The URL can be used to link to this page

Weitz Golf/Palmer Golf Course Construction 04SECTION 1300 AGREEMENT THIS CONTRACT, by and between the LA QUINTA REDEVELOPMENT AGENCY, herein referred to as "Agency" and Weitz Golf Construction, herein referred to as "Contractor." WITNESSETH: In consideration of their mutual covenants, the parties hereto agree as follows: 1. Contractor shall furnish all necessary labor, material, equipment, transportation and services for Project No. 2002-07C SilverRock Ranch Golf Course No. 1, in the City of La Quinta, California pursuant to the Invitation to Bid, dated February 18, 2004, the project Specifications, and Contractor's Bid, dated March 12, 2004, all of which documents shall be considered a part hereof as though fully set herein. Should any provisions of Contractor's Bid be in conflict with the Notice Inviting Bids, Specifications, or this Contract, then the provisions of said Contract, Specifications, and Invitation to Bid shall be controlling, in that order of precedence. The time frame for construction work shall be in accordance with that specified in the Invitation to Bid. 2. Contractor will comply with all Federal, State, County, and La Quinta Municipal Code, which are, as amended from time to time, incorporated herein by reference. 3. All work shall be done in a manner satisfactory to the City Engineer. 4. Contractor shall commence work after the issuance of a written Notice to Proceed and agrees to have all work completed within the specified 214 consecutive calendar days completion time period. 5. In consideration of said work, Agency agrees to pay Contractor such sums as shall be approved by the City Engineer at lump sums and/or unit prices stated in the Contractor's Bid, the base consideration of Eleven Million Three Hundred Twenty -One Thousand Four Dollars ($11,321,004.00). All payments shall be subject to approval by the City Engineer and shall be in accordance with the terms, conditions, and procedures provided in the Specifications. 6. The Contractor shall not knowingly pay less than the general prevailing rate for per diem wages, as determined by the State of California Department of Industrial Relations and referred to in the Invitation to Bid, to any workman employed for the work to be performed under this contract; and the Contractor shall forfeit as a penalty to the Agency the sum of Twenty -Five Dollars ($25.00) for each calendar day, or fraction thereof, for such workman paid by him or by any subcontractor under him in violation of this provision (Sections 1770-1777, Labor Code of California). 7. Concurrently with the execution of this Contract, Contractor shall furnish bonds of a surety satisfactory to Agency, as provided in said Specifications or Invitation to Bid, the cost of which shall be paid by Contractor. 8. Contractor shall defend, indemnify and hold harmless the Agency, its officers, employees, representatives and agents ("Indemnified Parties"), from and against those actions, suits, proceedings, claims, demands, losses, costs, and expenses, including legal costs and attorneys' fees, for injury to or death of person(s), for damage to property (including property owned by Agency) and for errors and omissions committed by Consultant, its officers, employees and agents, which arise out of Consultant's negligent performance under this Agreement, except to the extent of such loss as may be caused by Agency's own negligence or that of its officers or employees. In the event the Indemnified Parties are made a party to any action, lawsuit, or other adversarial proceeding in any way involving such claims, Consultant shall provide a defense to the Indemnified Parties, or at the Agency's option, reimburse the Indemnified Parties their costs of defense, including reasonable attorney's fees, incurred in defense of such claim. In addition, Consultant shall be obligated to promptly pay any final judgment or portion thereof rendered against the Indemnified Parties. Agreement 1300-1 9. Except as otherwise required, Contractor shall concurrently with the execution of this contract, furnish the Agency satisfactory evidence of insurance of the kinds and in the amounts provided in said Specifications. This insurance shall be kept in full force and effect by Contractor during this entire contract and all premiums thereon shall be promptly paid by it. Each policy shall further state that it cannot be canceled without 30 days unconditional written notice to the Agency and shall name the Agency as an additional insured. Contractor shall furnish evidence of having in effect, and shall maintain, Workers Compensation Insurance coverage of not less than the statutory amount or otherwise show a certificate of self-insurance, in accordance with the Workers Compensation laws of the State of California. Failure to maintain the required amounts and types of coverage throughout the duration of this Contract shall constitute a material breach of this Contract. 10. Contractor shall forfeit as a penalty to Agency $25.00 for each laborer, workman, or mechanic employed in the execution of this Contract by said Contractor, or any subcontractor under it, upon any -of the work herein mentioned, for each calendar day during which such laborer, workman, or mechanic is required or permitted to work at other than a rate of pay provided by law for more than 8 hours in any one calendar day and 40 hours in any one calendar week, in violation of the provisions of Sections 1810-1815 of the Labor Code of the State of California. 11. In accepting this Contract, Contractor certifies that in the conduct of its business it does not deny the right of any individual to seek, obtain and hold employment without discrimination because of race, religious creed, color, national origin, ancestry, physical handicap, medical condition, marital status, sex or age as provided in the California Fair Employment Practice Act (Government Code Sections 12900, et seq.) Contractor agrees that a finding by the State Fair Employment Practices Commission that Contractor has engaged during the term of this Contract in any unlawful employment practice shall be deemed a breach of this Contract and Contractor shall pay to Agency $500.00 liquidated damages for each such breach committed under this contract. 12. Contractor also agrees that for contracts in excess of $30,000 and more than 20 calendar days duration, that apprentices will be employed without discrimination in an approved program in a ratio established in the apprenticeship standards of the craft involved (Sections ' 1777.5 and 1777.6, Labor Code of California). Contractors who willfully fail to comply will be denied the right to bid on public projects for a period of six months in addition to other penalties provided by law. 13. This Contract shall not be assignable by Contractor without the written consent of Agency. 14. Contractor shall notify the City Engineer (in writing) forthwith when the Contract is deemed completed. 15. In accepting this Contract, Contractor certifies that no member or officer of the firm or corporation is an officer or employee of the Agency except to the extent permitted by law. 16. Contractor certifies that it is the holder of any necessary California State Contractor's License and authorized to undertake the above work. 17. The Agency, or its authorized auditors or representatives, shall have access to and the right to audit and reproduce any of the Contractor records to the extent the Agency deems necessary to insure it is receiving all money to which it is entitled under the contract and/or is paying only the amounts to which Contractor is properly entitled under the Contract or for other purposes relating to the Contract. 18. The Contractor shall maintain and preserve all such records for a period of at least three years after termination of the contract. 19. The Contractor shall maintain all such records in the Agency of La Quinta. If not, the Contractor shall, upon request, promptly deliver the records to the Agency or reimburse the Agency for all reasonable and extra costs incurred in conducting the audit at a location other than at Agency offices including, but not limited to, such additional (out of the Agency) expenses for personnel, salaries, private auditors, travel, lodging, meals and overhead. 20. The further terms, conditions, and covenants of the Contract are set forth in the Contract Documents, each of which is by this reference made a part hereof. Agreement 1300-2 IN WITNESS WHEREOF, the parties have executed this Agreement as of the dates stated below. Dated: ATTEST: 4-s-4 * "AGENCY" By: T ry Henderson, Chairperson P—E,� A, , d) Dated: '4 - P - 04 Juneka..Adek, Agency Secretary APPROVED AS TO FORM: Agency Colinsel Dated: Dated: A0*-1 -?—, , "o; &,, K If r By: Na e• Me: Dated: By: Name: Title: (If corporation, affix seal) Agreement 1300-3 SECTION 1310 FAITHFUL PERFORMANCE BOND 1.) FEDERAL BOND NO. 8187-60-84 2.) ST . PAUL FIRE & MARINE BOND NO. 400SY3928 KNOW ALL MEN BY THESE PRESENTS: THAT the La Quinta Redevelopment Agency, hereinafter designated the Agency, has, on March 16, 2004, awarded to Weitz Golf Construction, hereinafter designated as the Principal, a Contract for Project No. 2002-07C SilverRock Ranch Golf Course No. 1, and WHEREAS, said Principal is required under the terms of said Contract to furnish a bond for the faithful performance of said Contract: 1.) FEDERAL INSURANCE COMPANY NOW, THEREFORE, we, the Principal, and 2.) ST . PAUL FIRE & MARINE INSURANCE COMPANY as Surety, are held and firmly bound unto the Agency in the just and full amount of Eleven, Million Three Hundred Twenty -One Thousand Four Dollars ($11,321,004.00) lawful money of the United States, for the, payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if said Principal, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and abide by, and well and truly keep and faithfully perform the covenants, conditions, and agreements in the said contract and any alterations made as therein provided, on his or their part to be kept and performed, at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless, the Agency, its officers and agents as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue. It is acknowledged that the Contract provides for one-year guarantee period, during which time this bond remains in full force and effort. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time,, alteration, or addition to the terms of the Contract or to the work to be performed thereunder or the specifications accompanying the same shall, in any way, affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition to the terms of the Contract or to the woix or to the specifications. Said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of California. Faithful Performance Bond 1300-4 IN WITNESS WHEREOF, the Principal and Surety have executed this instrument under their seals this 19TH _ day of MARCH , 20 04 , the name and corporate seal of each corporate. party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. T.MTT7 r-nT T'i ('nwCTPTTrTTnM TATr (Seal) Title of Signatory 1.) FEDERAL.INSURANCE COMPANY SIGNATURE AR SURETY (Seal) 2.) ST. PAUL FIRE & MARINE INSURANCE COMPANY �4 Signature fbow&y MALCOLM G. MCCAMPBELL, ATTORNEY —IN —FACT Title of Signatory 1.) FEDERAL INSURANCE COMPANY2.15 MOUNTAIN VIEW ROAD, WARREN, NJ 07059 2.) ST. PAUL FIRE & MARINE INSURANCE COMPANY, 385 WASHINGTON STREET, MAIL CODE 105D, ST. PAUL MN Address of Surety 55102 2.) ST. PAUL FIRE & MARINE (800) 356-4098 1.) FEDERAL INSURANCE COMPANY (908) 903-3485 Phone Number of Surety Contact Person For Surety MALCOLM G. MCCAMPBELL C/O ACORDIA 501 S. FLAGLER DRIVE, SUITE 600 WEST PALM BEACH, FL 33401 TEL (561) 655-5500 Faithful Performance Bond 1300-5 SECTION 1320 PAYMENT BOND 1.) FEDERAL BOND NO. 8187-60784 2.) ST. PAUL FIRE & MARINE BOND NO. 400SY3928 KNOW ALL MEN BY THESE PRESENTS: THAT the La Quinta Redevelopment Agency, hereinafter designated the Agency, has, on�March 16, 2004, awarded to Weitz Golf Construction, hereinafter designated as the Principal, a Contract for Project Nii. 2002-07C SilverRock Ranch Golf Course No. 1, and WEMREAS, said Principal is required to fiunish a bond in connection and with said Contract, providing that if said Principal, or any of it or its subcontractors shall fail to pay for any materials, provisions, or other supplies used in, upon, for, or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety of this bond will pay the same to the extent hereinafter set forth: 2.) ST PAUL .FIRE. `:N; ,MARINE :..INSURANCE COMPANY NOW, THEREFORE,we, the Principal, and 1.) FEDERAL' INSURANCE COMPANYas Surety, are held and firmly bound unto the Agency in the just and full amount of Eleven Million Three Hundred Twenty -One Thousand Four Dollars ($11,321,004.00) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if said Principal, it or its heirs, executors, administrators, successors, or assigns, shall fail to pay for any materials, provisions, or other supplies used in, upon, for, or about the performance of the work contracted to be done, or for any work or labor thereon of any kind or for amount due under the Unemployment Insurance Act with respect to such work or labor, or for any amounts due, or to be withheld pursuant to Sections 18806 of the Revenue and Taxation Code of the State of California with respect to such work or labor, then said surety will pay the same in or to an amount not exceeding the amount hereinabove set forth, and also will pay in case suit is brought upon this bond, such reasonable attorney's fees to the Agency as shall be fixed by the court. This bond shall insure to the benefit of any and all persons, companies, and corporations named in Section 3181 of the Civil Code of the State of California so as to give a right of action to them or their assigns in any suit brought upon this bond. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, .or addition of the terms of the Contract or to the work to be performed thereunder or the specifications accompanying the same shall, in any way, affect its obligations of this bond, and it does hereby waive notice of any change, extension of time, alteration, or addition to the terms of the contract or to the work or to the specifications. Said Surety hereby waives the provisions of Sections 2819 and 2945 of the Civil Code of the State of California. Payment Bond 1300-6 IN VvTrNESS WHEREOF, the Principal and Surety have executed this instrument under their seals this 19TH day of MARCH , 20 04 , the name and corporate seal of each corporate party being hereto affixed and these ?resents duly signed by its undersigned representative, pursuant to authority of its governing body. (Seal) WRTT7 WT.F rnNSTRTTrTTON _ TNC _ Title of Signatory 1.) FEDERAL INSURANCE 9OMPANY Zip SIGNATUR FO SURETY (Seal) 2.) ST. PAUL FIRE & MARINE INSURANCE CO ANY Signature fo Surety MALCOLM G. MCCAMPBELL, ATTORNEY —IN —FACT Title of Signatory 1,) FEDERAL INSURANCE COMPANY, 15 MOUNTAIN VIEW ROAD, WARREN, NJ 07059' 2.) ST. PAUL FIRE & MARINE INSURANCE COMPANY, 385 WASHINGTON STREET, MAIL -..'CODE 105D, ST.PAUL MN 55102 Address of Surety 2.) ST. PAUL FIRE & MARINE (800) 356-4098 1.) FEDERAL INSURANCE COMPANY (908)903341 Phone Numbe. of Surety Contact Person For Surety MALCOLM G. MCCAMPBELL C/O ACORDIA 501 S. FLAGLER DRIVE,.SUITE 600 WEST PALM BEACH, FL 33401 TEL (561) 655-5500 Payment Bond 1300-7 St. Paul Fire and Marine Irsurance Cumpanv United States Fidelity and Guaranty Company $imll Surety St. Paul Cuardisn Insurance Company Fidelity and Guaranty 1nlu1'2nC9 Company St. Paul Mercury Insurance Company Fidelity and Guaranty Insurance Underwriters. Inc. Seaboard Surety Compaq St. Paul Medical Liability Insurance Company Bond No. 400SY3928 RIDER CONTAINING DISCLOSURE NOTICE OF TERRORISM COVERAGE This disclosure notice is required by the Terrorism Risk Insurance Act of 2002. No action is required on your part. This Disclosure Notice is incorporated in and a part of the attached bond. You should know that, effective November 26, 2002, any losses caused by certified acts of terrorism would be partially reimbursed by the United States under a formula established by the Terrorism Risk Insurance Act of 2002. Under this formula, the United States reimburses 90% of covered terrorism losses exceeding the statutorily established deductible paid by the insurance company providing the coverage. There is a cap on our liability to pay for such losses if the aggregate amount of insured losses under the Act exceeds $100,000,000,000 during the applicable period for all insured and all insurers combined. In that case, we will not be liable for the payment of any amount which exceeds that aggregate amount of $100,000,000,000, The portion of your premium that is attributable to coverage for acts of terrorism is $0.00. IMPORTANT NOTE: THE COST OF TERRORISM COVERAGE IS SUBJECT TO CHANGE ON ANY BOND THAT PREMIUM IS CHARGED ANNUALLY. SIGNED AND SEALED this �._9THday of _ SURETY: Signature: Attorney -in -Fact MARCH , 2004. [SEAL] MALCOLM G..MCCAMPBELL, ATTONREY-IN-FACT TnTni r) n-7 This Notice pertains to the following Surety Bond issued hy�amumlyar insurer of the Chubb Group of Insurance Companies, including Federal Insurance Company', Vigilant Insurance Company and Pacific Indemnity Company. Bond Number: 8187-60-84 POLICYHOLDER DISCLOSURE NOTICE TERRORISM RISK INSURANCE ACT OF 2002 You are hereby notified that pursuant to the Terrorism Risk Insurance Act of 2002 (the "Act") effective November 26, 2002, we are making available to you coverage for losses arising out of certain acts of international terrorism. Terrorism is defined as any act certified by the Secretary of the. Treasury, in concurrence with the Secretary of State and the Attorney General of the United States, to be an act of terrorism; to be a violent act or an act that is dangerous to human life, property or infrastructure; to have resulted in damage within the United States, or outside the United States in the case of an air carrier or vessel or the premises of a United States Mission; and to have been committed by an individual or individuals acting on behalf of any foreign person or foreign interest, as part of an effort to coerce the civilian population -of the United States or to influence the policy or affect the conduct of the United States Government by coercion. Coverage for acts of terrorism is already included in the captioned Surety Bond. You should know that, effective November 26, 2002, any losses caused by acts of terrorism covered by your Surety Bond will be partially reimbursed by the United States under the formula set forth in the Act. Under this formula, the United States of America pays 90% of covered terrorism losses that exceed the statutorily established deductible to be paid by the insurance company providing the coverage.. The portion of your premium that. is attributable to coverage for such acts of terrorism is zero, because we could not distinguish (and separately charge for) acts of terrorism from other causes of loss when we calculated your premium. If you have any questions about this notice, please contact your agent or broker. cHuNae Chubb 1,L WI.