No. 31116
Type of Bond
Bond No.
Warranty Amount
Warranty (off -site)
213754803
$35,135
Warranty (on -site)
213754702
$126,056
Developer: Mr. Richard Oliphant
CP Development La Quinta, LLC
77-564 Country Club Drive, Suite 100
Palm Desert, CA 92211
Surety Company: Insurance Company of the West
11455 El Camino Real
San Diego, CA 92130-2045
cc: Project File I, Parcel Map No. 31116
Amy Yu, Assistant Engineer 11
T4hf 4 4axhrw
P.O. Box 1504
LA QUINTA, CA 92247-1504
78-495 CALLE TAMPICO
LA QUINTA, CA 92247-1504
May 5, 2010
CP DEVELOPMENT LA QUINTA, LLC
Richard Oliphant
77-564 Country Club Drive, Suite 100
Palm Desert, CA 92211
Re: Parcel Map 31116
Dear Mr. Oliphant:
OFFICE OF THE CITY CLERK
(760) 777-7103
FAX (760) 777-7107
Per authorization from the Public Works Department, the City Clerk's Office hereby
releases the following bonds:
Performance Bond 6373465 in the amount of $7,540 (Dust Control)
Performance Bond 104351624 in the amount of $69,900 (Dust Control)
Performance Bond 104351623 in the amount of $182,080 (Grading)
If you have any questions, please call me at (760) 777-7002
Sincere y
VERONICA . MONTECINO, City Clerk
City of La Quinta, California
cc: Tim Jonasson, Public Works Director/City Engineer
Safeco Insurance Company of America
Travelers Causality & Surety Company of America
File
164Q vtu.ntl - O
jj. — yew
4199,o80
fi+ -0
n�a .
T4ht 4 4wQ"
MEMORANDUM
To: Veronica J. Montecino, CMC, City Clerk
From: EEdd Wimmer, Development Services Principal Engineer
Via: 6 Wnothy R. Jonasson, P.E., Public Works Director/ City Engineer
Date: April 30, 2010
Re: Release of Grading and PM-10 Dust Control Securities
Parcel Map No. 31 1 16, Centre Pointe
Please release the following grading and PM-10 securities held in your files
for the above referenced project. The off -site and on -site improvements
were accepted by City Council on March 16, 2010.
The security amounts and the address to the surety company are as follows:
Parcel No. 31116
Type of Bond
Bond No.
Performance Amount
Grading
104351623
$182,080
PM-10
104351624
$69,900
Developer: Mr. Richard Oliphant
CP Development La Quinta, LLC
77-564 Country Club Drive, Suite 100
Palm Desert, CA 92211
Contractor: Turner Construction Company
1900 S. State College Blvd.
Anaheim, CA 92806
Surety Company: Travelers Casualty and Surety Company of America
One Tower Square
Hartford, CT 06183
cc: Project File I, Parcel Map No. 31116
Amy Yu, Assistant Engineer 11
T4,ttt 4 4a Q"
MEMORANDUM
To: Veronica J. Montecino, CMC, City Clerk
From: Ed Wimmer, Development Services Principal Engineer
Via: AM othy R. Jonasson, P.E., Public Works Director/ City Engineer
Date: April 30, 2010
Re: Release of PM-10 Dust Control Security
Parcel Map No. 31 1 16, Desert Villas
Please release the following PM-10 security held in your files for the above
referenced project. The Desert Villas project is now Tract Map No. 36089
and the new developer of the Desert Villas, Dolphin La Quinta, LLC, has
posted with the City a PM-10 dust control cash deposit in the amount of
$10,520.
The security amount and the address to the developer are as follows:
Parcel No. 31116
Type of Bond
Bond No.