� iCLICl GI II 1.7 f„11 G116■G VaJ.■■r....■� t-■aa�■.. v.r....•7 ... ..r—. ......... NEW OF Vigilant Insurance Company 15 Mountain View Road Su,ety ATTORNEY pacific Indemnity Company Warren, NJ 07059 Know All by These Presents, That FEDERAL INSURANCE COMPANY, an Indiana =pon."ation, VIGILANT INSURANCE COMPANY, a New York corporation, ar ed PACIFIC INDEMNITY COMPANY, a Wisconsin corporation, do each hereby constitute and appoint Ma i c p 11M. G. McC ampb e ll , Sam L. EI? _ngton and T=ac7 W. Lambert of W. Da1m Beach, 'Flor--4da ------------------------ each as their true and lawful Attomey-in-Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety thereon or otherwise, bonds (other than bail bonds) and undertakings given or executed in the course of its business (but not to Include any instruments amending or altering the same, nor consents to the modification or alteration of any instrument referred to in said bonds or obligations). In Witness Whereof, said FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY have each executed and attested these presents and affixed their corporate seals on this 15 tia day of A-D i i 1, 1999 nneth C. Wend , Assistant Se ,petary S a ATE OF NEiN JERSEY sa. County of Somerset Gerardo G. Maud7, Vice President . On this 13 t1, _ dW of April. 1999 , before me, a Notary Public of New Jersey, pemonaiiy came Kenneth C. Wendel, to me !mown to be Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMr Y OCAVANY, the companies which executed the foregoing Power of Attorney, and the said Kenneth C. Wendel being by. me duty swum, .did depose and sW that he Is Assistant Secretary of FEDERAL INSURANCE CCMPANY, VIGILANT INSURANCtE'COMPANY, and PACIFIC INDEMNITY COMPANY and knows the -corporate seats thereof, that the seals =17b ed to thie foregoing Power of Attorney are such corporate seals and were thereto affbced by authority of the Sy-1.2ws of said Companies; and that he signed. said Power of Attorney as Assistant Secretary of said Companies by Uke authority; and that he is acquainted with Gerardo G. Maurix, and knows him to be Vice. Pmasident of said Companies; and that the signature of Gerardo G. Mauriz, subscribed to said Power of Attomey is in the genuine handwriting of Gerardo G. Mauriz, and was thereto subscribed by authority of said By -Laws anp deponeni's presence. �. Cr HERESA S. CICHOWSIQ e Q . Nat- P.-jbiic, Sts:e of Now Jerst Q-rU ly (D No. t?0'I "'�'[�LTC '''r! Notary Public Z'ee :t F}.JLLiC d`�? Commission E.-cpires July 27, 2001 �� , C CATION Extract from the By -Laws of FEDERAL INSURANCE COMPANY, VIGILANT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY: "AII powers of attorney for and an behalf of the Company may and shall be executed in the name and on behalf of the Company, either by the Chairman or the President or a Vice President or an Assistant Vice President, jointly with the Secretary or an Assistant Secretary, under their respective designations. The signature of such officers may be engraved, printed or lithographed. The signature of each of the following officers: 0-a rman, President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary and the seal of the Company may be affixed by facsimile to any power of attorney or to any. certificate relating thereto appointing Assistant Secretaries or . Attorneys -in -Fact for purposes only of executing and attesting bonds and undertaknge and other writings obligatory In the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached." I, Kenneth C. Mendel, Assistant Secretary of FEDERAL INSURANCE COMPANY, VIGiLkNT INSURANCE COMPANY, and PACIFIC INDEMNITY COMPANY (the 'Companies') do hereby car* dint the foregoing extract of the By -Lawn of the Companies is true and correct, the Ccmpaniesi are duly kweed and aged to transact surely business In all SO of the United States of America and the District of Columbia and are audxxtzed by the U. S. Treasury Department; furdw, Federal and Vigilant are licensed in Puerto Firs and the i.i. S. virgin Islands, and Federal Is ker,.� in Anwkmn Samoa, Guam, and each of the Provirtcas of Cara evept Prince Edward Wam and (10 the foregoing Power of Attorney is true, correct and In full force and effect Given under my hand and seals of said Companies at Warren, NJ this 19TH day of MARCH, 2004 ,5t}I�1C.� aEltr/ft ��,gL1AANCtr w T enneth C. Wendel, Aiisistani Secretary IN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM, VERIFY THE AUTHEN T ICa T Y OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER, PLEASE CONTACT US AT ADDRESS LISTED ABOVE, OR BY Telephone (908) 903-3485 Fax (908) 903-3656 e-mail: suretypc■hubb.com Form 1&1"568 (Ed. 1-m NON-rANSENT meStPAuI Power of Attorney No. POWER OF ATTORNEY Seaboard Surety Company St. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company St. Paul Mercury Insurance Company 23661 United States Fidelity and Guaranty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. Certificate No. 1621005 KNOW ALL MEN BY THESE PRESENTS: That Seaboard Surety Company is a corporation duly organized under the laws of the State of New York, and that St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company and St. Paul Mercury Insurance Company are corporations duly organized under the laws of the State of Minnesota, and that United States Fidelity and Guaranty Company is a corporation duly organized under the laws of the State of Maryland, and that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance Underwriters, Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies'), and that the Companies do hereby make, constitute and appoint Malcolm G. McCampbell, Sam L. Ellington, and Tracy Lambert of the City of west Palm Beach , State Florida, their true and lawful AttomeY()s -n-Fact, i each in their separate capacity if more than one is named above, to sign its name as surety to, and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertaking&ed or itted i y actions or proceedings allowed by law. 20`h December 2002 IN WITNESS WHEREOF, the Companies have caused this instrum it se eli day of , Seaboard Surety Company 'VAnited States Fidelity and Guaranty Company St. Paul Fire and Marine Ins o Fidelity and Guaranty Insurance Company St. Paul Guardian Insuran ei Fidelity and Guaranty Insurance Underwriters, Inc. St. Paul Mercury Insurance S1MF�y p� C�'N iNa`+ U1. °�Ar -WA 927 iPETER W. CARMAN, Vice President k� MN� � f1� State of Marylan d City of Baltimore THOMAS E. HUIBREGTSE, Assistant Secretary On this 2e day of December 2002 , before me, the undersigned officer, personally appeared Peter W. Carman and Thomas E. Huibregtse, who acknowledged themselves to be the Vice President and Assistant Secretary, respectively, of Seaboard Surety Company, St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, United States Fidelity and Guaranty Company, Fidelity and Guaranty Insurance Company, and Fidelity and Guaranty Insurance Underwriters, Inc.; and that the seals affixed to the foregoing instrument are the corporate seals of said Companies; and that they, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing the names of the corporations by themselves as duly authorized officers. In Witness Whereof, I hereunto set my hand and official seal. My Commission expires the 1 st day of July, 2006. �9E 0ir0 REBECCA EASLEY ONOKALA, Notary Public 86203 Rev. 7-2002 Printed in U.S.A. SECTION 1330 WORKERS' COMPENSATION INSURANCE CERTIFICATE In accordance with California Labor Code Section 1861, prior to commencement of work on the Contract, the Contractor shall sign and file with the Agency the following certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." va.= r Signature Title ,—T 2W 4- Date Workers' Compensation Insurance 1300-8 SECTION 1340 LIABILITY AND INSURANCE REQUIREMENTS 1.0 INDEMNIFICATION The Contractor shall indemnify, hold harmless and assume the defense of the Agency, its elected officials, officers, agents, and employees from all damages, costs, or expenses in law or equity that may at any time arise to cause damages to property, or of personal injury received by reason of or in the course of performing work, which may be occasioned by any willful or negligent act or omission of the Contractor, any of the Contractor's employees, or any of its subcontractors arising out of work under this Contract. Approval of any insurance contracts by the Agency does not relieve the Contractor or subcontractors from liability under Section 1340-1.0, Indemnification. The Agency will not be liable for any accident, loss, or damage to the work prior to its completion and acceptance. 2.0 INSURANCE REQUIREMENTS 2.1 General After award of Contract, the Contractor shall promptly obtain, at its own expense, all the insurance required by Paragraph 1340-2.0, INSURANCE REQUIREMENTS, and shall submit coverage verification for review and approval by the Agency upon execution of the Contract. The Notice to Proceed with the Work under this Contract will not be issued, and the Contractor shall not commence work, until such insurance has been approved by the Agency. The Contractor shall not allow any subcontractors to commence work on its subcontract until all similar insurance required of the subcontractor has been obtained and verified by Contractor. Such insurance shall remain in full force and effect at all times during the prosecution of the Work and until the final completion and acceptance thereof. The Notice to Proceed does not relieve the Contractor of the duty to obtain such insurance as required by Paragraph 1340-2.0 INSURANCE REQUIREMENTS. 2.2 Commercial General Liability Policy The Contractor shall take out and maintain during the life of the Contract, a Commercial General Liability Policy, on an occurrence basis, with a minimum limit of not less than One Million Dollars ($1,000,000) combined single limit for bodily injury and property damage for any one occurrence and a Two Million Dollar ($2,000,000) annual project aggregate, for all of the following: a. Premises Operations, including Explosion, Collapse and Underground (X, C, and U) Coverage. b. Completed Operations/Products, including X, C, and U Coverage. C. Independent Contractors. d. Blanket Contractual. e. Deductible shall not exceed One Thousand Dollars ($1,000). 2.3 ComIercial Business Auto Policy The Contractor shall take out and maintain during the life of this Contract a Commercial Business Auto Policy, on an occurrence basis, with a minimum amount of not less than One Million Dollars ($1,000,000) combined single limit for bodily injury and property damage, providing at least all of the following coverage: Liability & Insurance Requirements 1300-9 a. Coverage shall be applicable to any and all leased, owned, hired, or non -owned vehicles used in pursuit of any of the activities associated with this Contract. b. Any and all mobile equipment, including cranes, which is not covered under said Commercial Business Auto Policy shall have said coverage provided for under the Commercial General Liability Policy. C. Deductible shall not exceed One Thousand Dollars ($1,000). 2.4 Workers' Compensation Insurance The Contractor shall take out and maintain during the life of the Contract, Worker's Compensation and Employers' Liability insurance providing coverage for any and all employees of Contractor: a. The required policy shall provide coverage for Workers' Compensation (Coverage A). _ b. This policy shall provide coverage for One Million Dollars ($1,000,000) Employers' Liability (Coverage B). 2.5 Endorsements All of the following endorsements are required to be made a part of the policies described in this Section hereof a. "The Agency, Agency employees and officers, the City Engineer, its consultants, elected officials, agents, and sub -consultants are hereby added as additional insured insofar as Work done under this Contract is concerned." b. "This policy shall be considered primary insurance as respects any other valid and collectible insurance, including self -insured retention, the Agency may possess, and any other insurance the Agency does possess shall be considered excess insurance only." C. "This insurance shall act for each insured, and additional insured, as though a separate policy had been written for each. This, however, will not act to increase the limit of liability of the insuring company. d. "Thirty (30) days prior written notice of cancellation shall be given to the Agency. Such notice shall be sent to: Thomas P. Genovese, Executive Director La Quinta Redevelopment Agency P.O. Box 1504 La Quinta, CA 92253 2.6 Change in Terms The Contractor shall provide immediate written notice to the Agency of any change in terms and conditions and/or reduction in the coverage of any nature to the insurance policies. The notice shall be sent to the location identified in Paragraph 1340-2.6.d, Endorsements. The Contractor shall be obligated to pay any extra premium for maintaining the insurance requirements specified herein. Liability & Insurance Requirements 1300-10 ., amxcH.eweyawsc^: '. ...°L9�;: T't�tM• '.S?'":x, �:°%.'.";° °y-� + ,7 �[^'.»`y&v 'Y • • •WWI 03/19/04 """ �" THIS CERTIFICATE 18 ISSUED AS A MATTER OF INFORMATION �� 1-515-ZZ3-6800 ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE Holmes Murphy and 1lssociates HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR - Kest Des Moines ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. P.O. Soar 9207 COMPANIES AFFORDING COVERAGE Des Moines, lk 50306-9207 COMPANY A► Zurich American Insurance Co. INSURED COMPANY B Fireman's Fund The Neit: Company, LLC COMPANY Locust Street, Suite 300 C COMPANY Des Moines, rA 50309 D THAT THE POLICIES OF INSUANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, MAY BE THIS IS TO CERTIFY TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE NOTWITHSTANDING ANY REQUIREMENT, BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. POLICY EFFECTIVE POLICY EXPIRATION LIMITS TYPE OF INSURANCE POLICY NUMBER DATE (MMIDOIYY) DATE (MMIDDrYY) FLTnR AGGREGATE $ GENERAL LIABILITYGENERAL PRODUCTS - COMPIOP AGG $ COMMERCIAL GENERAL LUleum FI PERSONAL a ADv INJURY $ CLAIMS MADE OCCUR EACH OCCURRENCE $ OWNERS a CONTRACTORS PROT $ FIRE DAMAGE WW arm f1m) MED EXP (Any on* person) $ A AUTOMOSILELNSNJTY BAP9374131 06/01/03 06/01/04 COMBINED SINGLE LIMIT $ 1000000 X ANY AUTO ALL OWNW AUTOS BODILY INJURY (P•r w ") i SCHEDULED AUTOS BODILY INJURY (Pw ) $ X HIREDAUTOS z NON-OWNEDAUTOS PROPERTY DAMAGE $ AUTO ONLY - EA ACCIDENT $ OTHER THAN AUTO ONLY: GARAGE LIABWiY ANY AUTO EACH ACCIDENT AGGREGATEEXCESS 7s7 LIABILITYEACH OCCURRENCE AGGREGATE $ UMBRELLA FDRM s OTHIRM" UMBREUAFORM � WC 8TATU- OTH• �.. WORM M COMPENIIATKIN Al"EMFLOYMlS' TORY LIMITS ER EL EACH ACCIDENT LIABWTY $ THE PRIORIETOPJ EL DISEASE - POLICY LIMIT $ PARTNERSIDMCUTNE INCL EL DISEASE - DISEASE $ OFFICERS ARE: EXCL B OTHER Contractors 3quipment UX197903880 06/01/03 06/01/04 Loss Limit -Prop. 2,500,000 DESCRIPTION OF OPERATION:II.OrATIONSNEHICLESISPECIAL ITEMS See attached page Z. law SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL 30 DAYS La Quints. Redevelopment Agency WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO Thomas P Genovese MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE PO Soz 1504 COMPANY ITS AGENTS OR REPRESENTATIVES. La Quint&, CA 92253 AUTHORIZED REPRESENTATIVE I V._ USA ,x WOMEN 01 :. ... + ,,.. or 5770Z 17067$3 PMM ByCe>tirlcatesNOwn" OUTSTANDING BOND REPORT Name: Weitz Golf Construction Tract No. (contract bonds only) Date of Contract: 4/8/04 Required Bond Amounts: $11,321,004 Dates of Bond Reductions: Outstanding Bonds and Bond Company: Federal Insurance Co. / St. Paul Fire & Marine Amount: Bond No. Date Cancelled/Released: $11,321,004 81876084 $11,321,004 (L&M) same Y SECTION 1310 FAITHFUL PERFORMANCE BOND 1.) FEDERAL BOND NO. 8187-60-84 2.) ST. PAUL FIRE & MARINE BOND NO. 400SY3928 KNOW ALL MEN BY THESE PRESENTS: THAT the La Quinta Redevelopment Agency, hereinafter designated the Agency, has, on March 16, 2004, awarded to Weitz Golf Construction, hereinafter designated as the Principal, a Contract for Project No. 2002-07C SilverRock Ranch Golf Course No. 1, and WHEREAS, said Principal is required under the terms of said Contract to furnish a bond for the faithful performance of said Contract: 1.) FEDERAL INSURANCE COMPANY NOW, THEREFORE, we, the Principal, and 2.) ST . PAUL FIRE & MARINE INSURANCE COMPANY as Surety, are held and firmly bound unto the Agency in the just and full amount of Eleven Million Three Hundred Twenty -One Thousand Four Dollars ($11,321,004.00) lawful money of the United States, for the, payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if said Principal, his or its heirs, executors, administrators, successors, or assigns, shall in all things stand to and abide by, and well and truly keep and faithfully perform the covenants, conditions, and agreements in the said contract and any alterations made as therein provided,. on his or their part to be kept and performed, at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless, the Agency, its officers and agents as therein stipulated, then this obligation shall become null and void; otherwise it shall be and remain in full force and virtue. It is acknowledged that the Contract provides for one-year guarantee period, during which time this bond remains in full force and effort. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time,. alteration, or addition to the terms of the Contract or to the work to be performed thereunder or the specifications accompanying the same shall, in any way, affect its obligations on this bond, and it does hereby waive notice of any such change, extension of time, alteration, or addition to the terms of the Contract or to the work or to the specifications. Said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of California. Faithful Performance Bond 1300-4 SECTION 1320 PAYMENT BOND 1.) FEDERAL BOND NO. 8187-60-84 2.) ST. PAUL FIRE & MARINE BOND N0. 