Performance Amount
PM-10
6373465
$7,540
Developer: Lennar Homes
391 N. Main St, Suite 300
Corona, CA 92880
cc: Project File I, Parcel Map No. 31116
Amy Yu, Assistant Engineer 11
ri
Tit(t 4 4 Qumz
MEMORANDUM
To: Veronica J. Montecino, CMC, City Clerk
From: Ed Wimmer, Development Services Principal Engineer
Via: �Atothy R. Jonasson, Public Works Director / City Engineer
Date: May 3, 2010
Re: Release of PM-10 Dust Control Cash Deposit
Parcel Map No. 31116, Desert Villas
The PM-10 Dust Control cash deposit in the amount of $3,000 was released
with a check issued by the Finance Department. A copy of the check is
attached for your record.
Cc: Project File I, Parcel Map No. 31116
Amy Yu, Assistant Engineer II
CADocuments and Settings\ayu\Desktop\Cash Deposit Release Memo Lennar PM 31116.doc
TwitXi� Qumm
y oy
. y� DEMAND 1 CHECK. REQUEST
OF
Qti .
Return check to requestor Mail check
Name / Title of person requesting check
Department individual is associated with:
`Tuhli«erLs
Check payable to:
Law dxa�s
(Name) p (Vendor o.)
(Address)
Comna
Check description and invoice number:
rF V I (I as (Aht ors
m
Amount: $ '30p u
Account Number: f — ODOD- ZZ S. % Zi OD
Project Number: 0& "— DI I
Receives( IOM-10 Ca54 delDc'J+ MPIO(CerH -��rQm 'GJo�lp�t`�v� �`frters
Signature:
.tip----
artent a
0 1-23( 0C)
( ate)
APPROVED FOR PAYMENT
(Finance Department Use Only)
BY,
BY:
ACCOUNT NO.
DESCRIPTION
l,ity c�o�a �uinta CHECK NO. 85131
LENNAR HOMES
4006
DATE INVOICE ACCOUNT DESCRIPTION
10/30/09 PM31116 101-0000-228-10.00 06-011 DEV DEP
Petrie. Of Prn -1 o (cpD5lf
beSe-r+ Vi I IG.S ( Rz!,t pF Centrc 'PD i h-i,--
11/10/2009
AMOUNT
3,000.00
DOCUMENT HAS A COLOREDBACKGROUND.ON
3� KNELLS FARGO BANK 851 V
{ 1
1f-24ds TOM 1
CHECK NO.
P.O. BOX 1504
78-495 CALLE TAMPICO DATE AMOUNT
LA QUINTA, CA 92247 11/10/2009 $*'***3, 000.00
CFkoF ° 1780) 777-7150
PAY mm,
TO
THE LENNAR HOMES
ORDER 391 N. MAIN ST., STE 300
OF CORONA CA 92880
AUTHORIZED 51 ATU
. M -�P- 6axAl--
AUTHOMIZEDYIGNATURE 3
II100008 5 L 3 LII' 1: L 2 1000 2481: L. L 5 9 213 2 t,8 211'
CASH DEPOSIT STATUS SHEET*
Budget Account No. 101-000-261-
DIN:31116 Project Location: Desert Villas (Part of Centre Pointe) PM 31116
Developer: LENNAR HOMES, 40004 COOK STREET; PALM DESERT, CA 92211
❑CASH SECURITY - DESCRIPTION OF OBLIGATION PROMPTING DEPOSIT
I ®Dust control; ❑As -built plans; ❑Removal of temporary improvements I
Other
❑CASH PAYMENT - DESCRIPTION OF OBLIGATION PROMPTING DEPOSIT
DATE
DEPOSIT
DEBIT
BALANCE
Amount
Receipt #
11/4/05
$3,000.00
$3,000.00
COMMENTS THIS IS MORE THAN 25%, SEE BOND FOR 7540. TOTAL OF -'5.27ACRES DISTURBED.