400SY3928 KNOW ALL MEN BY THESE PRESENTS: THAT the La Quinta Redevelopment Agency, hereinafter designated the Agency, has, on -March 16, 2004, awarded to Weitz Golf Construction, hereinafter designated as the Principal, a Contract for Project NO.2002-07C SilverRock Ranch Golf Course No. 1, and WHEREAS, said Principal is required to furnish a bond in connection and with said Contract, providing that if said Principal, or any of it or its subcontractors shall fail to pay for any materials, provisions, or other supplies used in, upon, for, or about the performance of the work contracted to be done, or for any work or labor done thereon of any kind, the Surety of this bond will pay the same to the extent hereinafter set forth: 2.) ST :-'PAUL.:FIRE_. �& ":MARINE. INSURANCE COMPANY NOW, THEREFORE, we, the Principal, and 1•) FEDERAL INSURANCE COMPANYas Surety, are held and firmly bound unto the Agency in the just and full amount of Eleven Million Three Hundred Twenty -One Thousand Four Dollars ($11,321,004.00) lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH, that if said Principal, it or its heirs, executors, administrators, successors, or assigns, shall fail to pay for any materials, provisions, or other supplies used in, upon, for, or about the performance of the work contracted to be done, or for any work or labor thereon of any kind or for amount due under the Unemployment Insurance Act with respect to such work or labor, or for any amounts due, or to be withheld pursuant to Sections 18806 of the Revenue and Taxation Code of the State of California with respect to such work or labor, then said surety will pay the same in or to an amount not exceeding the amount hereinabove set forth, and also will pay in case suit is brought upon this bond, such reasonable attorney's fees to the Agency as shall be fixed by the court. This bond shall insure to the benefit of any and all persons, companies, and corporations named in Section 3181 of the Civil Code of the State of California so as to give a right of action to them or their assigns in any suit brought upon this bond. And the said Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or addition of the terms of the Contract or to the work to be performed thereunder or the specifications accompanying the same shall, in any way, affect its obligations of this bond, and it does hereby waive notice of any change, extension of time, alteration, or addition to the terms of the contract or to the work or to the specifications. Said Surety hereby waives the provisions of Sections 2819 and 2845 of the Civil Code of the State of California. Payment Bond 1300-6 000 4 44 Q9&r(V OF 'r9 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 - 07C CONTRACTOR: Weitz Golf International Sheet 1 of 1 CONTRACT CHANGE ORDER NO. # 1 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to perform the dirt filling operation within the BOR right a way along the east side of the All American Canal. The work will be performed in less than 30 days with no additional days to the original contract. Total Quantity of dirt wiU be determined by load counts. Total cu. yds. 22.000. Cost per cu-rd $3.45 = $75.900 No additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 1 $1193219004.00 Add This Change Order No.1 $ 75,900.00 Revised Contract Total $ $11,396,904.00 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is. 11105104 The revised contract completion date shall be: 11/ 05 /04 Submitted By: Date: 05-12-04 Approved By: Date: Xe, the undersigned Contractor, have given ca sideration to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all or, cept as may be noted above, and perform all services necessary to complete the above specified work, and hereby 11 nt he amount s own above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title. AMMVA u J /4 Contractor. Z Date: WM I 'eeay-07-04 09:25am From-WEITZ GOLF INTERNATIONAL T-423 P.02/06 F-382 Construction Change Directive TWC, Detailed, Grouped by Number Page 1 of 1 silver Rock Ranch Golf Course Directive Number: 001 Project # G125000 Date Crested: 4/ 612004 $ever Rook Ranch Golf Course 79.722 Avenue 54 La Quints, CA 9=63 _ �� ,,, bIAA Proposed Adjustments 1. The proposed basis of adjustment to the Contract sum or Guaranteed Maximum Price is: [ ] Lump Sum (increase/decrease) of ( ] unit Price of per t ] As provided in Subparagraph 7.3.6 of AIA Document A201, 1997 F-dition. [ ] Time and Material not to exceed [ ] as follows: Z. The contract Time as a result of this n � der � not delay the project. e unchanged. 3. Approval Required by Upon ezecu0on by the Architect and Owner, this direOtNe shall be effective immediately. sll2{t ARCHITECT NE Address: ddress: By: By; Date. Date: Sheet 1 of 1 . CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 2 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Pace has requested the control panel for the water feature pumps be separated from the golf course irrigation control panel. This additional equipment was not specified daring original bid process. This equipment change has been reviewed and approved by PACE and Dale Wincbester No additional compensation is associated witb this change order Previous Contract Amount Through Change Order No. 1 $111,3969,904.00 Add This Change Order No.2 6,900.00 Revised Contract Total $ $119403 .00 By reason of this contract change order the time of completion is adjusted as follows: 0_ days added/deleted to contract time. The original contrail compk on date is. 11105104 The revised contract compktion date shall be: 11/ 05 /04 Submitted By Approved By We, the undersigned Contractor, have given cau nslderation to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all or, except as may be noted above, and perform all services necessary to complete the above specified work, and here t the amp shown above, which includes all direct and indirect overhead expenses for any delays f,. Accepted By: Title: Contractor: Date: May-07-04 09:26am . From-WEITZ GOLF INTERNATIONAL T-423 P.03/06 F-382 Construction Change Directive TWC, Detailed, Grouped by Number Page 1 of 1 Silver Rock Ranch Golf Course Directive Number. 010 project # G125000 Date Created: 4/6/2004 Silver Rock Ranch Golf Course 79-722 Avenue 54 Le Qulnta, CA 92= Proposed Adjustments 1. The proposed basis of adjustment to the Contract Sum or Guaranteed Maximum Price is: I Lump Sum (increase/decrease) of 2, The Contract Time as a result of this 'work �e 1� be �unchanged. eproject. 3. Approval Required by Upon execution ky the AmhKed and Owner, Inis dim" shall be effective immediately. ARCHITECT r Address: ddr By By, Date: Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 3 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Credit due to the cbame from the Signature Control System to the Rain Bird Control System. This equipment change has been reviewed and approved by Dale Winchester No additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 2 $11,403,804.00 Delete This Change Order No.3 -40j.MQ,pp Revised Contract Total $ $11,363 .00 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contrail completion date is.11105104 The revised contract completion date shall be: 11/ 05 /04 Submitted By: J Approved By: Date: / y Date: 05-12-04 We, the undersigned Contractor, have given careful co erasion to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all materials : or, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby acc amount s n above, which includes all direct and indirect overhead expenses for any delays. I -:;� - W Accepted By: Title: Contractor: Date: Il/� Construction Change Directive TWC, Detailed, Grouped by Number Page 1 of 1 Silver Rock Ranch Golf Course Directive Number: 007 Project # G125000 Date Created: 5/ 4/2004 Silver Rock Ranch Golf Course 79-722 Avenue 54 La Quinta, CA 92253 Tel:909-322-2708 Fax: 909469448491 Proposed Adjustments 1. The proposed basis of adjustment to the Contract Sum or Guaranteed Maximum Price is: [ ] Lump Sum (increase/decrease) of 2. The Contract Time as a result of this work will be unchanged. 3. Approval Required by in order to not delay the project. Upon execution by the Architect and Owner, this directive shall be effective immediately. ARCHITECT WNE Address: Address: By: By: Date: Date: �. L Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 4 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Credit due to the elimination of ProMe from the areens mix material. This is a recommendation from Ted Horton agronomist for Palmer Course Design Company. Recommendation reviewed and approved by Erik Larsen No additional compensation b as.�ociat,�with this chance order Previous Contract Amount Through Change Order No. 3 $119,3633,804.00 Delete This Change Order No.4 $-70,278.00 Revised Contract Total S $119293,526.00 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 11/ 05104 Submitted By: �-- Date: 05-12-04 " 7� Approved Ey. Date: w i�l I We, the undersigned Contractor, have given provide all equipment, furnish all n ter specified work, and here Accepted By: 100001C Contractor:A146� d&AL- P*o�— Whud*on to the change proposed and hereby agree, if this proposal is approved, that we will as may be noted above, and perform all services necessary to complete the above "amounts above, which includes all direct and in& t overhead expenses for any delays. Title: 'ill mywlk Date: mtovl /q J 74�q_ `May-07-04 09:26am From-WEITZ GOLF INTERNATIONAL T-423 P.06/06 F-382 05/07/2004 Silver Rock Resort Weitz Golf Construction, Inc. Project: G12500 43525 Ridge Park Drive, Suite 200 Mix.B{end_Deductive.Proposal CCD Exhibit Temecula, CA 92590 Scope of Work: Replace the originally bid blend of s5:15 $and/Profile Root Zone Mix for 90:10 Sand/Dakota Peat MOSS Root Zone Mix Description of Work Qty Unit Unit Price Total 44.70 $ (307,983.00) Credit Mix per original Specifications M0 TN $ 34.50 $ 231,705.00 Replace with 90:10 Blend Subtotal $ (70,278.00) Change Qrder Re nest 70,278.00 Richard G.Stevens Date: Weitz Golf Construction, Inc. P ved y. Date: a, o 5 OF CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 - 07C CONTRACTOR: Weitz Golf International Sheet 1 of 1 CONTRACT CHANGE ORDER NO. # 5 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Credit due for sand used for tee construction. Sand depth has been reduced from 6" to 4". The reduction has been reviewed and approved by Erik Larsen (05-20-04) No additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 4 $1192933,526.00 Delete This Change Order No.S -47 856.00 Revised Contract Total $ $11 45 670.00 By reason of this contract change order the time of completion is adjusted as follows: 0_ days added/deleted to contract time. The original contract completion date is. 11105104 The revised contract completion date shall be: 11/ 05 /04 Submitted Approved By: Date: 05-21-04 By: /� � • � Date: We, the undersigned Contractor, have gtven provide all equipment, furnish all wm specified work and hereby a Accepted By: Contractor: Mefz 6�/P- q consideration to the change proposed and hereby agree, if this proposal is approved that we will 0 or, ept as may be noted above, and Perform all services necessary to complete the above the amounts own above, which includes all direct and indir erhead expenses for any delays. Title: ZV Date: L'14J 2%�LI Weitz Golf Construction, Inc. 5/13/2004 43525 Ridge Park Drive, Suite 200 Tee.Sand.Material.Change Temecula, CA 92590 Reduce the amount of Sand per bid from 6" to 4" in thickness above grade Silver Rock Resort Project: G12500 CCD Exhibit (2) Description of Work Qty Unit Unit Price Total Tee Sand per bid @6" -8200 TN $ 19.94 $ (163,508.00) Tee Sand per bid @4" 5800 TN $ 19.94 $ 115,652.00 Subtotal $ (47,856.00) Total $ 47,856.00 Ap rov d By: Date: - W y o� �p • � 5 5 OF T9� CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International Sheet 1 of 1 CONTRACT CHANGE ORDER NO. # 6 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Labe # 1 Island at the north end of lake was mass graded to an elevation of 20. Pace required the back portion of the island to be filled to an elevation of 25 with the front to an elevation of 23. Weitz Golf hauled 7,502 cu. vds na, $3.45 to complete the fill. No additional compensation is associated with this change order Previous Contract Amount Through Change Order No. s $111)2453,670.00 Add This Change Order No.6 25 $$1.90 Revised Contract Total $ $11471551.90 By reason of this contract change order the time of completion is adjusted as follows: 0_ days added/delWA to contract time. The original contract comrletion date is. 11105104 The revised contract completion date shall be: 11/ 05 /04 Submitted By Approved By We, the undersigned Contractor, have given car nsideration to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all r cept as may be noted above, and perform all services necessary to complete the above specified work, and here b 1 nt t amount own above, which includes all direct and indirect overhead expenses for any delays. .,Phm Accepted By: Title: Contractor: #MTEnM^TIIMM^L Weitz Golf Construction, Inc. 43525 Ridge Park Drive, Suite 200 Temecula, CA 92590 Silver Rock Resort Project: G1250 5/21 /2004 Island[ 1 ].Cut. Fill. Proposal.xls Note: Base on the elevations that PACE and Heinbuch agreed to for the mounding on the island, the work Is now complete. The back part of the Island is at an elevation 25 Instead of a 27, the front is at a 23 instead of a 25. A total of 7502 cubic yards were placed in this area. Description of Work Qty Unit Unit Price Total Cut and Fill (Long Haul) 7502 CY $ 3.45 $ 25,881.90 Subtotal $ 25,881.90 Weitz nstruction, Inc. Dat . Approved By: Date: Sheet 1 of 1 CONTRACT: SWerRock Resort Golf Course Construction PROJECT NO. 2002 - 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 7 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein descn1W cbAnW or do the fallowing descried work not included in the plans and spexificatiiong for this Contrax. Unless otherwise stated all wolk shall conform to the terms, genentl co ndhions, and spacial provisions of the original Contract. RLQ&B IlO_ftANGE Sewer gM Pot nbk !water credit duetre-l_tion of fort at ttion #2 from (role #12 to bole #14 1 i� 7k�tlk�k#�klnkdc�rdr�t#�t�k�kdnk#�C�k#�Ar�r7�r#�k�r#*�k#�k�rdcdr�dr�kdr#�k��C�+k'rk#�rlr#�r�r#�k�k�#i'�k�r�k�k#*�k*'�k�r�r�r�k�k�r#�r�At#�r�Ar�k#'r�r�t�r�r�r��t�k Previous Contract Amount Through Change Order No. $119,2719,551.90 Deduct This CbMV Order No.7 -2 842.94 Revised Contracx Total $$119M,17dale OL79 By remon of this contract c h mge order the time of completion is stusted as follows: 0 days added/deleted to contract time. ne CM~ aMWk iM date &-1"S no revised contract oomphdou daft shun be 11/ 05 /04 Submitted By: Approved By: */O////o V r We, the undersigned Cond�ctar, lrstnegirert clmrfirl aareidt ►ow to the u1 mgepropaeed d=d hereby drM i this proposal is aAWV VW4 than we will provide all equoment, fwwkh all materials, Perform all labor, except as may be noted above, analperfarm all servuw neMvary to cooWkte the above sped, W world and by accept as full rit the ancount shown abovie, which iwludes all direct and indirect owrrhead expenses for any delays Acre ted ! -71-0 �� T— P By: Tile: contractor: r-� C-�,P L-F �or„�s-t- Date: 2m `f Weitz Golf Construction, Inc. 43525 Ridge Park Drive, Suite 200 Temecula, CA 92590 5/25/2004 Sewer. Potable.ChangesCredit Silver Rods Resort Project G12500 CCD Exhibit Scope of Wont: Reduction in Sesser and Potable 1 VMw scope of wort due to the relocation of the comfort station from hole #12 to hole # 14. Changes directed In the revised shoat SW4 dated May 109 2004 Description of Work t�ty Unit Unit Price Total Credit 6" sewer pipe 1 LS $ (14,225.00) $ (14,225.00) Credit 2" Water Pipe 1 LS $ (9,162.00) $ (9,162-00) Credit Cleanouts 1 LS $ (3,910.00) $ (3,910.00) Subtotal $ (279207.00) Additional Bond and Insurance 2% 1 LS $ (545.94) $ (545.94) Total (27,842.94) Additional Days requested Approved By: Date: 0 i Sheet 1 of 1 CONTRACT: SOverRock Resort Goff Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 8 PW=ant to the terms ofthe original Contract Agreement, You are hereby directed to make the herein descnIW changes or do the following described work not included in the plans and specifications for this Contract. Unless otheawise stated all work shall conform to the terms, general conditions, and special Provisions of the original �. DESCRIPTION OF CHANGE dedueft for fake mWacdoo of Y&E ham #3 #7 North Lake =d the uIdWes of bewb bankers to hole #18 as dirybed by rah er Coame Desim Comnanv. See bW Brie =own dated OS 23;04 No sdditionai compensation is asaociatied whit this change order Previous Contract Amount Through Change Order No. 7 $11,2431,708.94 Add "is Change Order Nab 25 070.62 Revised Contract Total S $ll 779.56 By reason of this contract change order the time of completion is adjusted as follows: 0_ days addW/deleted to cow time. Tlhe wtin l c&Wra t wmrk ion dote Av 1L19SiW The rimed eontnet eewpktion date shall be: I V 051+04 ****��#��****st***s•*�*st***�*s•******�***�*sip*��**��*s:sus•s;f*****�*****�****��*�***�***s•�* Submitted ApprovedI we w4 We, the undersigned Contractor, It w giv x casgW cn' B M a,SM to Me ehawPr*Pose i&xd 1 keneby #Srec if this proposal is alpproved that we will provide all equWnen4 furnish all material.& perform all labor, except as may be noted above, andperform all services necessary to complete the above specified work and accept as, full the amouwt shown above, which includes aU direct and indirect overhead e,Venses for any delays: Accepted P BY Title: ' L(U4A-s 66 CLIJ T- Contractor: I L—C-Z- Dote: Weitz Golf Construction, Inc. 5/26QO04 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Water. Feature.Changes Project: G12500 Temecula, CA 92590 CCD Exhibit Lake and Water feature changes as directed by PACE Engineering. Pending to be proposed arethe Telemetry changes, the added costs (if any) for the increased scope of work on Lake #7 (once we receive a revised plan we will prepare a cost impact analysis), the added costs of the larger Aeration Blower and the changes in cost (if any) of the Turnout Structures once we receive an approved set of plans as approved by CVWD. Description of Work Village Lake #3 — Extend 36" PVC future pipe Village Lake #3 — Deduct Shoreline Rock at one ton per 30 LF Village Lake #2 — Add Rods Wall Village Lake #2 — Deduct Shoreline Rock North Irrigation Lake — Deduct Bio Filter North Irrigation -- Sewer line 1br Bio Filter North Village Lake — Add Beach Bunker #18 North Village Lake — Add Concrete Veneer North Village Lake — Add Shoreline Rock Lake #7 -- Deduct Beach Bunker Additional Bond and Insurance 2% Additional Days requested Approved By: Date. Qty Unit Unit Price Total 40 LF $ 132.25 $ 5,290.00 90 TN $ 114.50 $ (10,305.00) 75 LF $ 270.35 $ 20,276.26 -100 TN $ 114.50 $ (11,450.00) -1 EA $ 13,300.00 $ (13,300.00) -1620 LF $ 4.90 $ (7,938.00) 160 LF $ 214.24 $ 34,278.40 8091 SF $ 2.19 $ 17,719.29 25 TN $ 114.50 $ 2,862.50 90 LF $ 214.24 $ (12,854.40) Subtotal $224,5 9 04 1 LS $ 491.58 $ 491.58 Total 25 1,070.62 � Ta Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 - 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 9 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Additional earthwork for Hole #9, #16, and #18. Increase to square footage of #18 green Three (3) days to be added to contract comoletion date See attached cost breakdown Previous Contract Amount Through Change Order No. 8 $11,2689779.56 Add This Change Order No.9 27 344.71 Revised Contract Total $ 11 96.124.27 By reason of this contract change order the time of completion is adjusted as follows: 3_ days added/deleted to contract time. The original control completion date is. 11105104 The revised contract completion date shall be: 11/ 08 /04 Submitted B! Approved By We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materials, perform all labor, except as may be noted above, and perform all services necessary to complete the above specified work, and eby accept as full the amount shown above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: � Contractor: Z wS7 = Date:�Qrd �- 2-Do4' Weitz Golf Construction, Inc. 5/26/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Bob.Hope.Changes PrOect G12500 Temecula, CA 92590 CCD Exhibit Scope of Work: Changes as directed by the Bob Hope Classic Committee on holes 9,16 and 18. Pricing does not include any changes to the irrigation system due to the revised layout. These changes, If any, will be presented once the irrigation consultant performs the head layout in the field. Description of Work Qty Unit Unit Price Total Earthwork on Hole #9 Cut and Short Haul Fill 1956 CY $ 1.42 $ 2,777.52 Earthwork on hole #16 Long Haul Fill 900 CY $ 3.45 $ 3,105.00 Additional Shaping #16 24 HR $ 250.00 $ 6,000.00 Earthwork on Hole #18 short haul Fill 2281 CY $ 1.42 $ 3,239.02 Additional Shaping #18 35 HR $ 250.00 $ 8,750.00 Additional SF of Green Construction 900 SF $ 0.92 $ 828.00 Additional SF of Green Mix 46 TN $ 34.50 $ 1,587.00 Additional grassing Green 900 SF $ 0:58 $ 522.00 Subtotal $26,808.54 Additional Bond and Insurance 2% 1 LS $ 536.17 $ 536.17 Total $ 279344.71 Additional Days requested 3 Approved By: Date: 1 Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. Pursuant to the terms of the original Cast Agreement, you are hereby directed to make the herein described changes or do the following described work not inchkied in ft plans and specifications for this Contract. Unless otherwise stated all work shall conform to the berms, general editions, and special provisions of the oral Continct PE _ ON OF CHANGE Lou #7 f the fairway bride goift to the maft lake. No itin compensaftn is nssoeiat+ed k cbawe order, Previous Contract Amount Through Change Order No. $119,296124.27 Add This Mop Order NaIA S 1 73. 7 Revised Cart Totid $ 11 12 97.54 By treason of Ibis contrast d =V order the timme of completion is adjustead as follows: 3 days adclod/delated to coo bma time. The wWad eao &wd eon Awe is.-11/MW TM re vied csntraet c"pletien date W" be: 11/ 08 /iO4 Submitted Approved By *7-.. 2 r J Y We, die Agreed Contractor, to the cdrarwprnpwa mrd 1 rerrby agm if this proPoW is gwroveA that we will provide all equ4went firr m all . =ept arr may be noted above and pwfom all services memary to cowkte the above Vft- ud work and I nt the spawn above, which ind u&r ell direct and M&rrect overhead expenses for any delays ?k' Accepted By. Tide. Contractor � Date. O/Zol Saw f fork Resort Weitz Golf Constructim, kv- f/17iL004 pr*ct: G12500 4=5 Ridge Park Drive. SU16 200 Lake 7 Changes CCD EAW (2) Temecula, CA 92590 Lake and Waller Feat um chan9m on Lake #7. Based on the revised grading plan Pfovkled to Weitz by Woad Bros. Description of Work Lake #7 — Deduct Liner with Earth Cover Lake #7 - Duct shoreline ROC* Lake #7 .—• Deduct Flock Wall Lake #7 — Add Grass Site Lake #7 -- Add Concrete Veneer Additional Bond and kmnance, 2% Additional Days isquesiffid Oty Unit Unit Pride Total 7160 LF $ 0.48 $ (3,436.80) -40 TN $ 114.50 $ (4,580.00) -310 LF $ 270.35 $ (83.8W.50) 310 LF $ 35.50 $ 11,005.00 44100 SF $ 2.19 $ 96.E 00 Subto�t $ 15,758.70 1 LS $ 315.17 $ 315.17 0 o� �o � 5 Irowau�� na 5 OF 'T1� CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International Sheet 1 of i CONTRACT CHANGE ORDER NO. Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE 1 gallon Pampas grass were bid as specified on the plans. There are no 1 gallon Pampas grass available at this time. This chanee order is to replace the 1 gaffon with 5 gallon. No additional compensation is associated with this change order See attached cost breakdown Previous Contract Amount Through Change Order No. 10 $113,312,197.54 Add This Change Order No.11 63077.31 Revised Contract Total $ 119,318,274.85 By reason of this contract change order the time of completion is adjusted as follows: 3 days added/deleted to contract time. The original contract conrkdon date is. 11105104 The revised contract completion date shall be: I1/ 08 /04 Submitted By. Approved By: 06-1&04 7- z --CAI We, the undersigned Contractor, have givengosefuPwnsideradon to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all m 8; p m all labor, except as may be noted above, and perform all services necessary to complete the above specified work, and here s ent the am nt shown above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: �4)V7kldv Frei �,, /�,� � Date. 3a 61 o�l Contractor: L/t/ ,y Weitz Golf Construction, Inc. 6116 004 Silver Rods Resort 43526 Ridge Park Drive, Suite 200 Pampas.Grass.Change Project G12500 Temecula, CA 92500 CCD Exhibit Scope of Work: PAgAace 1 Gallon Pampas Grass with 5 Gallon Pampas Grass. This change must take place due to the fact that 1 gallon plants are not available. Pinnacle Design has approved this change. Description of Work city increase container size from 1 gallon to 5 gallon 1 Additional Bond and Insurance 2% 1 Additional Days requested 0 O(Of/p/O f By: Unit Unit Price Total LS $ 5,958.15 $ 5,958.15 Subtotal $ 51,958.15 LS $ 119.16 $ 119.16 Total 6 .31 s ; V Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 12 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Installation of 18' cart oath bridge that was missing from plans during bid process No additional compensation is associated with this change order See attached cost breakdown Previous Contract Amount Through Change Order No. 11 $111,3189,274.85 Add This Change Order No.12 25 219.50 Revised Contract Total $ 11,343 494.35 By reason of this contract change order the time of completion is adjusted as follows: 3 days added/deleted to contract time. The original contact con0rkdon date is. IL05104 The revised contract compkdon date shall be: 11/ 08 /04 Submitted Approved We, the undersigned Contractor, have given provide all equipment, furnish all specified work, and hereby Accepted By: Contractor: t� %7,C90 06.30-04 7-- 2 — # A.J consideration to the change proposed and hereby agree, if this proposal is approved that we will all labor, except as may be noted above, and perform all services necessary to complete the above amount shown above, which includes all direct and indirect overhead expenses for any delays. Title: Date: r r Weitz Golf Construction, Inc. 6/25/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Bridge on #18 Project: G12500 Temecula, CA 92590 CCD Exhibit Scope of Work: Construct a cart bridge on Hole #18 per detail J on sheet WF20 of the Water Featrure construction plans. Description of Work Qty Unit Unit Price Total Cart Bridge per Detail, approximately 18' long. 1 EA $ 24,725.00 $ 24,725.00 Subtotal $ 24,725.00 Additional Bond and Insurance 2% 1 LS $ 494.50 $ 494.50 IL Total $ 25,219.50 0 By: Date: x ` (. - .'s 1B T a itf 4 �W Qu1�1w Sheet 1 of 1 CONTRACT: SWerRo& Resort Golf Comes Comumction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf international CONTRACT CHANGE ORDER NO. # 13 Pursuant to the terms of the original Contract Agmemeet, You are hereby died to make the herein described changes or do the following descr'bed work not included in the plans and specifications for this Contract. Unless otherwise swed all work shall conform to the terms, general conditions, and special provisions of the original Contract. ._DESCRIPTION OF CHANCE II&CO . to The cad tb on bole #17 w►M abo serve ss seem for kMe deliveryto We hTkxd-0K ina"WthecalItpytb ddelumm 11rom 4" to 6" sad width from 109 to 12". No addiitioael comoeaaatioa is associated Milk this ARM" order See attacbed cost breakd—own prewious Contract Amount Through Change Order No. 2 $11,343,494.35 Add This Cbmp Order Na13 41 46.35 Revised Cat Tola1 $ 11 740.70 BY reason of #his t ontrad chmw ceder the tim of Compktion is adjusted as follows: 3_dgs added/dekted to c mUnd time. 7U wtbd cM&wd conf"m dale is.• HASW The revised contract compkdom date AM be: J V OB 184 Saber B Approved A We, the undersigned Contractor, havrgivrw enwsi dos- to tyre dWwptnpe d and hereby dWW &W pm js�'oveA that we will provide all' equipment, famish all matermis, perform all labor, c wept as may be noted above, and perform all services necessary to complete the shave spec#Ud work and hereby awept ace, full paayment die amount shown above which includes all dibsd and.indbwet overhead expenses for any delam. Accepted W: Title:_, Date: Contractor: Weitz Golf Construction, Inc. 6/25/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Pump.Stabon.Access.Road Project: G12500 Temecula, CA 92590 CCD Exhibit Scope of Work: Install Cart path on hole #17, 6" thick, I wide to allow service vehicle to access the Pump Station. Description of Work Cart Path 8' Wide 4" thick Cart Path 12' wide 6" thick u4 Goq5e Additional Bond and Insurance 2% Approved By: Date: CIY -8960 23280 `l 0 Unit Unit Price Total SF $ 1.85 $ (16,598.40) SF $ 2.45 $ 57,036.00 $ r 1$ Subtotal 40,437.60 LS $ 808.75 $ 808.75 Total 41,246.35 Sheet 1 of 1 lilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 14 pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE The location of main switch gear along Ave 52 was chanted by GMA. The new location west of entry road and behind #2 green created a revision of the DID connection along Ave 52. No additional comuensation is associated with this change order See attached cost breakdown ***dc>k****7kM#NdedtWWMW M�k�kr.a..rr..r.��.,b.,��,tr4�ir�r�r�tr�r�lr�k��k�k�k�k�lt�k�k�k�k�le�k�t�t�k�k�k�k�kde�lydrdetk�k�r�k�kde�lr�kdc�k�r�k�k�t�k�t�r�kdc�c�k�tt�t�t�k Previous Contract Amount Through Change Order No. 13- $119384,740.70 Add This Change Order No.14 63 147.84 Revised Contract Total $ 11447 88.54 By reason of this contract change order the time of completion is adjusted as follows: 3 days added/deleted to contract time. The original contras compledon date is. 11105104 The revised contract completion date shall be: 11/ 08 /04 Submitted A Approved BI 07-26-04 7/3 We, the undersigned Contractor, have gtvtn CWTfid consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mate ' orm all labor, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby ten ce ount shown above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Date: Contractor: Weitz Golf Construcdon, Inc. 7/2&2004 Silver Rods Resort 43525 Ridge Park Drive, Suite 200 tID Changes Project: G12500 Temecula, CA 92590 CCD Exhibit Scope of Work: 1113 revisions to the electrical scope or work as described in the breakdown presented on 7M6/04 (see attached). Description of Work Additional costs due to 1113 revisions Additional Bond and Insurance 2% MY Unit Unit Price TOW 1 LS $ 62,020.20 $ 62,020.20 Subtotal $ 62,020.20 1 LS $ 1,127.64 $ 1,127.64 TOM $ 63147.84 0 Sheet l of 1 CONTRACT: SWear W& Rewft Golf Coarae Comm ruuC&D PROJECT NO. "M — WC CONT MICrOR: Wentz Golf Interaadong CONTRACT CHMGE ORDER NO. Pursuant to the terms of the original C 0 ad Agemait, You are herby ducted to maim the herein desan'W chsnW or do the followM described work not inchided in the plans and specifications for this Cow. Unless otherwise stated all work shall conform to the terms, genezal conditions, and special proyiskms of the o9rig W Cow. DVVA R1� n OF CHArtC E s..e.ar ..adi.e mud ft iatk sLnnisM t f the 2nM Akroamd #4_tQ 1 - of N- tD 00 k.�.�T 52 Previous Contract Amount Through Change Order No. _l $113,4475,888.54 Add This Chase Order NGAS 29.555.55 Revised Cow Total S 11477 .@9 By reason of this comet d rap order the time of compiedw is 84ustod as follows: Z days addod/deleiod to conUad tmsy. TIC erva d e A"W WMPIWOW "eisa . "S" The rcvbed eonbvd c mpidba date stall bc: 11/ 10104 *W7�*y*e7�_*W*Jlk&#f****w*..h*.*.wY#r*fj**#�f******f*f*�*##*�**�***f*f** j*#ks p*p/*�/*y'��sd**?s*/*�y*��.o*ve#A**jam*O****tJ*J we provide all egwip�ne fr�rnish ria�la, peyfww all labor. except as mybe noted abom and perfom all services necessary to coaWkte the abm *wofted word and hen paysrent the shown aboae, which mc&aite all direct and overhead expemer for any Map. A crapted By. Tide:� .._� . Contractor. Weitz Golf Construction, Inc. 43525 Ridge Park Drive, Suite 200 Temecula, CA 92590 7/28/2004 Silver Rods Resort Storm Drain Project G12500 CCD Exhibit 4 r .' Scope of Work: Install storm drain qy@tsmto ca" waW a10'gy frOM #4 tee complex Into a debris basin. We will install 160 LF of Wr N42 HDPE pipe and one drop shucbKO to captum the water'• pesctiption of Work clty Unit $ Unit Prke 39.32 $ Total 6,291.20 30" N-12 Drain Pipe 160 1 LF EA $ 520.55 $ 520.55 30" Flared End 1 EA $ 1,514.28 $ 1,514.28 30" Drop inlet 4p F Drain with Gravel 500 LF $ $ 7.50 7,850.00 $ $ 3,750.00 7,850.00 Additional shaping 1 1 LS LS $ 9,050.00 $ 9,050.00 Cut and Fill Subtotal $ 28IW6.03 Additional Bond and Insurance 2% 1 LS $ 579.52 $ 579.52 2 Sheet 1 of 1 CONTRACT: SilverRock resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE butaliation of 2" & 3" conduit from golf maintenance to holes #14 & #15 for Hope Classic leader boards No additional compensation is with with this change order See attached cost breakdown Previous Contract Amount Through Change Order No. 15 $1194779,444.09 Add This Change Order No.16 40 197.89 Revised Contract Total $ 11517 641.98 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contrail conrkdon date is:11105M The revised contract completion date shall be: 11/ 10 /04 Submitted B� Approved By We, the undersigned Contractor, have given carejbi considera don to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materials, per all labor, except as may be noted above, and perform all services necessary to complete the above specified world and her_& accept as full paymeaant shown above, which includes all direct and indi t overhead expenses for any delays. Accepted By: 12;01 Title:-/l14,1111 Contractor: Date: Wertz Golf Construction, Inc. 8/3/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Leader.Board.Conduit.South Project: G125W Temecula, CA 92590 CCD Exhibit ti 16 Scope of Work: Install Conduit for future Leader Boards. This work is to be performed only on holes #14 and #15. The remainder of the work required for the entire course will be proposed at a later date. Description of Work MY Unit Unit Price Total One 2" Conduit and One 3" Conduit o holes 14 & 15. 1 LS $ 39,409.70 $ 39,409.70 $ - Subtotal $ 39,409.70 Additional Bond and Insurance 2% 1 LS $ 788.19 $ 788.19 Total 40,197.89 Additional Days '-1 0 !`"Richard G. Stevens Weitz Golf Construction, Inc. Qa q�( Ap y Date: .V Y.. �v � • V V 0 V � • Bmdv' Inc. F.L.RCTRzc,AL C *nRAcroRS 600 Road Pahn Sp by CA 92264 Phone: 760 320-4429 Faac 760 323-3302 June 259 2004 UOmm to Weitz Go>fco�a, ,., Inc. 43525 Ridge Park Drive, Sutra 200 Tcnx=b. CA 92590 Ann: Mc Pickard Sfn mes Re: Sim Rode Resort Bob Hope Saudi Leader Bouds Trench, Conduits & Mr. note an add of $35,827.00 to and instep i ea 2" and 1 ea 3" PVC coodnits to leader board kmsdm "ocatcd at the loath end oftbe pmicm This prioc iwJudes sit ing, cones, poll hose's, alogg with bsdr811 and aoenpactiou Please find attached breaicdawn for a complete review. NWMW Mudv* Inc. Sheet 1 of 1 ' CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 17 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE The removal of the site palm grove. After close inspection the Quality of calm tree found in this grove was very poor and the landscape contractor would not guarantee the palm once transplanted. The onsite grove will be removed and the landscape contractor will provide high quality palm for SilverRocL No additional compensation is associated with this change order See attached cost breakdown Previous Contract Amount Through Change Order No. 16 $1195179641.98 Add This Change Order No-17 67 728.QQ Revised Contract Total $ I 1,585r169.98 By reason of this contract change order the time of completion is adjusted as follows: 0_days added/deleted to contract time. The original contract cong"on date is. 11105104 The revised contract completion date shall be: 11/ l0 /04 Submitted By: Approved By: • g- -tie—W We, the undersigned Contractor, have gimn careful consideration to the change proposed and hereby agree, if this proposal is approveck that we will provide all equipment, furnish all materials, perform all labor, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby a t as full payment the amount shown above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: Contractor: Date: Weitz Golf Construction, Inc. 7/28/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Palm Grove Project: G12500 Temecula, CA 92590 CCD Exhibit �17 Scope of Work: Credit for not harvesting the palm grove per the specifications. In lieu of this work, we will supply and install Washingtonia Falifers "unskinned" of various heights as directed by the Landscape architect. Description of Work Qty Market Palm Grove 1 Credit installation of palm grove 1 Supply and Install Washingtonia Falifera "unskinned" 1200 Additional Bond and Insurance 2% 1 Additional Days request 0 Date: Weitz Golf Construction, Inc. -XprW By: �Dated31�:� Unit Unit Price Total LS $ (10,500.00) $ (10,500.00) LS $ (23,750.00) $ (23,750.00) LF $ 83.88 $ 100,650.00 Subtotal $ 66,400.00 LS $ 1,328.00 $ 1,328.00 Total $ 67,728.00 000 - Iruo�e��4 5 C� OF p4' Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 18 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Fairway #121andine area was raised 2' per the recommendations of the PGA Tour in preparation for the Hope Classic. 