Cash deposits placed in City administered trust accounts are typically received for two basic reasons: 1) CASH SECURITY- to provide a source of funds for the City
to draw upon if the City incurs costs satisfying obligations of the developer, or 2) CASH PAYMENT- to provide a source of funding for improvements, property, or
services to be acquired, or administered, by the City at the developer's expense. The City will release the fund balance when the developer's obligations that
prompted the cash deposit are fully satisfied. The release function is initiated via the Request/Demand for Release of Cash Deposit (Form F058)
F059 8/00
FINANCE
Revenue Code
CASH DEPOSIT STATUS SHEET*
DIN:31116 Project Location: Desert Villas (Pz
Developer: LENNAR HOMES, 40004 COOK S'
❑CASH SECURITY - DESCRIPTION O
Dust control; ❑As -built plans; ❑Rt
Other
❑CASH PAYMENT - DESCRIPTION OF
DEPOSI"
DATE I Amount
11/4105 1 $3,000.00
C11Y OF LA 11CIINTA
*** CUSfONER RECEIPT
Date: 11/08/05 01 Receipt no: 4781
Customer Location Name Amount
2173 2173 LENNAR HOMES PRDJ #0
AD A/R DEVELOPER DE -POSITS
Trans number:
i3000.00
43391
LENNAR/DEV DEP PROD #06-011
Tender detail
CK UECK 3-18314 $3000.00
fetal tendered $3000.00
Total payment f3000.00
franc date: 11/08/05 Time: 9:47:18
*** 1 K4W YW FOR YOUR PAYMENT **t
w,.�,aww�+.rororoaaa►roaaaar�.a+rawr�rwvaryw�.n.m
PAYM9EMS RECEIVED AFTER 3 P.M. WILL
BE POSFED TO THE NEXT DAY'S ACTIVITY
11-000-261-
COMMENTS THIS IS MORE THAN 25%, SEE BOND FOR 7540. TOTAL OF—5.27ACRES DISTURBED.
Cash deposits placed in City administered trust accounts are typically received for two basic reasons: 1) CASH SECURITY- to provide a source of funds for the City
to draw upon if the City incurs costs satisfying obligations of the developer, or 2) CASH PAYMENT- to provide a source of funding for improvements, property, or
services to be acquired, or administered, by the City at the developer's expense. The City will release the fund balance when the developer's obligations that
prompted the cash deposit are fully satisfied. The release function is initiated via the Request/Demand for Release of Cash Deposit (Form F058)
&t46 A a«3
F059 8100
Bond #2137548
Premium $7,795.00
SUBDIVISION IMPROVEMENTS
Parcel Map No. 31116
PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS:
THAT, the City Council of the City of La Quinta has approved the final map for Parcel Map
No. 31116 , prior to installation of certain designated public improvements required by the
Conditions of Approval for the subject map, in accordance with the California Map Act (Government Code
Section 66462)
WHEREAS, the City Council of the City of La Quinta, State of California, and
CP DPVP 1 ni mc-nt. La Qn i nta LLc a ('-a1Jfqrnia LLC hereinafter designated as ("principal")
have entered into an agreement whereby principal agrees to install and complete certain designated public
improvements, which said agreement, dated Marr•hl , 200ri. , and identified as
Parcel Map No. �, , , , is hereby referred to and made a part hereof; and
WHEREAS, said principal is required under the terms of said agreement to furnish a bond for the
faithful performance of said agreement.
NOW, THEREFORE, we, the principal and Insurance Company of the West ,
as surety, are held and firmly bound unto the City of La Quinta hereinafter called ("City"), in the penal sum
Of Five Hundred Sixty Thousand Four Hundred TenDOLLARS ($ 560 , 410.00 * * * * * *) lawful
money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our
heirs, successors, executors and administrators, jointly and severally, firmly by these presents.
The condition of this obligation is such that if the above bounded principal, his or its heirs, executors,
administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and
perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as
therein provided, on his or their part, to be kept and performed at the time and in the manner therein
specified, and in all respects according to their true intent and meaning, and shall indemnify and save
harmless the City, its officers, agents and employees, as therein stipulated, then this obligation shall become
null and void; otherwise it shall be and remain in full force and effect.