12 sprinkler were adiusted to the new finish grade. No additional compensation is associated with this change order See attached cost breakdown Previous Contract Amount Through Change Order No. 17 $11,585,369.98 Add This Change Order No.18 8,731.20 Revised Contract Total $ 119594101.18 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is. 11105104 The revised contract completion date shall be: 11/ 10 /04 Submitted By: Date: M-25=$4' 9 '0 O� Approved By. Date: --U We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if thisproposal is approved, that we will provide all equipment, furnish all materials r I labor, except as may be noted above, and perform all services necessary to complete the above specified work; and hereby acce aye the ant shown above, which includes all direct and ind . overhead expenses for any delays. AcceptedTitle:��' 4"J�L Contractor: Date: Weitz Golf Construction, Inc. 7/29/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Raise #12 Fairway Project: G12500 Temecula, CA 92590 CCD Exhibit Scope of Work: At the recommendations of the PGA, the Landing area on #12 Fairway was raised. Irrigation heads had to be raised and the area had to be re -shaped. Additional Shaping was recommended on hole #18. Description of Work Qty Unit Unit Price Total Raise 12 sprinkler heads 12 EA $ 55.00 $ 660.00 Additrional Shaping 1 LS $ 7,900.00 $ 7,900.00 Subtotal $ 8,560.00 Additional Bond and Insurance 2% 1 LS $ 171.20 $ 171.20 Total $ 89731.20 Sig Weitz Golf Construction, Inc. ,,)q1A0 ' ro ed B Date: 0 Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Conrge ConstrueOon PROJECT NO. 2002 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 19 Pursuant to the teens of the original Contract Ageemad, you are hereby directed to make the herem descnlW changes Or do the following described work not inchxied in the plans and specifications for this Con la Unless otherwise stated all work shall conform to the terms, goal conditions, and special provisions of the original Contract. nF_REnON OF C7E�ANGE E e s d coMMct nestrRM & kitAeo Dad ka m N odditiomg COAMMgM h anodaled MA thia chsnse order ###+Ik#�e#dlr#tiklk##alk�lk####�Ilrilr#�ilr#�k#i�nl�e#dlydlr#lirilr##�It�lr�lir##Ik#tlkdlr####91e###dir##tlk�iir##�iraAr#�Ir####�Ik�lr#�Ikdlr###allr####direr####a1t## pmvious Contract Amount Through Change Order No. 11$119,594.101-18 Add This Change Order No.19 Revised Contract Total j $ 1 By reason of this contract change order the time of eomple ion is adjusted as follows: 0 days sddedldelded to oo hW time. ne orkind coWmd eon At W IIASW The revind contract templedm date sbaN be: I L 10 //04 Date: Submitted By: •4gy."— - 4 1 9 Date: Approved By: '� y We, the u►edersigned Contractor, lore Sim ersid ioeY tb &e p vpos e d and kw4y ago ift�prgpo� Js �'o'� Heat we will ve PWide all eguejwuen4 fW7s&h all , vwept as may be noted above, and perform all services nec�essmy to complete the ela p. spw#kd work, and lane the am shown above, which includes all direct and indirect overhead expense's for any delays. 1'0�4 - Accepted By: 7 Tldie. Contractor: Z Date. Wert� Silver Rods Resort z Golf Construction, Inc. Project G12500 43525 Ridge Park Drive, Suite 200 Pool Demo CCD Exhibit Temecula, CA 92590 Scope of Work: Demo and haul ON sure concrete material from pool. Excavate soil, haul, fill and compact pool cavity. Shape and drain area In of future putting gam. We have excluded any irrigation, feature construction and grassing at this tlms pending review by architect and consultants. Description of Work city Unit Unit Price Total Demo Concrete and debris haul ofTsite 1 LS $ 6,900.00 $ 6,900-00 Fill dirt excavation 1100 CY $ 2.45 $ 2,696.00 Grading and Compaction 1 LS LS $ $ 1,900.00 2'700.00 $ 1,900.00 2,500.00 Drainage Pipe and connection to network 1 1 LS $ $ Additional Dust Control i LS $ 700.00 $ 700_00 Additional Supervision and General Conditions Subtotal 15,. 5.00 Additional Bond and Insurance 2% 1 LS $ 307.90 $ 307.90 Total 1 TOZ.90 Additional CW" requested for this work 0 Page 1 of 1 Sheet 1 of 1 CONTRACT: SHverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Goff International CONTRACT CHANGE ORDER NO. # ZO Pursuant to the terns ofthe original Contract Agreement, you are hereby directed to make the herein descn'bed changes or do the following descril3ed work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, ggneral conditions, and special provisions of the original Contract. DE ' RE"'ILON OF CHANGE d , # of • restraints stall cow,to a_re the nalubne. N s"kk" aunoeaaatioa 38__ tell with this ckaote order Previous Coact Amowt Through ChaW Order No. 19 $111 ,804.08 Add Thits Chance Order No.20 2 983. 0 Revised Contract Total $ 11612 787.58 By reason of this contract change order the time of completion is adjusted as follows: 0 days ad&&dekftd to contrad time. T die orWnW taawrbact wmpWon date W 11/pSW IU revised contract empledw date shill be: 11/ lh 104 ftbnitted By Approved By We, the undersigned Co Duclor, l dWSh m dvW to the chnigepreposed+awd benabp d Vf his proposal is ypproved that we will provide all equipment, 1 sh all nw iwk, t as may be noted above, and perform all services necesscay to complete the above specified work and hereby t t shown which includes all direct and ' overhead expenses for any delays Accepted By: Title.' Contractor: &T7 a Date: Sitver PM�12soo 812 yVeft Gw cOw- inm Jo* t b 8kft #'12 CCO Exhbl 4=6pjogpwK D&M, suite 200 - m all Joint on Main LiM on Hpw 912and #!5- SWpa of Work- � ll� Ur�! P'� Told Dwswiption o[ YVork 7 EA $ 276-W $ I,925.a0 JoK l�� 01 5 �, 00.00 1,000.00- joitt nesnjift Hole #15 $ Subtotai „ "g2500 LS 58.50 $ 58M Addome, Bond aid durance 2% .50 ohtl 4 woQ 4sim %Pw M w" sawn- -1 -- - - Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 21 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE �i1r� �.i.r �rl Irk ■ �� Cost iocrease due to the relocation of the comfort station from Hole #12 to Hole #14. This required an additional MP'Z5 electric�ral navel rrrrrr�l��l�rl No o additional compensation is associated with this change order See attached cost breakdown Previous Contract Amount Through Change Order No. 20 $1196129787.5 8 Add This Change Order No.21 15 360.00 Revised Contract Total $ 11628147.58 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is: IlIV5104 The revised contract completion date shall be: 11/ 10 /04 Submitted By Approved By We, the undersigned Contractor, have given carefi deration to the change proposed and hereby ogree, if this proposal is approved, that we will provide all equipment, furnish all materials labor, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby acce t amount s n above, which includes all direct and indirect overhead expenses for any delays. BY Accepted : Title: h Contractor: Date: 1"/ Weitz Golf Construction, Inc. 8/11 /2004 43525 Ridge Park Drive, Suite 200 Power to Comfort Station #14 Temecula, CA 92590 Silver Rock Resort Project: G12500 CCD Exhibit Scope of Work: Install power on Comfort Station on hole #14. Includes one MPZ5 panel per Dream Engineering plans. (see attached) Description of Work MY Provide power to comfort station on hole #14 per plan. 1 Backfili of trench 1 Additional Bond and Insurance 2% Additional �Riftokd G. Stevens Weitz Golf Construction, Inc. � os llromv'ed—Sy: Date: 1 0 Unit Unit Price Total LS $ 13,750.00 $ 13,750.00 LS $ 1,308.82 $ 1,308.82 Subtotal $ 15,058.82 LS $ 301.18 $ 301.18 Total 15,360.00 Brudvil Inc. �criucAL oo*ncRAczio�s 600 Ro®d PAW Sp*sA CA 922" Phone: 7W 320-"29 Fate 760 323-3= August 10, 2004 Weitz Golf C=tnxtian., . 43525 Ridge Park Drivt,, Suite 200 TCM=1186 CA 92590 AMx Mr. Richard Sftvcm Re: S&r Rock Rind MPZ-5 Chao$e Omar Request Mr. Stevens, pleaw now an add of $12,800.00 to famish and install aU labor mid nEtclial nary to rdocate the w mft MPZ-4 to *e soath comfort stadopi and to add 1 each MPZ-5 atthe k tan station. This price hw&dm an &eochia& co®pa cdon, bad dl conduk and wire. The bulk afore conduit to be used is eaisft as part aMe South Leader Bcmrds condo systean. Ibis was at the mgaast oftbe City. R�espectfoUy Subndttod Toay Brudv& Ehxb* Inc. i Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR Weitz Golf International CONTRACT CHANGE ORDER NO. # 22 Pursuant to the terms of the onginal Contract Agreement, You are hereby directed to make the herein described changes or do the following descry -bed work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE r pbome service wet bower on D E The MjMft syvtomn is tro Tee area to cetr,�t Aye_.8 No additional comaensation is witk this IMM order See attwdied cost b realm,= Previous Coact Amount Through Clams Order No. 21 $11,628J47.58 Add "Is Change Order No.ZZ 1 26,124.21, Revised Contract T $ 11654 1.79 By reason of this comrade change order the time of completion is adjusted as follows: 0 days added/deleted to contt ad time. M orig ad wfift ad awrkWon doe is:• l""i The revieoed ee usd mnpleden date sitttil be: 11110 /04 Submitted Approved We, the undersigned Contractor, "MSbM err ioMe to the doWp4mmadend hereby ftwm ffthis proposal is Wp wrA that we will provide all equ4ment, fm»ish all moteria labor, as may be noted above, and per orm all services necessary to complete the above sped, f ied word and hereby am«u:t hown above, which includes all direct and indirect ovcrhead expemses for any delays Accepted By: Title. Lp Contractor: / Date: 7hl� Ll Weu ra Conswcoon, Inc. 8/1WON 43526 Ridge Park Drive, Suite 200 Telephone Conduit Temecula, CA 92590 Scope of Work: lnstaN one.4" Conduit for telephone from 82 Tee wea to Ave 52 Saver Rodc Resort Project G12500 CCD ExhN* Description of Work CAY Unit Unit Prim Total Approx 2180 LF of 4r Conduit. See Attached 1 LS $ 25,680.60 $$ 25,680.60 Subtotal $ .s Additional Bond and Insurance 2% 1 LS $ 513.61 $ 513.61 Total 19+t.Z1 f7mm- r 'T v• Sheet 1 of 1 CONTRACT: SWerRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Wdit Golf International CONTRACT CHANGE ORDER NO. # 23 Pumwnt to the terms of the original Contract Agreement, You are hereby directed to make the heroin described changes or do the following deem'bed wok not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. No a diti -W conoensativais _amociated ED this ebasge order Previous Contract Amount Through Chaoge Order No. ,M $11,654,341.79 Add Tl k Cbsege Order NOM 90 8.54 Revised Contract TOW S 11744 .33 By reason ofd& eontrad change order the time of completion is adjusted as follows: 0 days added/delcted to c muect time. T1Ue mWad waftW a w#idk a dote IW• MOM The mvinr d contract cmpletWn dxi*:full ba 1U 10 /04 Submitted Br: Approved By: Date.. _ _ -to-a4 We, the undersigned Contractor, l ravegben emVOrl ar to Me choWeprqwed and korby qVVr, if this proposal is 4wrove4 dW we will provide all equipnten4 furnish all material as may be noted above, and per,farm all services necessary to complete the above gwcifkd work, and hereby ount show above, which includes all direct and Indirect overhead far any dekom . �j2lj r C� Accepted BY: Title:.._.,L-l- ILA Contractor: ZAPam— Z CA 11F Date; ZiZJL - 0 Weitz Golf Construction, Inc. 9/2/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 Entry Lake Changes Project: G 12500 Temecula, CA 92590 CCD Exhibit (2) Scope of Work: Lake and Water Feature changes on Entry Lakes. Based on the revised drawing supplied by PACE. We estimate that the grading portion of this work will required approximately 15 days to be completed. However, an allowance of 10 days has been set as a starting point, if additional time Is required it will proceed ONLY after review and written approval of Heinbuch Golf. Description of Work Deduct Liner with Earth Cover Add Liner w/Concrete Veneer Deduct Stream Hole #2 and entry lakes Deduct Concrete Shoreline Add Pond Shoreline Add Rock Add for pipe trench 2' deeper Add for extension 2' of vault, ladder, risers etc. Add 18" PVC Pipe Grading and Earthwork Additional Bond and Insurance 2% Additional Days vv el¢ "Oil k.tx 15u uIUuw 1, if 1%0. city Unit Unit Price Total -15060 SF $ 0.48 $ (7,228.80) 6840 SF $ 2.19 $ 14,979.60 -6150 SF $ 5.59 $ (34,378.50) -740 LF $ 26.76 $ (19,802.40) 200 LF $ 12.82 $ 2,563.00 390 TN $ 114.50 $ 44,655.00 1 LS $ 6,160.00 $ 6,160.00 1 LS $ 1,540.00 $ 1,540.00 1 LS $ 9,504.00 $ 9,504.00 10 DAY $ 7,084.00 $ 70,840.00 Subtotal $ 889831.90 1 LS $ 1,776.64 $ 1,776.64 10 Total $ 90,608.543 Sheet 1 of 1 CONTRACT: saverRock Resort Golf Coarse Construction PROJECT NO. 2002 — 07d CONTRACTOR: Weitz Goff International CONTRACT CHANGE ORDER NO. # 24 Pursmant to the terms of the original Contract Agr+eemeot, You are hereby directed to make the herein dewnlmd changes or do the following descried work not included m the plans and specifications for this Contract. Unless otherwise stated aU work shall conform to the terms, general conditions, and special provisions of the original Cow DESCRIPTION OF OJANgE 0001trudQu is not kdgM in Weitz SQUIEVIL Wdft g2rif RMRMM is to su 10 r feet of 14" P'V eitac WIN a do the 14" M for the turnout at Lose #15, 3Lbj& i M reduce the cost of the #15 turnout it IL Njft has rwaceftd. an mg 12 dam be added to th ect # 2002- QV Pmvious Conhaci Amount Thwugh Change Order No. —23 $113,744 905.54 Add This C'bme Order Na24 14 98.7 Revised Contract Total S 1 1JM9204.32 By reason of this cot change order the tine= of completion is adjusted as follows: 12 days adeted/delebed to coMlt time. fie or46d em owd cmrWox dWe is.• ]AV"# no revised mdra t eompld m date dwN be: 11/ 22 /04 Submitted By:, Approved By2:Li:�� Date.. 1017 /a We, the undersigned Cmawctor, iewShow CwW provide all equowt!r=pq0y" mart r specified world and nWalt/ Accepted Contractor: U�A�, 61r) to tie chamWepwposed dnd hereby ASS sfthis proposal is approve4 that we will pf as *W be noted above, and perfamr all mr wees necasapyto complete the above Wabove, which includes all direct and indirect overhead expensesfor any delay& Title: �t� 1M Date.- Weitz Golf Construction, Inc. 8/27/2004 Silver Rock Resort 43525 Ridge Park Drive, Suite 200 14 inch Well Line Project: G12500 Temecula, CA 92590 CCD Exhibit Scope of Work: Supply and Install3810 Linear feet of 14" C905 PVC pipe, including ductile iron fittings per plan. Our proposal Is ONLY for the installation of the pipe, we have not included any portions of the work pertaining to the construction of the well and related appurtenances required to complete the scope of Project # 2002-07C . Description of Work Qty Unit Unit Price Total 14" C905 PVC Pipe and Fittings 3810 LF $ 35.59 $ 135,590.96 Dust Control 1 LS $ 9,800.00 $ 9,800.00 Subtotal $ 145,390.96 Additional Bond and Insurance 2% 1 LS $ 2,907.82 $ 2,907.82 Total $ 148,298.T8 Additional 12 7 w.4 N My: Richard G. Stevens Weitz Golf Construction, Inc. Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. RLVdQ t1PTIOht OF CHANGE Cost Inere-mn chanjues es b CVWD far Hole #15 -o t s re. Inclnd credit for 14" Q05 PVC replaced by 1_8" Previous Contract Amount Through Change Order No. 24 $11,893,249.73 Add This Change Order No.25 S 23363150 Revised Contract Total $ 11 16 .23 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original condwct compkdon date is: l M"4 The revised contract completion date shall be: 11/ U /04 Submitted By Approved By We, the undersigned Contractor, have provide all equipment, furnish all specified work and hereby. Accepted By: nmw It—In-0'1- /X 2, f /Op V - consideration to the change proposed and herby agree, if this proposal is approved that we will all labor, except as may be noted above, and perform all services necessary to complete the above amount shown above, which includes all direct and indirect overhead expenses for arty delays - Title: (4J oL Contractor: k Date: 1 v o Sheet 1 of 1 CONTRACT: S&erRo& Resort Golf Course Consttnedw PROJECT NO. 200 — 07C CONTRACTOR: Weitz Golf IntamdoiW CONTRACT CHANGE ORDER NO. # Z6 Purmumm6ekrtas ofthe origbW Co fttmt Agreement, you are hereby dimxud to make the heroin described chows oardothe fniknvh g described wo& not included in the pleas and spxiilc�tions for this Contract. Un%ss o�rwise stated all work shall coafotm to the terms, San"om�rdttim% and special ptrovisions of the mWaal Contract N4—�MUM" h.-in! Wid-I M chsAft order Previous ConftW Amount T Ordkrxo• —Z $l 1916,888.23 Add Tim Chug Order N926 Revised Cam Total S 11 .9j By reason of Ws contract dmp order the time ofcompldlon is athwed as follww&- 8 days to contrast time. 7W w4rAW ewVlM%* dote IW- IM" TM.ow combad eempletka dale dwN be: ll/ U /04 SobmWed Approved We. tht rurders:'gntd Contractor, lraais ma Qeu�eja�!' diem to tl rt 4pIddi+tl y d3►aay 'dais pnopo�sal to a ppraysd that wa wilt p vv ik all apdpmeaK fta►ntiah 'ala, alM all labor. crept as nay be seated above, and peerfa�e all stn4m naeisay to comph� the above gmcikd wank and as the amoral` shown above, which indades all direct and indb a overhead eVenses for any delq� 0000 Accepted By. Tithe. Ca►ntractor. Date: W-Z&Li Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 27 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRMLONOFOF,C„HANGE W e labor, ea nipment, and materiab to. s ilize MIMAIIII 4.5 ac, of waste W S k e -spray ni meat aired --for the a tion once as o order. No additional comnensstion is associated with this chance order Previous Contract Amount Through Change Order No. __2¢ $119928,530.91 Add This Change Order No.27 1 7.00 Revised Contract Total $ 11 39 087.91 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The odgind cou&ad caonViWon dote Is. l Ui 5W The revised contract completion date shall be: 11124 /04 Submitted Approved We, the undersigned Contractor, kave given cwVW consideaadan to the changeproposed and kereby agree, f this proposal is approved that we will provide all equipment, furnish all orm all labor, except as may be noted above, and perform all services necessary to complete the above speed wort; and here nt own above, which includes all direct and indirect overhead expenses for any delays&MW : Accepted By: Title. Contractor. �CN��L Cj'�,CJ )IC Date:I l Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 07C CONTRACTOR: Weitz Golf international CONTRACT CHANGE ORDER NO. # 28 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not inchided in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz to rovide r ui men and ma to install 4 .fit: of decom cart at hole #15 green. DG win vo_t in_ in ormi W contract Noadditioaal compensation is associated with thin cbanse order _�. Previous Contract Amount Through Change Order No. 27 $11 939,087.91 Add This Change Order No.28 17x334.22 Revised Contract Total $ 11 56 422.81 By reason of this contract change order the time of completion is adjusted as follows: Qdays added/deleted to contract time. The original cwnftd aompkilon date is.11105104 The revised contract completion date shall be: 11/ 24 /04 Submitted By: Approved By: rxzo;64� HCOFW tk—tet—O `F r Z.... o V.-o y Z We, the undersigned Contractor, have given carpal consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mate ' orm all labor, except as may be noted above, and perform all services necessary to complete the above specified worlti and hereby ac otint shown above, which includes all direct and indirect overhead expenses for any delays. �t LkA [.CA Accepted BY. Title:�'i fuc Contractor. Date: PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 29 Pumniat to the terms of the origirtai Comes Agreernag, you are haeby directed ted to make the heYeem de smW changes or do #w Mowing descr &W w t to included in &e p1m and CoubwL Unless oducwise stated all work shall eonfmm to the tams, gaaaW conditiom and special provisions of the anginal Conft wt. L }.I.._�, �I �.: _i._I.iL 7,7177, <.. a...LiL7..i__�,. _�a_y - _ __._' ..._ �� __i.. .__' �.J, '_. 1 ! ( i1_ 1 1 1 + 0 T_l K,%Ti�' Imo'..._ i IJ .. .�iI.�M r' J I i.�.L/ 1 ,. �_ 1 �1Ad . Provions Cmaact Amount 7'hough type Order No. --$ $l l y956 422.81 Add "Is Aube Ord Dia29 Revised Caubac** Totd $ 11 77.21 By reason of this eonead cue order the time of complexion is adjosaed as follows: 0 days to contma time Tie MW*W mood comple" dWe &- I"S✓rK IU revered mdnm t eeeaple dm dab sWU ber. 11/ 24 /84 fs:��t*#�*��*eat**s•t�**sretf***ts;**��#tar***�#��#*�f**�**�f**��***�*�*******�#�tt#*#*tet#�s•t Submitted By: Approved Dr., We, Ow axnderslftd Contractor, imiegirm provide all equonwKlitr bh aU mwmd&W spec#W work and lxnby aes Ir4 1 iw1 Contmctgr 4a�- -�� Go IF- . lAk,� -z -',�-_0 4 � to tie chaWpopmed md kawby ##rw, ifthisp„wpasd is approevc4 &at we will nt , awept as that' be noted above, andpwfarm all services necessmy to cosq*m the above dee spawn above, wh" inL',&&r all a npa and In4*wt overhead afor aW delays. Date: .0� W�� I A f fl Sheet 1 of 1 CONTRACT: S%iverRock Resort Golf Comae Construction PROJECT NO. 2002 — 07C CONTRACTOR Weitz Golf International CONTRACT CHANGE ORDER NO. 30 to the teems ofthe original Cow A a m k your am hereby directed to make the herein described changes or do the following des rAW v(k not inchided into ph= and specificationss for this Conicact. L%km o,&uvise stated all work shall. conform to tha terns, SmeW condidom and special provisim of the original Contract t"'Yac . (o Previous Coact Amo mt Thmu& tie Order No- .n $11 y970y M.21 Add This CMW Order No-3d iiovised Contract Total S IlMiM7.67 By ream of Ws cou act d mge ordar the three of coaWiWm is sdjuftd as follows: © days added/ddeted to contract time. Tire at Wad a -so ad coxpdWm ate Ir.- HOW The rmit ed mMratt mmpkdm date dub be: lV 24 /04 u-nifted 1-19,- o U UApproved 4> y o �7Qf%#/#}#wC/fey#��#s/iLr_f,�#`iJi�(#(-lsii�###i.###7f###7##i'#####if#1f#7fif#7. 7f if##if###ifpifr7—_#`#_7_ij)#.Tr#Q####7fQ1#. #�#v(`#'###i]#] we aU "4=wK fiamh aU mamrials. j7�'Ifel9 t aU labor. as xW be moad above, Q►d�orm aU sovkm meommy to comp1m Ow above Vw$ed work, andhmsby amq&I op AM",jshowa above, which Lwh du all d b vct and Wkwa overhead cgmum for mg' dhlcrya. i Accepted By �; Contractor. !Z W 1 - Dates </ (% �Z �ctc� °� �V"QKINiCu Sheet 1 of l CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 071 CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 31 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE �� Sri i��l�r Weitz Golf to ymft labor, eaniament, and materials to install terra water for the fire hydrant at the Golf coarse maintenance building No additional, compensation is associated with this change order See attached coat breakdown Previous Contract Amount Through Change Order No. �3 $1199899527.67 Add This Change Order NoJ1 13 826.87 Revised Contract Total $ 12 003 54.54 By reason of this contrast change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract congWedon date is: 11105104 The revised contract completion date shall be: 11/ 24104 Submitted By: Approved %\,1Ct-0IA 12,...oY O We, the undersigned Contractor, hem given careful Consideradon to the chmye proposed and hereby ague, if this proposal is approved that we will provide all equipment, furnish all materials, 11 labor, except as may be noted above, and perform all services necessary to complete the above speed work, and hereby accept amount s own above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title:�� ~ Contractor: �' Date:-0 16) ,r/ Sheet 1 of 1 CON' TACT: SHverR►ock Resort Golf Coarse Construction PROTECT NO. 2002 — 07C CONTRACTOR: Weitz Golf Internutionol CONTRACT CHANGE ORDER NO. # 32 Purmint to the berms ofthe original Contract Aft; you we h aeby directed to make the herein de mind changes or do the fi)Ibv W descrAW work not inchtided in the plans and sped for this Contract. Unless otherwise sb tod all work shell conform to the tmnsv Swazi conditiaos, and special p visions ofdw original Contract. 7.__717 M' No addii" 90nua a is aseoc" 20 ft,gee order Pnwious Conhu t Amount Through Chop op Order No 31 $12 003 54.54 Add "Is Cbmp Order N632 2.408.00 Revised Contract Total $ 11762.34 BY reason of this eoabm d=e orda tha time ofeompWon is adjastcd as folk we I days aMed/ddeaed to contract time. Tie w4ondewMrMd" emqdWsw doe 1w• .IlMSW IU of aatraat cnq"m dab dwN be: IV 24 /04 Sa11 ft, I Appre"d Dr.. 0-1z- oy We. do �Co�►+a�ctar. isaedirmt uote�trl Qoe "m tie if p�ropoaal is appraNed thaatwr will Pr,vaide all �, Dish all a atertat� labor, axcspt as Dray be nosed above, and perforin all savfces neemmy► to complete d w above q wa* mad #. —..l X I 1A, above; which includes all fdbvet and infdi wt overhead cepenur for any delays. Accepted By: Title. e®for: Date: Sheet 1 of l CONTRACT: SRverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weidz Golf International CONTRACT CHANGE ORDER NO. # 33 Pucauentm the terms ofthe owl CmUM Agreement, You are hereby dheccted to make the herein descried cbmges oardothe following descxlW work not inchided in the plans and specif�alians for this Contract Unless otherwise stated ail vmk shall conform to the tom, g owW conditions, and special provisions of the original Contract. T, S=-:.�L_ ��`..�_. 1it .�.� 1 T'. 1 1 Previous Contract AMOMIt Through Chur Order No...,U $12 005 762.54 Add Thk Cimp Order N&33 Revised Contract Total $ 1290797221.45A4 By reason of d& non A r ! chah�e ofdw the time of c wVkfon is sQusted as follows: 6 days to contract tim& lhewibGcsiie r+rate *gVAW u doe lw IL SW Tie ne►imi o AlnW aoasplsdon date smog bee M U M Su Br, Anomved�• +'+�• iww��i i iwwww�� • - t:-%dt—o4 i�7f7I7f��if��ii��if7�7f��ii 7{'��7f 7f if �if 7f�i��i{iiii 7�7f �7i 7f if �7i 7i�ii 7�7� i��7f 7i�a�7f 7i 1�7�7�if�7s if 7f i�if�7f �i'ii i��7��1f 7�7f7f if 7� 7s 7f 7� Wg the► xwkniped Cax actar, llreriesbm coW eaaeuoiefiml core to the I 1p 1000feawi A*Vby dfM #A& prropasal is approved that we will PVVW9 all a4U"WK fW7dSh all n rials bar, owept as may be nasod above, andperJarss nil swvim neoma y to compkte the above epec#Ud word amd haneby n above, which inchdes all &rwt and indirect ovv*ead c pmw for any dehow AcoepW Bp: AdAA6��tTitle. Contractor. C (Cj Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 34 Pursuant to the terms of the original Contact Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Ad�nal sod required to complete gassing of the Palmer Course & Driving Range Tee „&,_ ning area. TTifsoo=Q $1 ,7" 0_ /ac (Re-grass Tees $28,W.80) - (Holes 3. 4. 5 $150,699.96) Tifdwarf 01) .80/sa.f%t. sod for putting greens $18,480.00 No dditional compensation is associated with this change order Previous Contract Amount Through Change Order No. 33 $12,007,722.54 Add This Change Order No.34 199 799.00 Revised Contract Total $ 129 2079521.54 By reason of this contract change order the time of completion is adjusted as follows: C days added/deleted to contract time. The original coin conpkdon date Is.11/0S/N The revised contract completion date shall be: 11/ 24 /04 Submitted By: Approved l2 ,. o y..,o V We, the undersigned Contractor, have given carfii dderadon to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all mazer' exc pawept as maybe noted above, and perform all services necessary to complete the above spec{fied work and hereby nt he amount n above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: ��►"�' . ' �' Contractor: (� Date: Z dZ 4� 74 4 Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 35 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Additional cost du to revised CVWD electrical requirements . No additional comaensatian is 03oeiated with this change order previous Contract Amount Through Change Order No. ,344 $12,2071,521.54 Add Thin Change Order N6.35 55IQ27.16 Revised Contract Total $ 12 262 58.70 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract com PkdOn date is.11105104 The revised contract completion date shall be: 11/ 24 /04 Submitted By Approved By We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approve4 that we will provide all equipment, furnish all materials, except as may be noted above, and perform all services necessary to complete the above specified work and hereby accept as nt t s I n above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: �f ,��i �=Ad►v� 2 Contractor: Q., '471F Date: T I'r a r �• Ar Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 36 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz to provide all labor, materials, and euuipment to install conduit and cabinet for Verizon telephone connection at Ave No Additional compensation is assoeiated with this change order Previous Contract Amount Through Change Order No. 35 $121,2623,558.70 Add This Change Order No.36 31 s915.07 Revised Contract Total $ 129 294 473.77 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The odlgixW control compkdon date is.11165104 The revised contract completion date shall be: 11/ 24 /04 Submitted Approved 12-!�-04 r 2, — p y..vy We, the undersigned Contractor, l m giwx Car - radon to the chwtge pr+opoeed and hereby Ww, if this proposal is approved that we will provide all equipment, furnish all n ,except as maybe noted above, and perform all services necessary to complete the above specified work and here 1 amount Phown above, which includes all direct and indirect overhead expenses for any delays. • Accepted By: Title. 8Contractor �%� �F— Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 37 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRMY� n N OF CHANGE Weitz to proldde Q labor, rials and eguiment to instaM onsite phone se ' Verjon telmhone demark connection at Ave 52. Temo clubhouse 50nr. Shot link 150nr, okver /media tent 200�tr. Additional Contract Dan 30 *****************46,b*********** *******�*�****�****************************** Previous Contract Amount Through Change Order No. ___36 $129,2941,473.77 Add This Change Order No37 99.12-9.00 Revised Contract Total $ 12 94 72.77 By reason of this contract change order the time of completion is adjusted as follows: 30 days added/deleted to contract time. The original con&ad cork Ion dale la: 11105104 The revised contract completion date shall be: 12/ 24 /04 Submitted By: Approved By: / Z —'V " 'V We, the undersigned Contractor, have given GarVid cons+ide ud" to the dhaage propose d and herby agree, f this proposal is approved that we will provide all equipment, furnish all materia orm labor, except as may be noted above, and perform all services necessary to complete the above specified work and hereby acce cy+rr am own above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title. � � .� � Contractor: W Date: F�e4p�'gA rpp 1 � r Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 - 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 38 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE We r, eguipment, and materials to install 3" conduit from wfteliffear to # 1 for Have No Additional compensation Is aasociated with this change, order Previous Contract Amount Through Change Order No. 37 $12,3949,372.77 Add This Change Order No.38 43500.00 Revised Contract Total $ 129 398 72.77 By reason of this contract change order the time of completion is adjusted as follows: Q days added/deleted to contract time. The 0r41eal cowderct coxrkdm date Is. 11105IN The revised contract empletion date shalt be: 12/ 24 /04 Submitted By: Approved —3-- 4 iL._pV-.oSr We, the undersigned Contractor, havegiven owiefWl consideradon to the change p Wased and hereby agree, if this proposal is approvec4 that we will provide all equipment, furnish all mater' ls, I labor, except as may be noted above, and perform all services necessary to complete the above speed word and hereby amounts awn above, which includes all direct and indirect overhead expenses for any delays Accepted By:.Title: ��AO /t Ll P Contractor: If Date:/ Z ml .r. r �r jj=� Mk Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 39_ Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESC UTION OF CHANGE SK equipment,mate to tall ni men as no on D m E SKI 3 04 Irclaft add_iti., onal general cand,,,_#ons & dost contcoL Ad= Con roct Days > 22 **7k1k*7k*lkM*7kN7k71tlkWW7k7k*��t7k.e.a.r.a.ta..�.,k,lr,lr��l4�r�le�t�tak�ttRtAt*'�k�k�k71e�t7k�k1k�k7k�R�k7k�t�t7k*�e7k11t�t9k�t�*7k7k71t*1k*7k�1'1k1k71e7k�t7k9k�t7k#'�le�t -' ^ -- Previous Contract Amount Through Change Order No...$ $121,3989,872.77 Add This Change Order No-39 S§9s220.1.8 Revised Contract Total $ 12 48819Z.70 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to conftd time. The ortghW eon&ad wmp/d on date is: IUOS/04 The revised a ttreict completion date AM be: 01-14 45 Submitted Approved We, the undersigned Contractor, have given eAmitfid coxddera&n to the changeprepomd and hereby agree" f this proposal is approved that we will provide all equipment, fra nkh all ";;7m except as may be noted above, and perform all services necessary to complete the above speeffied world and here fullshown above, which includes all direct and indirect overhead expenses for any delays• t WV411 Accepted By: Title: Contractor: Weitz Golf International _ Date: 10 4 A -A Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 40 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Correct. DESCR PTION OF CHANGE Adnl�i reau_ired for storm damne repair tbtrouah-out the golf course. Installed by Weitz Golf. No additional compensation is associated with- t„_hu cbanee order Previous Contract Amount Through Change Order No. 39 $1 Z488,192.95 Add This Change Order No.40 41 107.67 Revised Contract Total $ 12 529 .62 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. T9ke original caors"d con ion date is:11/OYN The revised contract completion date shall be: 01-14-05 L Submitted By: Date:,, Z 0� Approved By: Date:=��,� _ We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materials, pe except as may be noted above, and perform all services necessary to complete the above specified work, and hereby accept as s own bone, which includes all direct and indirect overhead expenses for any delays. Accepted By. Title �TWO " Contractor: Weitz Golf International Date: �_ i � t Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 41 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supply temp water vine line for fire protection golf maintenance building 1. Re_locat n of pipe at entrance for Pacific Hydrotech (52.298.58) 2. Inatall pipe below ground at entrance ($2.061.311 3. Rent for Nov & Dec 04 ($7,574.461 No .additional compensation is associated with this change order *********W*W**********dk.".y46464•46***42******************************************************** ^ _ - Previous Contract Amount Through Change Order No. 0 $1295299300.62 Add This Change Order No.41 12 173.04 Revised Contract Total $ 12 5414?3.66 By reason of this contract change order the time of completion is adjusted as follows: kdays added/deleted to contract time. The ori&d control completion date is.1110510t The revised eoatrnct completion date shall be: 01-1445 Submitted By Approved By We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agate, if this proposal is approved' that we will provide all equipment, furnish all materials, bo t as may be noted above, and perform all services necessary to complete the above specified work, and he amount show above, which includes all direct and indirect overhead expenses for any delays. Title: Accepted IRy: Contractor: Weitz Golf International Date: W f � r Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 42 pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DE10iff ON OF CHANGE Weitz Golf nu Hwang to supply labor, equipment, materials. to remove &install terra perimeter fencing Ave 5 —1. I ov A re -install of portable fencin aloneAve 52 for Granite t Padff 18 5 .61 2. Inv# 4763474 Portable fence rent Noy_Dec,18 ($ 4.876.431 3, Iw# 4690 044 Portable fence rent Oct 24-Nov 20 ($4,5K18) 4. Permanent fence rental to fan 15, 05 ($8,970) No additional eomuenaaftn is associated with this change order ##########gate#######�###a•,��,k��r�r�r�tr�c�r##do#######ak###########ilr#d►e##ate#atr�llrate####dlr##�k###atr###########fir Previous Contract Amount Through Change Order No. 41 $12,5411,473.66 Add This Change Order No.42 37s494.39 Revised Contract TWO $ 12 578 OW By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. 71se original contract co Wkdon date Is.