As a part of the obligation secured hereby and in addition to the face amount specified therefor, there
shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred
by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment
rendered.
F201 - Performance Bond Page 1 of 2
Bond #2137548
Premium included in
Performance Bond
SUBDIVISION IMPROVEMENTS
Parcel Map No. 31116
LABOR AND MATERIAL BOND
KNOW ALL MEN BY THESE PRESENTS:
THAT, the City Council of the City of La Quinta has approved the final map for Parcel Map
No. 31116 , prior to installation of certain designated public improvements required by the
Conditions of Approval for the subject map, in accordance with the California Map Act (Government Code
Section 66462)
WHEREAS, the City Council of the City of La Quinta, State of California, and
cP hereinafter designated as "the principal" have
enteredinto an agreement whereby the principal agrees to install and complete certain designated public
improvements, which agreement, dated March 1, 200 5, and identified as Parcel Map
No. 31116 , is hereby referred to and made a part hereof; and
WHEREAS, under the terms of the agreement, the principal is required before entering upon the
performance of the work, to file a good and sufficient payment bond with the City of La Quinta to secure the
claims to which reference is made in Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the
Civil Code of the State of California.
NOW, THEREFORE, the principal and the undersigned as corporate surety, are held firmly bound
unto the City of La Quinta and all contractors, subcontractors, laborers, materialmen, and other persons
employed in the performance of the agreement and referred to in Title 15 (commencing with Section 3082)
of Part 4 .of Division 3 of the Civil Code in the sum ofFive Hundred Sixty Thousand Four Hundred Ten
& no/10001-LARS ($ 560, 410.00**** ), for materials furnished or labor thereon of any kind, or for
amounts due under the Unemployment Insurance Act with respect to this work or labor, that the surety will
pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought
upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees,
including reasonable attorney' s fees, incurred by city in successfully enforcing this obligation, to be awarded
and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered.
It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all
persons, companies, and corporations entitled to file claims under Title 15 (commencing with Section 3082)
of Part 4 of Division 3 of the Civil Code, so as to give a right of action to them or their assigns in any suit
brought upon this bond.
Should the condition of this bond be fully performed, then this obligation shall become null and void,
otherwise it shall be and remain in full force and effect.
F202 - Labor and Material Bond Page 1 of 2
Bond # 2137547
Premium: $26,793.00
SUBDIVISION IMPROVEMENTS
Parcel Map No. 31116
PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS:
3 11 , the City Council of the City of La Quinta has approved the final map for Parcel Map
No. 3 16 , prior to installation of certain designated public improvements required by the
Conditions of Approval for the subject map, in accordance with the California Map Act (Government Code
Section 66462)
WHEREAS, the City Council of the City of La Quinta, State of California, and
CP Development La Quinta LLC a California LLC
hereinafter designated as ("principal")
have entered into an agreement whereby principal agrees to install and complete certain designated public
improvements, which said agreement, dated Ma rah i , 200� , and identified as
Parcel Map No. ti , is hereby referred to and made a part hereof; and
WHEREAS, said principal is required under the terms of said agreement to furnish a bond for the
faithful performance of said agreement.
NOW, THEREFORE, we, the principal and Insurance Company of the West
as surety, are held and firmly bound unto the City of La Quinta hereinafter called ("City"), in the penal sum of
Two Million Twenty Two Thousand Five Hundred Seventy DOLLARS ($2,220,570.00**** lawful
money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our
heirs, successors, executors and administrators, jointly and severally, firmly by these presents.
The condition of this obligation is such that if the above bounded principal, his or its heirs, executors,
administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and
perform the covenants, conditions and provisions in the said agreement and any alteration thereof made as
therein provided, on his or their part, to be kept and performed at the time and in the manner therein
specified, and in all respects according to their true intent and meaning, and shall indemnify and save
harmless the City, its officers, agents and employees, as therein stipulated, then this obligation shall become
null and void; otherwise it shall be and remain in full force and effect.
As a part of the obligation secured hereby and in addition to the face amount specified therefor, there
shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred
by City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment
rendered.
F201 - Performance Bond Page 1 of 2
Bond #2137547
Premium included
in Performance Bond
SUBDIVISION IMPROVEMENTS
Parcel Map No. -1111 ,;
LABOR AND MATERIAL BOND
KNOW ALL MEN BY THESE PRESENTS:
THAT, the City Council of the City of La Quinta has approved the final map for Parcel Map
No. 31116 , prior to installation of certain designated public improvements required by the
Conditions of Approval for the subject map, in accordance with the California Map Act (Government Code
Section 66462)
WHEREAS, the City Council of the City of La Quinta, State of California, and
CP Development La Quinta LLC A California LLC hereinafter designated as "the principal" have
entered into an agreement whereby the principal agrees to install and complete certain designated public
improvements, which agreement, dated Marr•h 1, 200L, and identified as Parcel Map
No. 31116 , is hereby referred to and made a part hereof; and
WHEREAS, under the terms of the agreement, the principal is required before entering upon the
performance of the work, to file a good and sufficient payment bond with the City of La Quinta to secure the
claims to which reference is made in Title 15 (commencing with Section 3082) of Part 4 of Division 3 of the
Civil Code of the State of California.
NOW, THEREFORE, the principal and the undersigned as corporate surety, are held firmly bound
unto the City of La Quinta and all contractors, subcontractors, laborers, materialmen, and other persons
employed in the performance of the agreement and referred to in Title 15 (commencing with Section 3082)
of Part 4 of Division 3 of the Civil Code in the sum of Twn Mi 1 1 i an Tqn ahnnsand si x. •HunrlrPrl &
No/100---DOLLARS ($ 2;, 010, 600.00** f, for materials furnished or labor thereon of any kind, or for
amounts due under the Unemployment Insurance Act with respect to this work or labor, that the surety will
pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought
upon this bond, will pay, in addition to the face amount thereof, costs and reasonable expenses and fees,
including reasonable attorney' s fees, incurred by city in successfully enforcing this obligation, to be awarded
and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered.
It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all
persons, companies, and corporations entitled to file claims under Title 15 (commencing with Section 3082)
of Part 4 of Division 3 of the Civil Code, so as to give a right of action to them or their assigns in any suit
brought upon this bond.
Should the condition of this bond be fully performed, then this obligation shall become null and void,
otherwise it shall be and remain in full force and effect.
F202 - Labor and Material Bond
Page 1 of 2
FAITHFUL PERFORMANCE BOND
(LQMC 6.16)
Bond No. 104351624
Premium: $1,328.00
Fugitive Dust Control Bond
WHEREAS, the City of La Quinta, California, is prepared to authorize Turner Construction Company
400 Exchange, Ste. 250, Irvine, CA 92602 , as Principal, to proceed with certain construction activities
pursuant to one, or more permits issued by the City, for various infrastructure improvements and/or
structures on, or associated with, privately -owned property generally known to the City and others as
and WN6 & 014ts&S c+ of tl4e_ a��F
5�crioN Iq j w s�►}� � 50 �.'KANG�"'%' S,A►5i, 'S •'i3.M.
WHEREAS, all such construction and demolition activities must be performed in such
manner as to conform with La Quinta Municipal Code, Chaper 6.16, entitled Fugitive Dust Control to
reduce fugitive dust and corresponding PM10 emissions; and
WHEREAS, said Principal is required by LQMC 6.16.050(A)(4) to ensure that Fugitive
Dust Control Plan # 04 0'� 3 , prepared specifically for the subject construction site, is financially
secure by furnishing security for the faithful performance of the dust control activitities required in the
Fugitive Dust Mitigation Plan.