- 11105104 The revised contract completion date shall be: 01-14-05 �- t 2 / O� Submitted By: Date: - Approved Date:, 7 �Ilo r PP By We, the undersigned Contractor, have given careful eoadderadon to the change p Wosed and hereby agree, if this proposal is approvett that we will provide all equipment, furnish all ial labor, except as may be noted above, and perform all services necessary to complete the above specified work, and her mount own above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: -� Contractor: Weitz Golf International Date: �� M 1 � , Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 43 Pursuant to the tenths of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz to ■ t su la r u' men materials, to de o reloca 6 Palm la a ers a the temp clubhouse. Tree locations to be marked by Doug Enroth (Pinnacle) No additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 42 $123,5782,968.05 Add This Change Order No.43 9 817.5 Revised Contract Total $ 129,588,785.55 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original conowd congdedon date is.11105104 The revisal contract completion date shall be: 01-14-05 Submitted By Approved By: Date:__& 1, 31,'�s Date: / Y/0 We, the undersigned Contractor, have gim careful conddauden to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mater - , pe bor, except as may be noted above, and perform all services necessary to complete the above specified work, and here own above, which includes all direct and indirect overhead expenses for any delays, i `, J&ti AcceptedTitle: rW � BY: Contractor: Weitz Golf International Date: Sheet 1 of 1 CONTRACT: SiiverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 44 ollowing pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein d a 1 work shallescried onfornes or o h the terms, described work not included in the plans and specifications for this Contract. Unless otherwise state general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE tn install 3 ea. 3" conduits for Hower & communication 1 Additional calendar day Previous Contract Amount Through Change Order No. 43 $1.295883,7E5.55 Add This Change Order No." Revised Contract Total I $ By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By: Approved By: ideration. to the change proposed and hereby agree, if this proposal is aproved that we will We, the undersigned Contractor, have given carefu orm all services necessary to complete the above provide all equipment, furnish all mat �a or abor, except as may be noted above, and pert provide amount own above, which includes all direct and indirect overhead expenses for any delays - specified world and hereby Accepted By: Title. Date: Contractor: Weitz Golf International Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 45 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supyly labor, equipment, materials, to repair damage to golf i 'anon Power wire at hole #11 caused by Landmark Golf staff. No Additional compensation is associated with this change order ************WW*WW��*�**spy.�,��,��r�*�****��**��*��*��**��*�**��****�**�*�****�k�****��* Previous Contract Amount Through Change Order No. 44 $12,596,403.93 Add This Change Order No.45 3177.58 Revised Contract Total $ 12 5"1.51 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract coor"on date is: 11105104 The revised contract completion date shall be: 01-15-05 .r..t,1•,tr�ir�r�rdr,lr �e******ak�lEak�*�Irdkakak�*�e*�*�*ak�kdcdrdle�c�****,k�hakicic��*��*�****dr�rdc***�vkde***��*��*��Ir****ak Submitted B Approved E We, the undersigned Contractor, have given careful consideration to the change proposed and hereby r agree, ifthis srn� ssarysal is app omelet hat we will above provide all equipment, furnish all materials, , cept as may be noted above, and pert specified work, and hereby acce ent t ount own above, which includes all direct and indirect overhead expenses for any delays. Title:` Accepted By: Contractor: Weitz Golf International r��Aov- � t Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supply labor, euuipment, materials, to install additional cart path from #5 tee to # 6 comfort station reguested by Landmark Golf staff. No Additional comoensation is associated with this change order Previous Contract Amount Through Change Order No. 45 $1295995,581.51 Add This Change Order No.46 1,764.21 Revised Contract Total $ 121,601 45.72 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is. 1.1105104 The revised contract completion date shall be: 01-15-05 Submitted By:12i� A - Approved By: -- -a I -Z' I ps- _ 2 We, the undersigned Contractor, have given car J' rsideradon to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mate or, ept as may be noted above, and perform all services necessary to complete the above specified work, and hereby acc nt amount own above, which includes all direct and indirect overhead expenses for any delays. fil Accepted By: Title: i Golf International Date: , OS Contractor: Weitz- Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 47 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the temps, general conditions, and special provisions of the original Contract. DPSRWTION OF CHANGE We Golf In,ernational to supply laborer ent, materials, to demo golf inrisation along Ahamanson for Granite to install sewer. This change order also includes the re -installation of irrigation once Granite work is completed. No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. —4 $12,6011,345.72 Add This Change Order No.47 2 816.62 Revised Contract Total $ 129604162.34 By reason of this contract change order the time of completion is adjusted as follows: Qdays added/deleted to contract time. The original contract completion date U. 11105104 The revised contract completion date shall be: 01-15-05 Submitted By Approved By 2 A3 I bs- Z/V/o s— We, the undersigned Contractor, haw given consideration to flee change proyposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materia n all labor, except as may be noted above, and perform all services necessary to complete the above specked work, and hereby n unt shown above, which includes all direct and indirect overhead e.Venses for any delays. Accepted By: Title._ • Date: )7#/�00S Contractor: Weitz Golf International Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 48 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supply labor, equipment, materials, to remove crass & prepare tee toes for sodding due to lost of ¢rays during grow -in. No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 47 $129604J 62.34 Add This Change Order No.48 11 155.43 Revised Contract Total $ 129 6159317.77 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract conrpletfon date is. 11105104 The revised contract completion date shall be: 01-15-05 31 Submitted By: Date: 0 r Date: Approved By: We, the undersigned Contractor, have given care deration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mate r' cept as may be noted above, and perform all services necessary to complete the above specified word; and hereby amount hown above, which includes all direct and indirect overhead expenses for any delays. qAqvi�; Accepted By: Title: Contractor: Weitz Golf International Date:-7 1 0;-011� � 4r t'..,f { Sheet 1 of 1 CONTRACT: SfverRock Resort Golf Conroe Constraetion PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 49 Pursuant to the berms of the original Coact Agreement, you are hereby directed to make the herein descnlW changes or do the following described work not included is the plans and ruaimiki for this OD act Unless otherwise stated all work shall conform to the terms, general ooadi MS, and special provisions of the original Contract. DESMEMON OF W' tioaal to sn r mea m a nd c es #11 r E Larsen No eoinoeasatba is associated witb i s che,� er Previous Contract Amount Through Change Order No. „ 9 $12,6159,317.77 Add T hk Change Order No.49 S 75 Revised Contract Total $ 12 OQ8.S2 By reason of this contract change order the time of complexion is adjusted as follows: 0 days add e&dekted to contmd time. Ue eertiad eery * d wofftlox date is.- 11/I -SW The rwbed eaub2d ©omplMea dabs dull be: 0145- S Submitted Approved We, the werkiaigned Carrd�ctor, hsrediaeie l d i� sv the caluJrgeprepoaead owd kereby a if this propoff l is approwA that we will provide all eguipmevK f amsh all materials, , except as may be noted atom andperfarm ag services aecaawy to coWkte the above specified work and hereby above, which includes all direct and indirect owhead a wmes for any delays Accepted By.• Title:.._. Contractor. &jjLz Golf International Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 50_ ********** or do the following pursuant to the terms of the original Contract Agreement, you are hereby directed to mak ease stated shall form to the terms, described work not included in the plans and specifications for this Contract. Unless general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE ms�tet'ials. to instaU conduit, wire & PVC pipe from west side of entrance road to main water feature No Additional commensation is associated with this chance order Previous Contract Amount Through Change Order No. $12,628,T8.52 Add This Change Order No.50 1 68 mz Revised Contract Total 1 $ 129,629 B reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. y n date is. Il/05104 The originol contract coo The revised contract completion date shall be: 01-1545 Submitted By: Date: VV/'0 Y Approved By: 'll ************ y if this proposal is roved that we w We, the undersigned Contractor, have consideration to the change proposed and hereby agree, P P aPP provide all equipment, furnish r, except as may be noted above, and perform all services necessary to complete the above work, and here 11 n he am t shown above, which includes all direct and indirec,ov, ad expenses for any delays. specified k Accepted By: Date: Contractor: Weitz Golf International , Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 51 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to su labor ui ment materials for Brudvik to re -schedule the connection of the final section of h• h voltage cable from cul-de-sac to switch ear located at 1A pump station location. Additional cost due to Brudvik worldng out of sea uence. No Additional comaensation is associated with this change order Previous Contract Amount Through Change Order No. 50 $12962%693.25 Add This Change Order No.51 $ 1,551.73 Revised Contract Total $ 129 6319244.98 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. ?lie original conbud conWlenon date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted B Approved By We, the undersigned Contractor, leave given careful consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mate ' a or, ept as may be noted above, and perform all services necessary to complete the above specified world and hereby accept as a amount s wn above, which includes all direct andP irect overhead expenses for any delays. Accepted By: Title: Date: l)Vd Contractor: Weitz Golf International f Y � Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 52 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supply labor. equipment ma___te_rials, for Brudvik to install traffic rated electrical boa in A.hamanson due to the alignment of the clubhouse service entrance. No Additional compensation is associated with this change order WWWWWWWWWW Previous Contract Amount Through Change Order No. 51 $121,631,6244.98 Add This Change Order No.52 2 642.31 Revised Contract Total 129 633 887.29 By reason of this contract change order the time of completion is adjusted as follows: 0-days added/deleted to contract time - The original combod co pldion date is: 11105104 The revised contract completion date shah! be: 01-15-M Submitted By Approved By We, the undersigned Contractor, have Evert Lion to the change proposed and hereby agues, if this proposal is approved that we will provide all equipment, orn all labor except as may be noted above, and perform all services necessary to complete the above specified wort; and here t men he amo t shown above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title. Contractor: Weitz Golf International Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 53 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supply labor, equipment, materials, install irrigation, soil prep, and turf left side cart path #8 green_ area. No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 52 $12,633,887.29 Add This Change Order No.53 15 687.60 Revised Contract Total $ 12, 649,574.89 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By: Date: 1 J Date: Approved By: i' ►� --T We, the undersigned Contractor, have given carefu n to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mate r' orm all or, excep as may be noted above, and perform all services necessary to complete the above specified work, and hereby acce men a ount sho above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: !�f- Date: Contractor: Weitz Golf International� I + 4r Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 54 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supply labor, equipment, materials, to install turnout structures as noted on revised plans per CVWD creating an additional cost to original bid. Changes reviewed and approved by Sonny (Pace) See Attached No Additional compensation is associated with this change order wwwwwwwwww -- -- -- -- -- -- -- - - - previous Contract Amount Through Change Order No. 53 $12,649,574.89 Add This Change Order No.54 $ 15,988.50 Revised Contract Total $ 12, 6659563.39 By reason of this contract change order the time of completion is adjusted as follows: 0_days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted B Approved By oo Date: Date: We, the undersigned Contractor, h to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish a , pe 1 labor, cept as may be noted above, and perform all services necessary to complete the above specified work, and her ept ment a amo shown above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title: � WV46*,: Contractor: Weitz Go ff International Date: 2 Z 4r Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 55 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf international to supply labor, equipment, materials, to trench and backfM conduit for Time Warner cable installation connecting entrance road to special use pad. See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 54 $129665,563.39 Add This Change Order No.55 3,813.68 Revised Contract Total $ 129 669,1377.07 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original conhad completion dote is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By: Approved : PP B Y 311 ( b,:7 Date: `3�xZ'6 We, the undersigned Contractor, have given careful consideration to the change proposed aced hereby agree, if this proposal is approved, that we will provide all equipment, furnish all materia pt as may noted above, and perform all services necessary to complete the above specified work; and hereby accept as the a t s own above hich includes all direct and indirect overhead expenses for any delays. Accepted By: Title: Contractor: Weitz Golf International Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 56 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International to supply labor, equipment, materials, to install 2 ea. 2" conduits for front entrance & water feature lighting. Change order includes credit for wire & conduit not required for installation of water feature aeration system. See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 55 $12,669,377.07 Add This Change Order No.56 $ 2,080.92 Revised Contract Total $ 12, 671,457.99 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is. 11105104 The revised contract completion date shall be: 01-15-05 Submitted By: Approved By: . ?/ I /-.b 6- 4�-10 -5-- We, the undersigned Contractor, have given ccaare�ul-�' the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materiafs, a cept as m be noted above, and perform all services necessary to complete the above specifted'work, and hereby accept amoun hown ab e, which includes all direct and indirect overhead expenses for any delays. Accepted By. Title n,, Contractor: Wertz Golf International Date: SUS Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 57 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE This change order is to adjust the final contract quantities for the items listed below. See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 56 $123,6719457.99 Add This Change Order No.57 102 970.20 Revised Contract Total $ 129 7749428.19 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By Approved By We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all materials, e o e noted above, and perform all services necessary to complete the above specified work, and hereby accept 4s a am own above hich includes all direct and indirect overhead expenses for any delays. au Accepted By: Title:��" Contractor: Weitz Golf International Date: FFM Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 58 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf to provide labor, eauipment and materials to repair golf irrigation, backrill & compact trenches, seed bed preration pre -plant and install sod behind #8 areen along cart path after sewer repairs performed by others. See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 57 $1237741,428.19 Add This Change Order No.58 12 810.04 Revised Contract Total $ 129 787438.23 By reason of this contract change order the time of completion is adjusted as follows: 0-days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By; Approved By: We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all mate ri , ept as may be noted above, and perform all services necessary to complete the above specified work and hereby pay t amount own above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title. Weitz Golf International Date: 0 09 Contractor: . Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 59 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf monthly rental expenses for temp water for golf maintenance Are protection. City account in progress with Rain for Rent See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. _M $12,787,238.23 Add This Change Order No.59 3,490.47 Revised Contract Total $ 12, 790 728.70 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is. 11105104 The revised contract completion date shall be: 01-15-05 Submitted Approved 1 r Da+'M lee 31 We, the undersigned Contractor, have given ideradon to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all a abor, exc t as maybe noted above, and perform all services necessary to complete the above specified work; and her, Il ent t amounts wn above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Contractor: Weitz Golf International Date: 3 �%-S Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 61 pursuant to the terms of the original Cow Agre ment, You are hereby directed to make the herein described changes or do the following desenbed work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the teams, general conditions, and special provisions of the original Contract - DESCRIPTION OF CHANGE installation through canal boring, re-shapin¢ & u�ation sdlustment abng canal hole # - See ttached No Additional comuens &n is associated with this change order previous Contract Amount Through Change Order No. $12,790,72E.70 Add This Chums Order Na60 Revised Contract Totals $ 12, 8204A.70 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to conhad time. ne origival a Wad aampledox date is: 1 110"4 The revised coe mct completion date shall be: 01-15-03 Submitted Approved We, the undersigned Contractor, Jr Wgfve�t pvvkk all equipmen4 all specifledvork and hereby ac nt the qr Accepted By: the chaiggepwposed and Jker+eby agreg ifthisproposal is approveA that we will xce as may be above, and perform all services necessary to comp or, elete the above --t ems, n ahrnw which includes all direct and indirect overhead expenses for any delay Contractor• Weitz Golf International Title*4) 7 Date: � )06, -Ad - Li Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 61 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf expenses incurred for temp water pipe rental for (Fire Protection) Golf Maintenance Building. See Attached No Additional compensation is associated with this change order ** ********************��**��*��*�******��*��*�**** ******* *** ************* * Previous Contract Amount Through Change Order No. 60 $129,8209228.70 Add This Change Order No.61 12 322.77 Revised Contract Total $ 12, 832,551.47 By reason of this contract change order the time of completion is adjusted as follows: 0_days added/deleted to contract time. The original contract conWletion date is: 11105104 The revised contract completion date shall be: 01-15-05 ****************************************************************************************** Date: Pate: ****************************************************************************************** We, the undersigned Contractor, have given careful co psi anon to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all mate ria except as may be noted above, and perform all services necessary to complete the above specified work, and hereby mount sh wn above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Contractor : Weitz Golf International Date: �/30,/�5 rp� . a I . , -0 f� Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 62 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Final irrigation head count variance for golf irrigation. Quantities verified by Dale Winchester Design, Weitz Goff, United .Irrigation and reviewed by Heinbuch Golf, LLC. See Attached No Additional compensation is associated with this chance order Previous Contract Amount Through Change Order No. 61 $125,8321,551.47' Add This Change Order No.62 + $ 6,831.1 S Revised Contract Total ( $ 12,839938262 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 � i� • � � ��5��:�i%ice �•ri�L r/2Gles- �Ir�Ic�k�ledE�le�k�Ik�e�k�E�e�e�e�4�e�tr�Ic�k�k9F�k�Ir�edF�F�e�e�e�c�e�i�k�k�E�Ic�iesti9F�e�t�e�k�te*�e�k4r�Ya1c9F�1e�e�k�c�k�ir�IF�t�Ies�E�k�e�kde�F�E�esk�le9k�le*4c�1s�e�e�e�ie�r9F�►e�E�k�k�c�k�le*�k We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, except as may be noted above, and perform all services necessary to complete the above specified work, and here pay amount s wn above, which includes all direct and ind' ct overhead expenses for any delays.-4 B3': Accepted Title: P Contractor: r Weitz Golf International Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Goff Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 63_ Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf provided labor, equipment. and materials to repair storm damage caused by a number of rain events daring the months of Sept,R Oct, and Nov through -out the golf course. See._ Attacbed No Additional compensation is associated with this change order Previous Contract Amount Through Change order No. A2 $12,839,382.62 Add This Change Order No.63 133 117.08 Revised Contract Total $ 129972,499.70, By reason of this contract change order the time of completion is adjusted as follows: 0_days added/deleted to contract time. The original contrad conVWon date is: 11105104 The revised contract completion date shall be: 01-15-05 • Submitted By: Date:�.. Approved By: Date:_ C% i We, the undersigned Contractor, hr given carefi deratio�e to the c1 kaxge propaw4 and ltm*y agreA if this proposal is approved that we will provide all equipment, furnish al7l eri ept as maybe noted above, and perform all services necessary to complete the above specified word and hereby ac nt t amount sh n above, which includes all direct and indirect overhead expenses for any delays. �-� Accepted By. Title:' • Date: � �v zoos eitz Golf International 4� 1 Sheet 1 of 1 CONTRACT: SilverR.ock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International's claim for irrigation and landscape delays incurred by their sub -contractor United Irrigation due to CVWD approval, Survey staking, BOR approval, and Hope design changes. See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 63 $1299723,499.70 Add This Change Order No.64 S 116 977.45 Revised Contract Total $ 139 089,477.15 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is. 11105104 The revised contract completion date shall be: 01-15-05 Submitted By: Date: 4 Approved gy. . . / Date: Z s0 r We, the undersigned Contractor, have given careful co ration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materials, bor, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby acc my 1r, n above, which includes all direct and indirect overhead expenses for any delays. Accepted By: Title. ✓� U • Weitz Golf International Date: Contractor. �S 4r r t Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 65 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf International's claim for irrigation and landscape delays incurred by their sub -contractor United Irrigation due to Wood Bros. inability to deliver complete golf holes for shaping per the approved contract schedule See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 64 $131,089,477.15 Add This Change Order No.65 135 472.55 Revised Contract Total $ 139 224 949.70 By reason of this contract change order the time of completion is adjusted as follows: 0_days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By: — VI-M Approved By. • ' • • PP ZZ / 0 Date: ` /Z Srlo 5-- We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all materials, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby me a n above, which includes all direct and indirect overhead expenses for any delays. �u Accepted By: Title. Contractor: Weitz Golf International Date: �U 2� 4r 1 { Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 66 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf ezpenses incurred to provide labor and equipment to install and overate temporary irrigation pump &pipe _due to dela with CVWD a rove Surve staking,BOR a rove and Ho des es. n ch n ql 1 dLske #30lake fill pumps & pi 1#17 irrigation lake), hole #2 lake. and village lakes #3 & #1. Temponry services generators used to power golf irrigation controllers (Hole #12 & A) and the main irrigation pump station. AU generator & pump credits have been included. Original time period for temp services was 3 mos. Actual rental period was 7 mos. See Attached No Additional comVensation is associated with this change order Previous Contract Amount Through Change Order No. 65 $13,224,949.74 Add This Change Order No.66 Revised Contract Total 1 $ By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original compact coi Wpledon date iss 1 U05104 The revised contract completion date shall be: 01-15-05 b 0'S Submitted By. - Approved By: We, the undersigned Contractor, have given car+efre ton to the ckenge proposed and 1 VvbY qVW, if th'sProPosal a approved that we will provide all equipment, furnish all ma t as may be noted above, and perform all services necessary to complete the above work, and hereby a a unt s above, which includes all direct and indirect overhead expenses for any delays - specified Accepted By: Title. • 'pal Date: 3Q Contractor: Weitz Golf International '000� �PP - 4r: t Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 -- 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 67 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf expenses incurred to provide labor and equipment to install and operate temporary irrigation pump & pipe due to Wood Bros. inabiUty to deliver complete holes for shaping per the approved contract schedule (Village Lake #31, lake fill pumps & pipe (#17 irrigation lake), hole #2 lake, and village lakes #3 & #1, Temporary services include temporary generators used to power golf irrigation controllers (Hole #12 & #1) and the main irrigation pump station. All generator & pump credits have been included. Original time period for temp services was 3 mos. Actual rental period was 7 mos. See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 66 $133'520J 84.89 Add This Change Order No.67 36 842.77 Revised Contract Total $ 139 5579027.66 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is. 11105104 The revised contract completion date shall be: 01-15-05 Submitted B Approved By wwwft' . tr�w .,✓ •" - `_ice • �: r We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all materials, no 1 labor, except as may be noted above, and perform all services necessary to complete the above specified world, and hereby ac�c ,�i the am shown above, which includes all direct and ind rect overhead expenses for any delays. .�� Accepted By: Title: I(LOCPOI Contractor: Weitz Golf International Date: �� s loop, 3 ! i/ Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 68 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE _Weitz Golf credit for Change Order #17 (Waste Area Stabilization). Remaining areas to be stabilize (holes 1 thru 9,11, and 12) by Doug Anderson (Landmark). Weitz to supply sprayer and chemical which was purchased as part of this change order. See Attached No Additional compensation is associated with this chance order Previous Contract Amount Through Change Order No. 67 $13,557,027.66 Add This Change Order No.68 -1 893.12 Revised Contract Total $ 139 555134.54 By reason of this contract change order the time of completion is adjusted as follows: 0_days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By Approved By • /40 ��Irdcalle�k�c$e91e�k�r4c�c�e�ic�c�tr�e�te�k�e�ak,t�k�k�c�k,F�le�e�tc�e�ks�e�lr�e�c�lriieak�fcat��te*�fc�E�e�dc�k�t�e�rik�lr�ir�t�cak�lr�fc��ic�k�icdedc�csir�c�cdc��est�+c�t�k�k�*�1r�k�c*�c�lr�ic�ic We, the undersigned Contractor, have given careful co eration to the change proposed and hereby agree, if this proposal is approved that we will provide all equipment, furnish all ma ept as may be noted above, and perform all services necessary to complete the above specified work, and hereby ac t mount sh n above, which includes all direct and indirect overhead expenses for any delays. Title:q� - � 1� � �' Accepted Ey. - Contractor: Weitz Golf International Date: Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 69 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf rental expense incurred during the month of Jan for a second temp water vibe line for (Fire Protection) Golf Maintenance Building. This second line was required during the relocation of the temp line along Ave54 for ParkWest to continue grading of the perimeter landscape. See Attached No Additional compensation is associated with this change order Previous Contract Amount Through Change Order No. 68 $13,5551,134.54 Add This Change Order No.69 $ 112582.26 Revised Contract Total $ 13, 566,716.80 By reason of this contract change order the time of completion is adjusted as follows: 0-days; added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 01-15-05 Submitted By Approved By S� 2. Y— 0J— We, the undersigned Contractor, havegiven careful consideration to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all materia labor, except as may be noted above, and perform all services necessary to complete the above specified work and hereby a own above, which includes all direct and indirect overhead expenses for any delays. Accepted By. .. Title: ' 1'w0-5 Contractor: Weitz Golf International Date: 1 Sheet 1 of 1 CONTRACT: SilverRock Resort Golf Course Construction PROJECT NO. 2002 — 07C CONTRACTOR: Weitz Golf International CONTRACT CHANGE ORDER NO. # 70 Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE Weitz Golf to install additional electrical & telemetry equipment to operate turnout structures as directed by CVWD Brudvik to perform this work. See Attached Additional Days: 42 Previous Contract Amount Through Change Order No. 69 $135661716.80 Add This Change Order No.70 $ 37,296.05 Revised Contract Total $ 139 6049012.85 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date is: 11105104 The revised contract completion date shall be: 02-27-05 Submitted B Approved By We, the undersigned Contractor, have given careful coy anon to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all materials r r, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby acc toun wn above, which includes all direct and indirect overhead expenses for any delays. _Accepted By: Title: a - Contractor: Weitz Golf International Date. • J s CONTRACT: CONTRACTOR: RECEIVED 14&t 4 -tP Q " SEP 2 1 Weitz Golf International Sheet 1 of 1 SilverRock Resort Golf Course No. 1 Construction Project No. 2002 — 07C Weitz Golf International CONTRACT CHANGE ORDER NO. # 71 *********************************************************************************** Pursuant to the terms of the original Contract Agreement, you are hereby directed to make the herein described changes or do the following described work not included in the plans and specifications for this Contract. Unless otherwise stated all work shall conform to the terms, general conditions, and special provisions of the original Contract. DESCRIPTION OF CHANGE: Additional sod quantities ordered to complete the golf course for opening. The additional sod was installed at various locations throughout the golf course. See Attached. Additional Days: 0 x.v. y.x .Y..*444as********************************************************************** Previous Contract Amount Through Change Order No. 70 $ 13, 604,012.85 Add This Change Order No.71 $ 27,590.67 Revised Contract Total $ 13,631,603.52 By reason of this contract change order the time of completion is adjusted as follows: 0 days added/deleted to contract time. The original contract completion date was: 1 1 /05/04. The revised contract completion date is: 02-27-05. *********************************************************************************** Submitted B Approved B O y. /D Date: y: Date: We, the undersigned Contractor, have given careful consideration to the change proposed and hereby agree, if this proposal is approved, that we will provide all equipment, furnish all materials, perform all labor, except as may be noted above, and perform all services necessary to complete the above specified work, and hereby accept as full payment the amount ich includes all direct and indirect overhead expenses for any delays. Accepted By: Contractor: Weitz Golf International Title- Date: T:\PWDEPT\PROJECTS\3—COMPLETED PROJECTS\2002 Prjcts\2002-07 SilverRock Resort\2002-07 C Golf Course\Construction\CCO PLEASE COMPLETE THIS INFORMATION RECORDING REQUESTED BY: JUNE S. GREEK, City Clerk AND WHEN RECORDED MAIL TO: CITY OF LA QUINTA Attn: June Greek P. 0. Box 1504 La Quinta, CA 92247-1504 DOO # 2006-0400787 06/01/2006 08:00A Fee:NC Page 1 of 2 Recorded in Official Records County of Riverside Larry W. Ward Assessor, Count RE C E I 1 �+� Lc Y Clerk & Recorder 206011UN15 Pn1?S5 CITY Or LA QUIIIlTA 'IT t' CLEni\"'S OFFICE M S U PAGE SIZE DA PCOR NOCOR SMF MISC. 4::::LAJR7 L COPY LONG REFUND NCHG EXAM NOTICE OF COMPLETION Arnold Palmer Classic Course at SilverRock Resort Project No. 2002-07C Title of Document THIS AREA FOR RECORDER'S USE ONLY THIS PAGE ADDED TO PROVIDE ADEQUATE SPACE FOR RECORDING INFORMATION M L PLEASE COMPLETE THIS INFORMATION RECORDING REQUESTED BY: JUNE S. GREEK, City Clerk AND WHEN RECORDED MAIL TO: CITY OF LA QUINTA Attn: June Greek P. O. Box 1504 La Quinta, CA 92247-1504 SPACE ABOVE FOR RECORDER'S USE ONLY NOTICE OF COMPLETION NOTICE IS HEREBY GIVEN: 1 . That the interest or estate stated in paragraph 3 herein in the real property herein described is owned by: The City of La Quinta, California, a Municipal Corporation, organized and incorporated pursuant to the laws of the State of California. 2. The City Clerk of the City of La Quinta is authorized and directed to execute, on behalf of said City, any and all Notices of Completion. 3. That the nature of the life of the stated owner, or if more, than one owner, then of the stated owner and co -owners is: In Fee. 4. That on the 16' day of May , 2006, a work of improvement on the real property herein described was completed. 5. The public work improvement is described as follows: Arnold Palmer Classic Course at SilverRock Resort - Project No 2002-07C 6. The name of the contractor for said work of improvement was: Weitz Golf Construction 7. The property on which said public work of improvement was completed is in the City of La Quinta, County of Riverside, State of California, and is described as follows: SilverRock Resort Golf Course, located south and west of Jefferson & Ave 52, consisting of approx. 140,000 sq. ft. of Greens, 335,000 sq ft. of Tees, 213,000 sq ft. of San Bunkers, 50 acres of Fairways, 75 acres of Rough, 18 acres of Lakes, 25 acres of Native Area Landscape, Driving Range and 30,000 linear feet of Golf Cart Path DATED: May 22, 2006 CALIFORNIACITY OF LA QUINTA, BY: X _ TITLE: City Clerk STATE OF CALIFORNIA 1 COUNTY OF RIVERSIDE ) I hereby certify that I am the City Clerk of the governing board of the City Council of the City of La Quinta, the political subdivision which executed the foregoing notice and on whose behalf I make this verification; that I have read said notice, know its contents, and that the same is true. I certify under penalty of perjury that the foregoing is true and correct. Executed at La Quinta, California on May 22, 2006 JUNE S. GREEKx",074 ,s Q� erk...,< City of La Quint ;`"ra