NOW, therefore, we the Principal and Travelers Casualty and Surety Company of America
as Surety, are held and firmly bound unto the City of La Quinta, as Obligee, in the penal
Sum of Sixty Nine Thousand Nine Hundred and No/100
Dollars ($69,900.00 ) lawful money of the United States, for the payment of which sum well and truly
to be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally,
firmly by these presents.
The condition of this obligation is such that if the above bonded Principal, his or its heirs, executors,
administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep
and perform the covenants, conditions and provisions in the said dust control plan and any alteration
thereof made as therein provided, on his or their part, to be kept and performed at the time and in the
manner therein specified, and in all respects according to their true intent and meaning, and shall
indemnify and save harmless the Obligee, its officers, agents and employees, as therein stipulated, then
this obligation shall become null and void; otherwise, it shall be and remain in full force and effect.
As a part of the obligaton secured hereby and in addition to the face amount specified therefor, there
shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred
by the Obligee in successfully enforcing such obligation, all to be taxed as costs and included in any
judgement rendered.
The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the
terms of the dust control plan or to the work to be performed thereunder or the specifications
accompanying the same shall in anywise affect its obligations on this bond, and it does hereby waive
notice of any such change, extension of time, alteration or addition to the terms of the dust control plan or
to the work, the specifications, or the conditions of approval of said plan.
Page 1 of 2
F211
FAITHFUL PERFORMANCE BOND
(LQMC 8.02.01 & CBC 3311)
Bond No. 104351623
Premium: $3,460.00
Grading Bond
WHEREAS, the City of La Quinta, California, is prepared to issue Encroachment Permit
# in accordance with the La Quinta Municipal Code, and the California Building Code which is
adopted by reference, to Turner Construction Company , as Principal,
whereby Principal will be authorized to perform certain grading improvements identified in the permit, and
as further detailed on the grading lans re fe enced therein, to privately -owned property generally known
to the City d others as 3�; and BCtN6 X 01g1& P c$:,A� f�P.hoh)
t11'k. 4 � S� d c�. r -M jP s 'SitkM 1 �� -7 CA`si'' S. a. Nt .
WHEREAS, Said Principal is required under the terms of the permit to furnish a bond for
the faithful performance of the grading work in accordance with the approved plans, specifications, and
permit requirements; or, if the work is abandoned (not completed as required), Principal shall correct or
eliminate any hazardous conditions that may exist.
NOW, therefore, we the Principal and Travelers Casualty and Surety Company of America
as Surety, are held and firmly bound unto the City of La Quinta, as Obligee, in the penal
sum of One Hundred Eighty Two Thousand Eighty and No/100
Dollars ($182,080.00 ) lawful money of the United States, for the payment of which sum well and truly to
be made, we bind ourselves, our heirs, successors, executors and administrators, jointly and severally,
firmly by these presents.
The condition of this obligation is such that if the above bonded Principal, his or its heirs, executors,
administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep
and perform the covenants, conditions and provisions in the said permit and any alteration thereof made
as therein provided, on his or their part, to be kept and performed at the time and in the manner therein
specified, and in all respects according to their true intent and meaning, and shall indemnify and save
harmless the Obligee, its officers, agents and employees, as therein stipulated, then this obligation shall
become null and void; otherwise, it shall be and remain in full force and effect.
As a part of the obligaton secured hereby and in addition to the face amount specified therefor, there
shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred
by the Obligee in successfully enforcing such obligation, all to be taxed as costs and included in any
judgement rendered.
The surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the
terms of the permit or to the work to be performed thereunder or the specifications accompanying the
same shall in anywise affect its obligations on this bond, and it does hereby waive notice of any such
change, extension of time, alteration or addition to the terms of the permit or to the work or to the
specifications.
Page 1 of 2
F210-1